Landlord’s Election Tenant’s request for consent to any Transfer shall he accompanied by a written statement setting forth the details of the proposed Transfer, including the name, business and financial condition of the prospective Transferee, financial details of the proposed Transfer (e.g., the term and the rent and security deposit payable), and any other related information that Landlord may reasonably require. Landlord shall have the right: (a) to withhold consent to the Transfer, if reasonable, (b) to grant consent, (c) to terminate this Lease as to the portion of the Premises affected by any proposed Transfer, in which event Landlord may enter into a lease directly with the proposed Transferee, or (d) to consent on the condition that Landlord be paid, as Additional Rent hereunder, fifty percent (50%) of all subrent or other consideration to be paid to Tenant under the terms of the Transfer in excess of the total rent due hereunder (including, if such Transfer is an assignment or if such Transfer is to occur directly or indirectly in connection with the sale of any assets of Tenant, fifty percent (50%) of the amount of the consideration attributable to the Transfer of the Lease, as reasonably determined by Landlord). The grounds on which Landlord may reasonably withhold its consent to any requested Transfer include, without limitation, that: (i) the proposed Transferee’s contemplated use of the Premises following the proposed Transfer is reasonably similar to the use of the Premises permitted hereunder, (ii) in Landlord’s reasonable business judgment, the proposed Transferee lacks sufficient business reputation or experience to operate a successful business of the type and quality permitted under this Lease, (iii) in Landlord’s reasonable business judgment, the proposed Transferee lacks sufficient net worth, working capital, anticipated cash flow and other indications of financial strength to meet all of its obligations under this Lease, (iv) the proposed Transfer would breach any covenant of Landlord respecting a radius restriction, location, use or exclusivity in any other lease, financing agreement, or other agreement relating to the Property, and (v) in Landlord’s reasonable business judgment, the possibility of a release of Hazardous Materials is materially increased as a result of the Transfer or if Landlord does not receive sufficient assurances that the proposed Transferee has the experience and financial ability to remedy a violation of Hazardous Materials and to fulfill its obligations under Articles 13 and 14. Landlord need only respond to any request by Tenant hereunder within a reasonable time of not less than ten (10) business days alter receipt of all information and other submission required in connection with such request.
LEASE ALTERATIONS The Owner hereby gives power to the Agent to initiate, sign, renew, modify, or cancel rental agreements and leases for the Property, or any part thereof and collect and give receipts for rents, other fees, charges, and security deposits.
Landlord’s Consent to Alterations Tenant may not make any improvements, alterations, additions or changes to the Premises (collectively, the “Alterations”) without first procuring the prior written consent of Landlord to such Alterations, which consent shall be requested by Tenant not less than fifteen (15) days prior to the commencement thereof, and which consent shall not be unreasonably withheld, conditioned or delayed by Landlord; provided, however, Landlord may withhold its consent in its sole and absolute discretion with respect to any Alterations which may adversely affect the structural components of the Building or the Systems and Equipment in more than a de minimis manner (e.g., the mere tying into Systems shall not be subject to the sole discretion standard) or which can be seen from outside the Building. Tenant shall pay (i) for Alterations performed by Tenant, Landlord’s reasonable third-party costs incurred in connection with reviewing such Alterations, and (ii) for Alterations for which Tenant has engaged Landlord to supervise and Landlord’s contractors to perform, a supervision fee of two and one-half percent (2.5%) of the total cost of such Alteration (for the avoidance of doubt, the foregoing supervisory fee shall not be due or payable in connection with the Tenant Improvements and the Vivarium improvements and no supervisory fee shall be due or payable in connection with any capital improvements performed by Landlord). Notwithstanding the foregoing, no Landlord approval shall be required (provided advance notice shall be provided to Landlord) for (a) installation, removal or realignment of furniture systems not involving any modifications to the structure or connections (other than by ordinary plugs or jacks) to the Systems, (b) Alterations which could not reasonably be expected to affect the structural components of the Building or the Systems and Equipment and which cost less than $150,000 for any one (1) job and no more than $300,000 in the aggregate in any calendar year during the Lease Term (excluding any costs for painting, carpeting, and similar purely cosmetic work), (c) Alterations which do not require a building permit, and (d) merely cosmetic work (such as painting and carpeting). The construction of the initial improvements to the Premises shall be governed by the terms of the Tenant Work Letter and not the terms of this Article 8.
