MINOR CHANGES IN THE WORK 7.4.1 The Architect will have authority to order minor changes in the Work not involving adjustment in the Contract Sum or extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes shall be effected by written order and shall be binding on the Owner and Contractor. The Contractor shall carry out such written orders without delay.
For Lump Sum Change Order The payment and extension of time (if any) provided by this Change Order constitutes compensation in full to the Contractor and its Subcontractors and Suppliers for all costs and markups directly and indirectly attributable to the Change Order herein, for all delays related thereto and for performance of changes within the time stated.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Change from Prior Year FY2023 County Executive Request
Rate Redetermination for Market Change In the event of delay or interruption, exceeding 90 days, under B8.33, Contracting Officer shall make an appraisal to determine for each species the difference between the appraised unit value of Included Timber immediately prior to the delay or interruption and the appraised unit value of Included Timber immediately after the delay or interruption. The appraisal shall be done after any rate redetermination done pursuant to B3.31, using remaining volumes. Tentative Rates and Flat Rates in effect at the time of delay or interruption or established pursuant to B3.31 will be reduced, if appraised rates declined during the delay or interruption, to become Current Contract Rates. Increases in rates will not be considered. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to a new Base Rate limitation of the cost of essential reforestation or 25 cents per hundred cubic feet or equivalent, whichever is larger. However, existing Base Indices shall not be changed under this Subsection. Redetermined rates shall be considered established under B3.1 for timber Scaled subsequent to the delay or interruption.
Market Adjustment The parties to this Agreement recognize the appropriateness of market pay adjustments in rare instances for compelling reasons. To effectuate judgments in such cases, the President and AAUP Chapter President, in consultation, shall each name three (3) individuals to a university Market Evaluation Committee. Deans may submit recommendations for market pay adjustments with supporting written reasons to the committee. Said Committee shall consult with the President concerning proposed market pay adjustments reporting its advice not later than May 15 in each year. Upon the favorable recommendation of the President and the Chancellor, market pay adjustments may be approved effective at the beginning of that pay period including September 1 of the following year. Not more than one (1) market pay adjustment per one hundred (100) full-time members, or fraction thereof, may be recommended in any contract year. A member’s salary may not be increased beyond the maximum for the rank. Funding for this program shall be governed by Article 12.10.2.
Bilingual Differential When formally assigned in the employee’s position description, an employee assigned to interpret to or from another language to English will receive a differential of five percent (5%) of base pay.
Market Adjustments 22. Neither this Article nor any other in this Collective Agreement prevents the Employer from using other funds to increase a Member’s salary in response to offers received from other employers or to accommodate other market forces.
Rate Redetermination after Catastro- phic Damage In event of Catastrophic Damage and ad- justment, if any, of Included Timber, Contracting Officer shall make an appraisal to determine for each species the catastrophe-caused difference between the appraised unit value of Included Timber remaining immediately prior to the catastrophe and the appraised unit value of existing and potential Included Timber immediately after the ca- tastrophe. Included Timber is any that would not be elimi- nated under B8.32. Potential Included Timber is any that would be added under B8.32. Tentative Rates and Flat Rates in effect at the time of catastrophe shall be adjusted by said differences to be- come the redetermined rates for the purpose of a contract modification under B8.32. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to new Base Rate limitations of 25 cents per hun- dred cubic feet or equivalent. However, existing Base In- dices shall not be changed under this Subsection. Upon agreement under B8.32, redetermined rates and Required Deposits shall be considered established under B3.1 for timber Scaled subsequent to Catastrophic Damage. At time of such appraisal, Specified Road construc- tion cost shall include the estimated cost of any construc- tion work listed in the Schedule of Items performed and abandoned.
Emergency Rate Redetermination Forest Service shall redetermine rates if, upon Purchaser's application, Forest Service determies that, because of changes in the timber market since the award date or the last rate redetermination under this provision, the Producer Price Index identified in A20 has declined by 25 percent. Rates shall be redetermined under B3.3 and shall be considered established under B3.1 for timber Scaled subsequent to Purchaser's application. This Subsection shall not apply during Contract Term Extension.
