Termination or Abandonment Notwithstanding anything in this Agreement to the contrary, this Agreement may be terminated and abandoned at any time prior to the Effective Time, whether before or after any approval of the Merger by the stockholders of the Company: (a) by the mutual written consent of the Company and Parent; (b) by either Parent or the Company if the Merger shall not have been consummated on or prior to June 30, 2012 (the “End Date”), provided, however, that if all of the conditions to Closing, other than the condition set forth in Section 6.1(c), shall have been satisfied or shall be capable of being satisfied at such time, the End Date may be extended by Parent or the Company from time to time by written notice to the other party up to a date not beyond December 31, 2012, the latest of any of which dates shall thereafter be deemed to be the End Date; and provided, further, that the right to terminate this Agreement pursuant to this Section 7.1(b) shall not be available to a party if the failure of the Closing to occur by such date shall be due to the material breach by such party of any representation, warranty, covenant or other agreement of such party set forth in this Agreement; (c) by either the Company or Parent if an injunction shall have been entered permanently restraining, enjoining or otherwise prohibiting the consummation of the Merger and such injunction shall have become final and non-appealable; provided that the party seeking to terminate this Agreement pursuant to this Section 7.1(c) shall have used its reasonable best efforts to remove such injunction to the extent such party is required to use its reasonable best efforts pursuant to this Agreement; (d) by either the Company or Parent if the Stockholders’ Meeting (including any adjournments or postponements thereof) shall have concluded and the Company Stockholder Approval shall not have been obtained; (e) by the Company, if Parent shall have breached or failed to perform any of its representations, warranties, covenants or other agreements contained in this Agreement, which breach or failure to perform (i) would result in a failure of a condition set forth in Section 6.1 or Section 6.2 and (ii) by its nature, cannot be cured prior to the End Date or, if by its nature such breach or failure is capable of being cured by the End Date, Parent does not diligently attempt or ceases to diligently attempt to cure such breach or failure after receiving written notice from the Company describing such breach or failure in reasonable detail (provided that the Company is not then in material breach of any representation, warranty, covenant or other agreement contained herein); (f) by Parent, if the Company shall have breached or failed to perform any of its representations, warranties, covenants or other agreements contained in this Agreement, which breach or failure to perform (i) would result in a failure of a condition set forth in Section 6.1 or Section 6.2(f) and (ii) by its nature, cannot be cured prior to the End Date or, if by its nature such breach or failure is capable of being cured by the End Date, the Company does not diligently attempt or ceases to diligently attempt to cure such breach or failure after receiving written notice from Parent describing such breach or failure in reasonable detail (provided that Parent is not then in material breach of any representation, warranty, covenant or other agreement contained herein); (g) by Parent, (i) prior to the Company Stockholder Approval, in the event of a Change of Recommendation or if the Board of Directors of the Company shall have approved or recommended to its shareholders an Acquisition Transaction, or (ii) the Company shall have willfully and materially breached any of its obligations under Section 5.4; and (h) by the Company, prior to obtaining the Company Stockholder Approval and if the Company has complied with its obligations under Section 5.4, in order to enter into a definitive agreement with respect to a Superior Offer; provided that any such purported termination by the Company pursuant to this Section 7.1(h) shall be void and of no force or effect unless the Company pays to Parent the expense reimbursement in accordance with Section 7.3(a) and the Breakup Fee in accordance with Section 7.3(c).
TERMINATION OR SUSPENSION § 9.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or, at the Architect’s option, cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services, the Architect shall give seven days’ written notice to the Owner before suspending services. In the event of a suspension of services, the Architect shall have no liability to the Owner for delay or damage caused the Owner because of such suspension of services. Before resuming services, the Owner shall pay the Architect all sums due prior to suspension and any expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.2 If the Owner suspends the Project, the Architect shall be compensated for services performed prior to notice of such suspension. When the Project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect’s services. The Architect’s fees for the remaining services and the time schedules shall be equitably adjusted. § 9.3 If the Owner suspends the Project for more than 90 cumulative days for reasons other than the fault of the Architect, the Architect may terminate this Agreement by giving not less than seven days’ written notice. § 9.4 Either party may terminate this Agreement upon not less than seven days’ written notice should the other party fail substantially to perform in accordance with the terms of this Agreement through no fault of the party initiating the termination. § 9.5 The Owner may terminate this Agreement upon not less than seven days’ written notice to the Architect for the Owner’s convenience and without cause. § 9.6 If the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall compensate the Architect for services performed prior to termination, Reimbursable Expenses incurred, and costs attributable to termination, including the costs attributable to the Architect’s termination of consultant agreements. § 9.7 In addition to any amounts paid under Section 9.6, if the Owner terminates this Agreement for its convenience pursuant to Section 9.5, or the Architect terminates this Agreement pursuant to Section 9.3, the Owner shall pay to the Architect the following fees:
Amendment, Suspension or Termination of the Plan By accepting this Award, Participant expressly warrants that he or she has received an Award of Restricted Stock Units under the Plan, and has received, read and understood a description of the Plan. Participant understands that the Plan is discretionary in nature and may be amended, suspended or terminated by the Company at any time.