Tenant Improvements Landlord shall cause the Core and Shell Contractor or another Contractor designated by Landlord and approved by Tenant, such consent not to be unreasonably withheld or delayed (“TI Contractor”, and together with Core and Shell Contractor, “Contractor”) to commence and thereafter diligently prosecute the construction of the tenant improvements in the Premises pursuant to the Work Letter (the “Tenant Improvements”); provided, however, that before performing the Tenant Improvements, Landlord shall prepare in good faith an estimated budget for the construction of the Tenant Improvements and deliver such budget to Tenant for Tenant’s written approval prior the start of construction (the “Budget”). Landlord and Tenant shall work together cooperatively and in good faith to achieve a mutually acceptable Budget. Landlord shall update the Budget for Tenant’s review and approval at reasonable intervals and shall notify Tenant in writing if the Budget is likely to be exceeded. If there is an indication that the Budget is likely to be exceeded, Landlord and Tenant shall work together cooperatively, if required by Tenant, to modify the scope of the Tenant Improvements to bring the same in line with a budget reasonably acceptable to Tenant. The Tenant Improvements shall be performed in a workmanlike manner and shall substantially conform with Applicable Laws and the Approved TI Plans (as defined in the Work Letter). Tenant shall pay all TI Costs, except that Landlord shall pay for TI Costs that do not exceed the TI Allowance. The “TI Allowance” shall mean (a) One Hundred Twenty Five Dollars ($125.00) per rentable square foot of the Premises (the “Initial TI Allowance”), together with (b) the Additional Allowance. The “TI Costs” shall mean all Tenant Core and Shell Costs (as defined in the Work Letter) and all costs and expenses of performing the TI Work, including without limitation the hard and soft costs of (i) construction, (ii) the Construction Management Fee (as such term is defined in the Work Letter) and any Project or construction management fees paid by Tenant to an unaffiliated third party (such fees not to exceed three percent (3%) of the TI Allowance), (iii) space planning, design, architect, engineering, data and phone cabling and other related services, (iv) costs and expenses for labor, material, equipment, data and phone cabling and fixtures (including, without limitation, any of the Attached Property (as defined in Section 18.5), (v) building permits and other taxes, fees, charges and levies by governmental and quasi-governmental agencies for permits or for inspections of the Tenant Improvements, and (vi) the Warm Shell Costs. In no event shall the TI Allowance be used for: (w) the purchase of any furniture, personal property or other non-building system equipment, (x) costs resulting from a Tenant Delay, (y) costs resulting from any default by Tenant of its obligations under this Lease, or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). In the event the estimated total TI Costs (as set forth in the Budget) exceed the TI Allowance, Tenant shall deposit with Landlord such overage (the “TI Allowance Excess”), within five (5) business days of receiving the Budget (the “TI Deposit”). In the event Landlord determines the estimate of the TI Costs set forth in the Budget underestimates the amount of TI Costs so that the TI Deposit will not be sufficient to cover the TI Allowance Excess, then Landlord shall communicate the same to Tenant and, if required by Tenant, the parties shall discuss revisions to the Budget and Tenant may make a TI Tenant Change Order Request to reduce TI Costs, and unless the TI Costs are reduced to be within the Budget and previously paid TI Deposit, Tenant shall promptly pay the additional amount to Landlord, and such additional amount shall be added to the TI Deposit. If the sum of the TI Allowance plus the TI Deposit is not sufficient to cover the TI Costs, Tenant shall reimburse Landlord the difference between (a) the TI Costs and (b) the sum of the TI Allowance and the TI Deposit. However, Landlord shall be solely responsible for any costs related to the Tenant Improvements to the extent the same result from Landlord’s gross negligence, intentional misconduct or breach of Lease. Landlord and Tenant shall work together cooperatively at no cost or risk to Landlord to maximize Tenant’s ability, to the extent reasonably possible, to obtain the benefit of any applicable research and development tax credits with respect to the Tenant Improvements.
