Lease Termination Except as provided in this Section 9.04, upon expiration or earlier termination of this Lease Tenant shall surrender the Premises to Landlord in the same condition as existed on the date Tenant first occupied the Premises, (whether pursuant to this Lease or an earlier lease), subject to reasonable wear and tear. All Alterations shall become a part of the Premises and shall become the property of Landlord upon the expiration or earlier termination of this Lease, unless Landlord shall, by written notice given to Tenant, require Tenant to remove some or all of Tenant's Alterations, in which event Tenant shall promptly remove the designated Alterations and shall promptly repair any resulting damage, all at Tenant's sole expense. All business and trade fixtures, machinery and equipment, furniture, movable partitions and items of personal property owned by Tenant or installed by Tenant at its expense in the Premises shall be and remain the property of Tenant; upon the expiration or earlier termination of this Lease, Tenant shall, at its sole expense, remove all such items and repair any damage to the Premises or the Building caused by such removal. If Tenant fails to remove any such items or repair such damage promptly after the expiration or earlier termination of the Lease, Landlord may, but need not, do so with no liability to Tenant, and Tenant shall pay Landlord the cost thereof upon demand. Notwithstanding the foregoing to the contrary, in the event that Landlord gives its consent, pursuant to the provisions of Section 9.01 of this Lease, to allow Tenant to make an Alteration in the Premises, Landlord agrees, upon Tenant's written request, to notify Tenant in writing at the time of the giving of such consent whether Landlord will require Tenant, at Tenant's cost, to remove such Alteration at the end of the Lease Term.
Landlord’s Termination Right Whether or not the Premises are affected, Landlord may, by notice to Tenant, within 60 days following the date upon which Landlord receives notice of the Taking of all or a portion of the Real Property, the Building or the Premises, terminate this Lease, provided that Landlord elects to terminate leases (including this Lease) affecting at least 50% of the rentable area of the Building.
Tenant’s Repairs Subject to Landlord’s repair obligations in Sections 7.2 and 11.1 below, Tenant shall, at Tenant’s own expense, keep the Premises, including all improvements, fixtures and furnishings therein, in good order, repair and condition at all times during the Lease Term, which repair obligations shall include, without limitation, the obligation to promptly and adequately repair all damage to the Premises and replace or repair all damaged or broken fixtures and appurtenances, together with all portions of the HVAC, electrical, mechanical plumbing, life safety and lab systems from the point that such systems solely serves the Premises and all portions of all fume hoods and other exhaust systems (all such systems collectively being referred to as the “Premises Systems”), in a first-class condition. Tenant’s obligations shall include restorations, replacements or renewals, including capital expenditures for restorations, replacements or renewals which will have an expected life beyond the Term, when necessary to keep the Premises and all improvements thereon or a part thereof and the Premises Systems in first-class order, condition and repair and in compliance with all applicable laws. Except as expressly set forth in this Lease, it is intended by the parties hereto that Landlord shall have no obligation, in any manner whatsoever, to repair or maintain the Premises, the improvements located therein or the equipment therein, or the nonstructural aspects of the Premises Systems, all of which obligations are intended to be the expense of Tenant (whether or not such repairs, maintenance or restoration shall have an expected life extending beyond the Term). Tenant’s maintenance of the Premises Systems shall comply with the manufacturers’ recommended operating and maintenance procedures. Tenant shall enter into and pay for maintenance contracts (in forms satisfactory to Landlord in its sole discretion) for the Premises Systems in accordance with the manufacturers’ recommended operating and maintenance procedures. Such maintenance contracts shall be with reputable contractors, satisfactory to Landlord in its sole discretion, who shall have not less than ten (10) years of experience in maintaining such systems in biotechnical facilities. Tenant shall be solely responsible for the cost of all interior nonstructural improvements or alterations to the Premises or the Premises Systems required by law. Notwithstanding the foregoing, at Landlord’s option, or if Tenant fails to make such repairs, Landlord may, but need not, make such repairs and replacements, and Tenant shall pay Landlord the cost thereof, including a percentage of the cost thereof (to be uniformly established for the Building) sufficient to reimburse Landlord for all overhead, general conditions, fees and other costs or expenses arising from Landlord’s involvement with such repairs and replacements forthwith upon being billed for same.
Base Building Work Landlord shall construct the Base Building Work as further set forth on Exhibit 10.03, attached.