TEN TERMINATION OR SUSPENSION CONTRACTOR shall be considered in material default of this Agreement and such default will be considered cause for OWNER to terminate this Agreement, in whole or in part, as further set forth in this section, for any of the following reasons: (a) failure to begin work under the Agreement within the times specified under the Notice(s) to Proceed, or (b) failure to properly and timely perform the services to be provided hereunder or as directed by OWNER, or (c) the bankruptcy or insolvency or a general assignment for the benefit of creditors by CONTRACTOR or by any of CONTRACTOR's principals, officers or directors, or (d) failure to obey laws, ordinances, regulations or other codes of conduct, or (e) failure to perform or abide by the terms or spirit of this Agreement, or (f) for any other just cause. The OWNER may so terminate this Agreement, in whole or in part, by giving the CONTRACTOR seven (7) calendar day’s written notice.
Permanent Suspension or Prohibition If the Employee is removed and/or permanently prohibited from participating in the conduct of the Bank's affairs by an order issued under Section 8(e)(4) or (g)(1) of the FDIA, 12 U.S.C. ss. 1818(e)(4) and (g)(1), all obligations of the Bank under this Agreement shall terminate as of the effective date of the order, but vested rights of the contracting parties shall not be affected.
No Termination or Abatement Lessee shall remain obligated under this Lease in accordance with its terms and shall not take any action to terminate, rescind or avoid this Lease, notwithstanding any action for bankruptcy, insolvency, reorganization, liquidation, dissolution, or other proceeding affecting any Person or any Governmental Authority, or any action with respect to this Lease or any Operative Agreement which may be taken by any trustee, receiver or liquidator of any Person or any Governmental Authority or by any court with respect to any Person, or any Governmental Authority. Lessee hereby waives all right (a) to terminate or surrender this Lease (except as permitted under the terms of the Operative Agreements) or (b) to avail itself of any abatement, suspension, deferment, reduction, setoff, counterclaim or defense with respect to any Rent. Lessee shall remain obligated under this Lease in accordance with its terms and Lessee hereby waives any and all rights now or hereafter conferred by statute or otherwise to modify or to avoid strict compliance with its obligations under this Lease. Notwithstanding any such statute or otherwise, Lessee shall be bound by all of the terms and conditions contained in this Lease.
Suspension or Debarment In addition to the representations and requirements set forth in Section C.4: (a) The Contractor certifies for itself and Contractor Parties involved in the administration of federal or state funds that they: (1) are not presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded by any governmental agency (federal, state or local); (2) within a three year period preceding the effective date of this Contract, have not been convicted or had a civil judgment rendered against them for commission of fraud or a criminal offense in connection with obtaining, attempting to obtain or performing a public (federal, state or local) transaction or contract under a public transaction; for violation of federal or state antitrust statutes or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements or receiving stolen property; (3) are not presently indicted for or otherwise criminally or civilly charged by a governmental entity (federal, state or local) with commission of any of the above offenses; and (4) have not within a three year period preceding the effective date of this Contract had one or more public transactions terminated for cause or fault. (b) Any change in the above status shall be immediately reported to the Agency.
Suspension or Termination In accordance with 24 CFR 85.43, the Grantee may suspend or terminate this Agreement if the Recipient materially fails to comply with any terms of this Agreement, which include (but are not limited to), the following: 1. Failure to comply with any of the rules, regulations or provisions referred to herein, or such statutes, regulations, executive orders, and HUD guidelines, policies or directives as may become applicable at any time; 2. Failure, for any reason, of the Recipient to fulfill in a timely and proper manner its obligations under this Agreement; 3. Ineffective or improper use of funds provided under this Agreement; or 4. Submission by the Recipient to the Grantee reports that are incorrect or incomplete in any material respect. In accordance with 24 CFR 85.44, this Agreement may also be terminated for convenience by either the Grantee or the Recipient, in whole or in part, by setting forth the reasons for such termination, the effective date, and, in the case of partial termination, the portion to be terminated. However, if in the case of a partial termination, the Grantee determines that the remaining portion of the award will not accomplish the purpose for which the award was made, the Grantee may terminate the award in its entirety.
Certification Regarding Suspension or Debarment Contractor certifies under the pains and penalties of perjury that, as of the date this contract amendment is signed, neither Contractor nor Contractor’s principals (officers, directors, owners, or partners) are presently debarred, suspended, proposed for debarment, declared ineligible or excluded from participation in federal programs, or programs supported in whole or in part by federal funds.
Debarment and Suspension A. The Contractor certifies by entering into this Contract that neither it nor its principals nor any of its subcontractors are presently debarred, suspended, proposed for debarment, declared ineligible or voluntarily excluded from entering into this Contract by any federal agency or by any department, agency or political subdivision of the State of Indiana. The term “principal” for purposes of this Contract means an officer, director, owner, partner, key employee or other person with primary management or supervisory responsibilities, or a person who has a critical influence on or substantive control over the operations of the Contractor. B. The Contractor certifies that it has verified the state and federal suspension and debarment status for all subcontractors receiving funds under this Contract and shall be solely responsible for any recoupment, penalties or costs that might arise from use of a suspended or debarred subcontractor. The Contractor shall immediately notify the State if any subcontractor becomes debarred or suspended, and shall, at the State’s request, take all steps required by the State to terminate its contractual relationship with the subcontractor for work to be performed under this Contract.