Landlord Improvements (a) On the Commencement Date, Landlord will deliver the Leased Premises to Tenant in a broom clean condition, and, along with the lighting, electrical (excluding the UPS system and the diesel generator), mechanical and plumbing fixtures, plumbing systems, dock doors and HVAC servicing the Leased Premises, hot water, doors and plate-glass, will be delivered to Tenant in good condition and repair, as defined in Section 5.05 above. (b) After receipt of the Letter of Credit and any required building permit, Landlord will commence and diligently pursue to completion, the construction of the improvements to the Leased Premises (the “Landlord Improvements”), in accordance with plans and specifications as shown in Exhibit B, subject to approval by local regulatory authorities (the “Plans”), which Plans are made a part of this Lease by reference. Any changes or modifications to the Plans must be made and accepted by written change order or agreement signed by Landlord and Tenant and will constitute an amendment to this Lease. Any Landlord Improvements made by Landlord are the property of Landlord and must be surrendered to Landlord upon the termination of this Lease without credit to Tenant. Upon completion of any Landlord Improvements and issuance of a final certificate of occupancy (to be applied for by Landlord’s general contractor) and certification from Landlord’s general contractor certifying to Tenant that all Landlord Improvements have been completed in accordance with the Plans (the “General Contractor’s Certificate”), thereafter Landlord shall provide and Tenant shall acknowledge receipt and acceptance of “as-built plans” of all work done in accordance with this Section 6.01. (c) Landlord shall furnish an allowance of up to $172,800.00 (One hundred seventy-two thousand, eight hundred dollars) (“Landlord Improvement Allowance”) to be credited against the cost of the construction of the Landlord Improvements. If the actual cost of construction of the Landlord Improvements is less than the Landlord Improvement Allowance (“Allowance Overage”), Tenant shall have no right or claim to such difference; provided however, that if there is an Allowance Overage, Landlord, upon submission of supporting documentation by Tenant, will reimburse Tenant for any third party costs of low voltage wiring and laboratory benches for the Leased Premises, but such reimbursement shall not exceed the lesser of the Allowance Overage or 69,120.00 (Sixty-nine thousand, one hundred twenty & xx/100 dollars). If the actual cost of construction of the Landlord Improvements exceeds the Landlord Improvement Allowance, Tenant shall pay such excess cost to Landlord within ten (10) business days after receipt of supporting documentation and the General Contractor’s Certificate,. (d) Notwithstanding anything contained in Section 6.01 (c) above, within 30 days after the issuance of the General Contractor’s Certificate, Landlord will determine the sum of (i) the actual cost of the Landlord Improvements, plus (ii) if any, the actual costs submitted by Tenant towards the Contingent Allowance, and the product of the calculation shall be rounded to the next $1,000.00 (One Thousand Dollars). If the resultant amount is less than the Landlord Improvement Allowance, Landlord shall reduce the monthly Base Rent by $20.25 (“Base Rent Reduction Factor”) for each whole $1,000.00 (One Thousand Dollars) of such amount effective January 1, 2012. If it is determined that the monthly Base Rent is to be reduced and if Tenant has already paid Base Rent in a pre-reduction amount, Landlord shall give Tenant credit for any such excess payment, and reduction in monthly Base Rent shall be memorialized in an amendment to this Lease. In the event that the monthly Base Rent is reduced in accordance with this Section 6.01(d), there shall be no reduction in the Security Deposit Amount or in the requirements set forth for the Letter of Credit. The following example illustrates the intentions of the parties hereto as to computation of any reduction of the monthly Base Rent: Assumptions: 1. Actual cost of the Landlord Improvements: $100,000.00 2. Actual cost of qualifying costs for Contingent Allowance: $50,500.00 Total cost of Landlord Improvements and Contingent Allowance Costs: ($100,000.00 + $50,500.00) = $150,500.00 Determination of reduction in monthly Base Rent: Total Landlord Improvement Allowance $ 172,800.00 Less total cost of Landlord Improvements and contingent costs 150,500.00 $ 22300.00 Rounded to next $1,000.00 (One Thousand Dollars) $ 23,000.00 Divided by $1,000.00 (One Thousand Dollars) 1,000.00 Base Rent Reduction Factor 20.25 Reduction in monthly Base Rent $ 465.75 (e) In addition to the Landlord Improvements, Landlord, at Landlord’s sole cost and expense, shall have the following additional work performed on the Leased Premises prior to delivery of possession to Tenant, such work to be coordinated with the construction of the Landlord Improvements: (i) Replace all stained, damaged or missing ceiling tiles, (ii) Paint all walls in the Leased Premises, the color to be designated by Tenant, (iii) Replace all vinyl floor tiles in the open laboratory area as shown in Exhibit C, (iv) Shampoo all carpets in the office areas and hallways and (v) Any existing water supply or drainage pipes in the open lab area that are not initially utilized by Tenant shall be capped and made reasonably flush with the floor, but such capping shall allow for those pipes to be tapped by Tenant for future use. (vi) Re-caulk all perimeter flashing; install new pads under all gas line blocking; repair any loose or open curb or wall flashing; repack all pitch pans; repair any open joints on gravel guard; repair any loose scupper flashing; clean, prime and install EPDM peel and stick tape to all roof side tilt wall joints; clean all debris from around drains and entire roof; install Xxxxxx 97 asbestos free aluminum coating to entire roof surface (vii) Repair any existing alligator or pothole areas.