Landlord’s Work Landlord shall construct the base-building elements of the Building (the "Base Building Work"), the sitework on the Land, and the parking structure and surface parking areas on the Land, all in accordance with the Design Specifications attached hereto as Schedule I (collectively, "Landlord's Work"). All of Landlord's Work shall be performed in a good and workmanlike manner, in accordance with plans and specifications ("Landlord's Plans") mutually approved by Landlord and Tenant. Tenant's approval of Landlord's Plans shall not be unreasonably withheld, conditioned or delayed, and Tenant shall not be entitled to condition its approval of Landlord's Plans upon the inclusion therein of any design specifications that are inconsistent with the Design Specifications attached hereto as Schedule I (including requiring a higher performance standard than any performance standard expressly set forth in Schedule I). Tenant shall respond to any request for approval of Landlord's Plans, or any portion or progress set thereof, or any modifications thereto, as promptly as reasonably possible and in any event within ten (10) business days in the case of the original complete set of Landlord's Plans and any structural modifications thereto and within two (2) business days in the case of any nonstructural modifications to Landlord's Plans, and Tenant's failure to respond within such time periods shall be referred to herein and in the Lease as a "Tenant Delay." In the event Tenant disapproves Landlord's Plans or any portion thereof or any modifications thereto, Tenant's notice of disapproval shall specify in detail the reasonable basis for such disapproval. Landlord shall promptly make such revisions to Landlord's Plans as may be necessary to address Tenant's reasonable objections, and shall resubmit Landlord's Plans to Tenant for Tenant's approval. Tenant shall review such revised plans as promptly as reasonably possible and notify Landlord whether Tenant approves or reasonably disapproves Landlord's Plans as modified. This process shall be repeated, if necessary, until Tenant's reasonable objections to Landlord's Plans have been addressed and Tenant has approved Landlord's Plans. After approval of Landlord's Plans, Tenant shall have the right to initiate changes to Landlord's Plans or Landlord's Work, subject to (i) Landlord's approval of any such proposed change, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) Landlord's and Tenant's mutual agreement concerning (and execution of a change order or other written confirmation of) (A) any net increase in design or construction costs resulting from such change, all of which increased costs shall be borne solely by Tenant, and (B) any delay such change will cause in the completion of Landlord's Work or the achievement of any milestone date(s), which delay shall not extend the Lease Commencement Date or the commencement of Tenant's rental obligations under the Lease (but shall appropriately extend any affected milestone date(s)) and shall be deemed a "Tenant Delay" for purposes hereof and of the Lease. Landlord shall be responsible for causing Landlord's Work to comply with all applicable legal requirements, including (without limitation) requirements of building codes, environmental laws and the Americans with Disabilities Act, and Landlord shall indemnify Tenant and hold it harmless with respect to any loss, cost, damage or liability resulting from Landlord's breach of this obligation (which indemnification shall survive the expiration or termination of the Lease). In constructing the Base Building Work, Landlord shall perform and install all work and materials designated "Base Building" in Schedule II attached hereto. In performing the Base Building Work, Landlord shall use best efforts to achieve the milestone dates set forth in Schedule III attached hereto. In the event Landlord fails to achieve any of said milestone dates, except to the extent such failure is caused by any Tenant Delay, the December 29, 1995 date set forth in Section 3.2 of the Lease shall be extended by one (1) day for each day of delay in achieving the milestone date; provided, however, that such extension shall not occur if (and then only to the extent) Landlord and Tenant mutually agree and acknowledge in writing that the completion of the Tenant Work (as defined below) was not delayed by reason of the delay in achieving Landlord's milestone date. Tenant agrees to use good faith reasonable efforts to counter the effect of any delay by Landlord in achieving any milestone date; however, Tenant shall not be obligated to expend any additional amounts in such efforts (e.g., by employing overtime labor) unless Landlord agrees in advance to bear any incremental cost associated with such efforts (whether or not such efforts are ultimately successful).
Release; Termination (a) Upon any sale, lease, transfer or other disposition of any item of Collateral of any Grantor in accordance with the terms of the Loan Documents (other than sales of Inventory in the ordinary course of business), the Administrative Agent will, at such Grantor’s expense, execute and deliver to such Grantor such documents as such Grantor shall reasonably request to evidence the release of such item of Collateral from the assignment and security interest granted hereby; provided, however, that (i) at the time of such request and such release no Default shall have occurred and be continuing, (ii) such Grantor shall have delivered to the Administrative Agent, at least ten Business Days prior to the date of the proposed release, a written request for release describing the item of Collateral and the terms of the sale, lease, transfer or other disposition in reasonable detail, including, without limitation, the price thereof and any expenses in connection therewith, together with a form of release for execution by the Administrative Agent and a certificate of such Grantor to the effect that the transaction is in compliance with the Loan Documents and as to such other matters as the Administrative Agent may request and (iii) the proceeds of any such sale, lease, transfer or other disposition required to be applied, or any payment to be made in connection therewith, in accordance with Section 2.06 of the Credit Agreement shall, to the extent so required, be paid or made to, or in accordance with the instructions of, the Administrative Agent when and as required under Section 2.06 of the Credit Agreement.
