Common use of Tenant Contractor Clause in Contracts

Tenant Contractor. Any independent contractor of Tenant (or any employee or agent of Tenant) performing Tenant’s Construction shall be a “Tenant Contractor” and shall be subject to all of the terms, conditions and requirements contained in the Lease. The identity and qualifications of each Tenant Contractor shall be subject to Landlord’s prior written approval, which shall not be unreasonably withheld, conditioned, or delayed. Without limitation, Tenant shall require each Tenant Contractor to adjust and coordinate Tenant’s Construction to meet the schedule or requirements of other work being performed by or for Landlord throughout the Building, which shall in all cases have precedence. Tenant shall insure that each Tenant Contractor shall take all reasonable steps to assure that any work is carried out without disruption from labor disputes arising from whatever cause, including, without limitation, disputes concerning union jurisdiction and the affiliation of workers employed by said Tenant Contractor or its subcontractors. Tenant shall be responsible for, and shall reimburse Landlord for, all costs and expenses, including, without limitation, attorney’s fees incurred by Landlord in connection with any breach by the contractor of such obligations. At all times while performing Tenant’s Construction, Tenant and each Tenant Contractor shall not discriminate against any individual because of race, color, sex, religion or national origin and will, as may be required by the municipality in which the Building is located or any other public authority having jurisdiction, comply with all applicable laws, regulations and equal opportunity policies generally adhered to by comparable office buildings in the same geographic area as the Building. In the event that special security arrangements must be made (e.g., in connection with work outside normal business hours), then the cost of such security must be paid by the Tenant Contractor requesting such security. Tenant must ensure that each Tenant Contractor and subcontractors use every effort to minimize noise caused by Tenant’s Construction. Work stoppage during Hours of Operation will be ordered if noise, in the sole judgment of the Building manager, disturbs other tenants of the Building, and Landlord shall have no liability therefor. In all events, Tenant shall indemnify the Indemnitees in the manner provided in Section 9.02 of the Lease against any claim, loss or cost arising out of any interference with, or damage to, any work in the Building being done by Landlord, or any delay thereto, or any increase in the cost thereof on account in whole or in part of any act, omission, neglect or default by Tenant or any Tenant Contractor in the performance of Tenant’s Construction.

Tenant Contractor. Any independent contractor of Tenant (or any employee or agent of Tenant) performing Tenant’s Initial Construction shall be a “Tenant Contractor” and shall be subject to all of the terms, conditions and requirements contained in the Lease. The identity and qualifications of each Tenant Contractor shall be subject to Landlord’s prior written approval, which shall not be unreasonably withheld, conditioned, or delayed. Without limitation, Tenant shall require each Tenant Contractor to adjust and coordinate Tenant’s Initial Construction to meet the schedule or requirements of other work being performed by or for Landlord throughout the Building, which shall in all cases have precedence. Tenant shall insure that each Tenant Contractor shall take all reasonable steps to assure that any work is carried out without disruption from labor disputes arising from whatever cause, including, without limitation, disputes concerning union jurisdiction and the affiliation of workers employed by said Tenant Contractor or its subcontractors. Tenant shall be responsible for, and shall reimburse Landlord for, all costs and expenses, including, without limitation, attorney’s fees incurred by Landlord in connection with any breach by the contractor of such obligations. At all times while performing Tenant’s Initial Construction, Tenant and each Tenant Contractor shall not discriminate against any individual because of race, color, sex, religion or national origin and will, as may be required by the municipality in which the Building is located or any other public authority having jurisdiction, comply with all applicable laws, regulations and equal opportunity policies generally adhered to by comparable office buildings in the same geographic area as the Building. In the event that special security arrangements must be made (e.g., in connection with work outside normal business hours), then the cost of such security must be paid by the Tenant Contractor requesting such security. Tenant must ensure that each Tenant Contractor and subcontractors use every effort to minimize noise caused by Tenant’s Construction. Work stoppage during Hours of Operation will be ordered if noise, in the sole judgment of the Building manager, disturbs other tenants of the Building, and Landlord shall have no liability therefor. In all events, Tenant shall indemnify the Indemnitees in the manner provided in Section 9.02 5.5.1 of the this Lease against any claim, loss or cost arising out of any interference with, or damage to, any work in the Building being done by Landlord, or any delay thereto, or any increase in the cost thereof on account in whole or in part of any act, omission, neglect or default by Tenant or any Tenant Contractor in the performance of Tenant’s Initial Construction.