Landlord’s Contribution Landlord shall contribute rent abatements up to the total amount of ONE HUNDRED FIFTY THOUSAND DOLLARS ($150,000.00) (“Landlord’s Contribution”) on account of the cost of refurbishing the Leased Premises including design and engineering costs. Landlord’s Contribution shall be available to Tenant only as follows: (i) Tenant shall submit to Landlord a written request to utilize a portion of Landlord’s Contribution as an abatement of one or more monthly installments of Base Rent (as hereinafter defined) (each a “Contribution Request”); (ii) each Contribution Request shall include evidence reasonably satisfactory to Landlord that Tenant has actually paid to contractors and other relevant professionals an amount at least equal to the amount sought in the Contribution Request in connection with construction, design and or other service and materials directly related to and necessary in connection with the Expansion Project (“Refit Expenses”); (iii) unless a Contribution Request is disputed by Landlord within ten (10) days from receipt by Landlord, Tenant shall be entitled to abatement of Base Rent monthly installment(s) first payable not less than thirty (30) days from submission of such Contribution Request to Landlord; (iv) in addition to the foregoing: (A) Tenant shall be limited to no more than three (3) contribution requests per year; (B) each Contribution Request shall be in an amount not less than the lesser of the remaining unused portion of Landlord’s Contribution and the Base Rent payable for one (1) month and shall specify how Tenant intends to apply the Base Rent abatements to upcoming monthly installment(s) of Base Rent; and (C) monthly abatements of Base Rent shall be applied to whole months and Tenant shall have no right to a partial abatement of monthly Base Rent other than with respect to the last Contribution Request.
Tenant Alterations Tenant will not make or allow to be made any alterations in or to the Premises without first obtaining the written consent of Landlord, which consent may be granted or withheld in Landlord’s sole discretion; provided, however that such Landlord consent shall not be required for changes that are not to the exterior, or are not to the structure, or are not to Buildings systems, or which are merely cosmetic in nature. All Tenant alterations will be accomplished in a good and workmanlike manner at Tenant’s sole expense, in conformity with all Applicable Laws by a licensed and bonded contractor approved in advance by Landlord, such approval of contractor not to be unreasonably withheld or delayed. All contractors performing alterations in the Premises shall carry workers’ compensation insurance, commercial general liability insurance, automobile insurance and excess liability insurance in amounts reasonably acceptable to Landlord and shall deliver a certificate of insurance evidencing such coverages to Landlord prior to commencing work in the Premises. Upon completion of any such work, Tenant shall provide Landlord with “as built” plans, copies of all construction contracts, and proof of payment for all labor and materials. All alterations or improvements, shall remain with the Premises upon Lease termination or expiration and will be surrendered to Landlord along with the Premises at such time and will be deemed owned by Landlord at all times from and after and upon completion thereof (but rights to the use of same and Tenant’s obligations to keep in good order, condition and repair and maintain same, as a part of the Premises, shall remain with Tenant pursuant to this Lease during the term of this Lease). Tenant will have no authority or power, express or implied, to create or cause any construction lien or mechanics’ or materialmen’s lien or claim of any kind against the Premises, the Property or any portion thereof. Landlord’s interest in the Premises is not and shall not be subject to any liens as a result of Tenant’s use or occupancy of the Premises including specifically, without limitation, for improvements made by Tenant, and all such liens are expressly prohibited. Tenant will promptly cause any such liens or claims to be released by payment, bonding or otherwise within thirty (30) days after request by Landlord, and will indemnify Landlord against losses arising out of any such claim including, without limitation, legal fees and court costs. Landlord has the right, but not the obligation, to discharge any such lien. Any amount paid by Landlord for such purpose and Landlord’s related reasonable attorneys’ fees shall be paid by Tenant to Landlord upon demand and shall accrue interest from the date paid by Landlord until Landlord is reimbursed therefor at the highest rate permitted by Law. NOTICE IS HEREBY GIVEN THAT LANDLORD WILL NOT BE LIABLE FOR ANY LABOR, SERVICES OR MATERIAL FURNISHED OR TO BE FURNISHED TO TENANT, OR TO ANYONE HOLDING THE PREMISES THROUGH OR UNDER TENANT, AND THAT NO MECHANICS’ OR OTHER LIENS FOR ANY SUCH LABOR, SERVICES OR MATERIALS WILL ATTACH TO OR AFFECT THE INTEREST OF LANDLORD IN THE PREMISES. TENANT WILL DISCLOSE THE FOREGOING PROVISIONS TO ANY CONTRACTOR ENGAGED BY TENANT PROVIDING LABOR, SERVICES OR MATERIAL TO THE PREMISES.
Tenant’s Plans (i) Tenant shall diligently pursue the preparation of all drawings, plans and specifications for Tenant Improvements in accordance with this Paragraph 2(b). All such plans, drawings and specifications shall be performed by an architect and/or engineer (as applicable) reasonably acceptable to Landlord and Tenant, and shall include the following: (i) a space plan for the Premises; (ii) complete architectural, engineering and other plans for the Tenant Improvements; and (iii) a list of tenant improvement building standards for interior design, including a schedule (e.g. color palate, material board and spec sheets) of all interior color and finishes. Items (ii) and (iii) above are collectively referred to herein as “Working Drawings”. The space plan and Working Drawings shall comply with all applicable regulations, laws, ordinances, codes and rules. Tenant shall submit its space plan to Landlord, for review and approval in Landlord’s sole discretion. Within ten (10) business days after such submission, Landlord shall either approve or disapprove the space plan. Tenant shall make any changes necessary in order to correct any item identified by Landlord as grounds for its disapproval, and shall resubmit the correct space plan to Landlord within ten (10) business days after Landlord’s disapproval. Within ten (10) business days after Landlord received the revised space plan, Landlord shall approve or disapprove it. This procedure shall be repeated until the space plan is finally approved by Landlord and written approval has been delivered to Tenant. If Landlord fails to approve or disapprove any submission within the required time period Landlord shall be deemed to have disapproved such submission. Landlord has approved the space plan for Building 2, a copy of which is attached hereto as Schedule 2 (the “Building 2 Space Plan”), subject to Landlord’s right to review and approve the Working Drawings, interior color and finishes, materials, specifications, and other items pursuant to Paragraph 2(b)(ii) and (iii) below, and further subject to compliance and conformance with the Minimum Specifications (as defined in Paragraph 2(b)(iii) below). (ii) Within twenty-one (21) days after Landlord has finally approved Tenant’s space plan, Tenant shall submit its Working Drawings and a pallet of interior colors and finishes to Landlord for Landlord’s review and approval, in Landlord’s sole discretion. Landlord’s approval or disapproval of such Working Drawings and pallet, and Tenant’s response thereto, shall follow the procedure (including deemed disapproval) described in Subsection (i) above with respect to the space plan. All items finally approved by Landlord pursuant to this Paragraph 2(b) are referred to herein collectively as “Tenant’s Plans”. Once approved by Landlord, no changes shall be made to Tenant’s Plans without the prior written approval of Landlord, in Landlord’s sole discretion. (iii) Landlord has established a partial list of Minimum Building Specifications for Building 2 (the “Minimum Specifications”) which is attached to this Exhibit as Schedule 1, for use in the design and construction of the Tenant Improvements, provided that the Minimum Specifications is not a complete list of products, specifications and finishes to be used in the construction of the Tenant Improvements and accordingly, Tenant shall cause to be described in the Working Drawings all products, specifications and finishes to be used in the construction of the Tenant Improvements which are not otherwise listed on, or which deviate from, the Minimum Specifications, all of which shall be subject to Landlord’s approval in Landlord’s sole discretion. Unless otherwise expressly agreed to by Landlord, the portion of the Tenant Improvements pertaining to the products, specifications and finishes specified in the Minimum Specifications shall comply with the Minimum Specifications.
Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Tenant’s Work Section 5.1 Except as may be expressly provided in this lease, Tenant shall not replace any fixtures in the Premises or make any changes, improvements, alterations or additions (collectively, “Tenant’s Work”), to the Premises, the Real Property, the Building systems, or any part thereof, without Xxxxxxxx’s prior consent. Landlord’s consent shall not be unreasonably withheld or delayed if Tenant’s Work (a) is nonstructural, and (b) does not (i) affect any part of the Real Property outside the Premises (including the Building roof) or the exterior of the Premises, (ii) affect any structural element of the Building, (iii) adversely affect any Building system, or (iv) require an amendment of the certificate of occupancy for the Premises or the Building, ( c) is not visible outside the Premises and (d) is performed only by contractors and subcontractors first approved by Landlord (which approval shall not be unreasonably withheld or delayed). Xxxxxxxx’s consent shall not be required with respect to such of Tenant’s Work as are cosmetic alterations (such as painting the interior of the Premises, carpeting, and installation of shelving and display cases) inside the Premises (“Cosmetic Alterations”), provided Tenant complies with the other applicable provisions of this lease. Tenant’s Work shall be performed, at Tenant’s expense, with diligence when started so as to promptly complete it in a good and worker-like manner using new materials of first class quality and in compliance with this lease, all Laws and Tenant’s Plans (as defined in Section 5.2) as approved by Landlord. As part of Tenant’s Work, Tenant shall soundproof the Premises and install appropriate ventilation if required so that Tenant’s use of the Premises shall not result in noise and/or odors being transmitted outside the Premises. Tenant’s Work shall be fully paid for by Tenant when payment is due and shall not be financed with any conditional sales or title retention agreements or by the granting of any security interests, liens, encumbrances or financing statements. Tenant’s Work shall be deemed, upon installation, to be improvements and betterments that become the property of Landlord at installation, and shall remain upon and be surrendered with the Premises, at the expiration of the Term (or the sooner termination of this lease in accordance with its provisions) unless Landlord notifies Tenant in accordance with the provisions of this Article that Landlord relinquishes its rights thereto, in which case Tenant shall be obligated to remove such Tenant’s Work. Section 5.2 Prior to commencing any Tenant’s Work other than purely Cosmetic Alterations, Tenant shall, at Tenant’s expense, deliver to Landlord detailed plans and specifications, for Tenant’s Work, in form reasonably satisfactory to Landlord, prepared, certified, signed and sealed by an architect or engineer licensed to practice in the State of New York, and suitable for filing with the applicable Authority, if filing is required by applicable Laws (such plans and specifications together with revisions thereto, collectively, “Tenant’s Plans”), and obtain Landlord’s approval of Xxxxxx’s Plans. Xxxxxxxx’s approval of Xxxxxx’s Plans shall not be unreasonably withheld or delayed to the extent Xxxxxxxx’s consent to Xxxxxx’s Work shown on Tenant’s Plans is not to be unreasonably withheld or delayed pursuant to this Article. Before commencing Tenant’s Work, Tenant shall (a) obtain (and deliver to Landlord copies of) all required permits and authorizations of any Authority for such work, and (b) deliver to Landlord such security as shall be reasonably satisfactory to Landlord, and (c) deliver to Landlord certificates (in form reasonably acceptable to Landlord) evidencing the following insurance coverages from each contractor and subcontractor: (i) worker’s compensation insurance covering all persons to be employed in the performance of any Tenant’s Work, and