Tenant Contractor. Any independent contractor of Tenant (or for any employee or agent of Tenant) performing perforating Tenant’s Expansion Construction shall be a “Tenant Contractor” and shall be subject to all of the terms, conditions and requirements contained in the LeaseLease relating to Tenant’s Expansion Construction and/or applicable to Tenant Contractor. The identity and qualifications of each Tenant Contractor shall be subject to Landlord’s prior written approval, which shall not be unreasonably withheld, conditioned, or delayed. Without limitation, Tenant shall require each Tenant Contractor to adjust and coordinate Tenant’s Expansion Construction to meet the schedule or requirements of other work being performed by or for Landlord throughout the Building, which shall in all cases have precedence. Tenant shall insure insure, that each Tenant Contractor shall take all reasonable steps to assure that any work is carried out without disruption from labor disputes arising from whatever cause, including, without limitation, disputes concerning union jurisdiction and the affiliation of workers employed by said Tenant Contractor or its subcontractors. Tenant shall be responsible for, and shall reimburse Landlord for, all costs and expenses, including, without limitation, attorney’s fees incurred by Landlord in connection with any breach by the contractor of such obligations. At all times while performing Tenant’s Expansion Construction, Tenant shall not, and shall endeavor to require that each Tenant Contractor shall not discriminate against against, any individual because of race, color, sex, religion or national origin and will, as may be required by the municipality in which the Building is located or any other public authority having jurisdiction, comply with all applicable laws, regulations and equal opportunity policies generally adhered to by comparable office buildings in the same geographic area as the Building. In the event that special security arrangements must be made (e.g., in connection with work outside normal business hours), then the cost of such security must be paid by the Tenant or the Tenant Contractor requesting such security. Tenant must ensure insure that each Tenant Contractor and subcontractors use every effort commercially reasonable efforts to minimize noise caused by Tenant’s Expansion Construction. Work stoppage during Hours of Operation will be ordered if noise, in the sole reasonable judgment of the Building manager, disturbs other tenants of the Building, and Landlord shall shall, have no liability therefor. In all events, Tenant shall indemnify the Indemnitees in the manner provided in Section 9.02 of 5.6.1 -of the Lease against any claim, loss or cost arising out of any interference with, or damage to, any work in the Building being done by Landlord, or any delay thereto, or any increase in the cost thereof on account in whole or in part of any act, omission, neglect or default by Tenant or any Tenant Contractor in the performance of Tenant’s Expansion Construction.

Tenant Contractor. Any independent contractor of Tenant (or any employee or agent of Tenant) performing Tenant’s Initial Construction shall be a “Tenant Contractor” and shall be subject to all of the terms, conditions and requirements contained in the Lease. The identity and qualifications of each Tenant Contractor shall be subject to Landlord’s prior written approval, which shall not be unreasonably withheld, conditioned, or delayed. Without limitation, Tenant shall require each Tenant Contractor to adjust and coordinate Tenant’s Initial Construction to meet the schedule or requirements of other work being performed by or for Landlord throughout the Building, which shall in all cases have precedenceincluding those performing the Landlord Work. Tenant shall insure that each Tenant Contractor shall take all reasonable steps to assure that any work is carried out without disruption from labor disputes arising from whatever cause, including, without limitation, disputes concerning union jurisdiction and the affiliation of workers employed by said Tenant Contractor or its subcontractors. Tenant shall be responsible for, and shall reimburse Landlord for, all costs and expenses, including, without limitation, attorney’s fees incurred by Landlord in connection with any breach by the contractor of such obligations. At all times while performing Tenant’s Initial Construction, Tenant and each Tenant Contractor shall not discriminate against any individual because of race, color, sex, religion or national origin and will, as may be required by the municipality in which the Building is located or any other public authority having jurisdiction, comply with all applicable laws, regulations and equal opportunity policies generally adhered to by comparable office buildings in the same geographic area as the Building. In the event that special security arrangements must be made (e.g., in connection with work outside normal business hours), then the cost of such security must be paid by the Tenant Contractor requesting such security. Tenant must ensure insure that each Tenant Contractor and subcontractors use every effort to minimize noise caused by Tenant’s Initial Construction. Work stoppage during Hours of Operation will be ordered if noise, in the sole judgment of the Building manager, disturbs other tenants of the Building, and Landlord shall have no liability therefor. In all events, Tenant shall indemnify the Indemnitees in the manner provided in Section 9.02 5.6.1 of the this Lease against any claim, loss or cost arising out of any interference with, or damage to, any work in the Building being done by Landlord, or any delay thereto, or any increase in the cost thereof on account in whole or in part of any act, omission, neglect or default by Tenant or any Tenant Contractor in the performance of Tenant’s Initial Construction.