Landlord Work In accordance with the mutually acceptable space plan dated January 4, 2012 prepared by Xxxxxxxx Xxxx Xxxxxxx Architects (the “Approved Plan”) attached hereto, Landlord shall perform the following work (collectively, the “Landlord Work”): · Build out 4 offices · Install a door to connect Suites 205 and 230 · Provide appropriate surfaces and air handling · Investigate the addition of an 8’ hood in lab Landlord shall cause the Landlord Landlord shall use commercially reasonable efforts to cause the Landlord Work to be constructed in a good and workmanlike manner, substantially in accordance with the Approved Plan and in compliance with applicable laws and covenants, conditions and restrictions in effect as of the date of such completion, and in good condition and working order. The Landlord Work shall be performed by Landlord, at Landlord’s sole cost and expense. Tenant shall have the right, on not less than two (2) business days’ advance written notice to Landlord, and, if specified by Landlord at Landlord’s option, accompanied by a representative of Landlord, to inspect the construction of the Landlord Work; provided that no such inspections shall interfere with or otherwise delay Landlord’s completion of the Landlord Work. Tenant shall have the right to submit to Landlord a list of incomplete or defective items within sixty (60) days after Substantial Completion, and Landlord shall diligently repair or replace such items at Landlord’s sole cost and expense. Landlord shall use commercially reasonable efforts to cause its construction contract for the Landlord Work to contain a minimum one (1) year warranty period. EXHIBIT C ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE THIS ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE is entered into as of [ ], 2012, with reference to that certain Lease dated as of August 24, 2007, as amended by that certain First Amendment to Lease dated as of March 30, 2008, that certain Second Amendment to Lease (“Second Amendment”) dated as of May 11, 2009, which Second Amendment was amended and restated pursuant to that certain Amended and Restated Second Amendment to Lease dated as of September 15, 2009, and that certain Third Amendment to Lease dated as of December [ ], 2011 (“Third Amendment”) (collectively, and as the same may have been further amended, amended and restated, supplemented or modified from time to time, the “Lease”), by RECEPTOS, INC., a Delaware corporation (“Tenant”), in favor of BMR-10835 ROAD TO THE CURE LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease. Tenant hereby confirms the following:
Removal of Tenant’s Property Upon the expiration or earlier termination of this Lease or the termination of Tenant's right of possession of the Premises only, Tenant shall have the right, at its sole cost and expense, for a period of fifteen ( 15) days thereafter to remove Tenant's Property, Distinctive Property and the Financed Personalty, respectively, from the Premises, provided that Tenant shall pay to Landlord Rent due under Article 3 hereof for the actual number of days which elapse during such fifteen (15) day period until the Tenant's Property, Distinctive Property and the Financed Personalty, as applicable, are removed from the Premises. If and to the extent that Tenant fails to remove any of such property by the expiration of said fifteen (15) day period, Landlord agrees that Tenant Lender, TE Lender and Franchisor each shall have the right for a period of forty (45) days thereafter to remove the same from the Premises, provided that Tenant shall pay to Landlord Rent due hereunder for the actual number of days which elapse until Tenant Lender, TE Lender or Franchisor remove the same from the Premises during such forty five (45) day period. If and to the extent that any such property remains on the Premises on the sixtieth (60th) day after such termination, the same shall be deemed abandoned, and at Landlord's option shall become the property of Landlord and may be sold or disposed of as Land-lord may determine; provided, however, that Landlord shall not use, suffer or permit the use of any Distinctive Property unless the attributes or features thereof associated with Tenant or Franchisor are removed or obliterated. Any and all damage to the Building caused by or resulting from the removal of Tenant's Property, Distinctive Property or Financed Personalty shall promptly be repaired at no cost or expense to Landlord and Tenant shall be liable for such cost and expense unless such repairs are made by Tenant, Franchisor or TE Lender, as the case may be.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Removal of Alterations If Tenant fails to remove by the expiration or earlier termination of this Lease all of its personal property, or any Alterations identified by Landlord for removal, Landlord may, at its option, treat such failure as a hold-over pursuant to Subparagraph 11(b) above, and/or Landlord may (without liability to Tenant for loss thereof) treat such personal property and/or Alterations as abandoned and, at Tenant's sole cost and expense, and in addition to Landlord's other rights and remedies under this Lease, at law or in equity: (a) remove and store such items; and/or (b) upon ten (10) days prior notice to Tenant, sell, discard or otherwise dispose of all or any such items at private or public sale for such price as Landlord may obtain or by other commercially reasonable means. Tenant shall be liable for all costs of disposition of Tenant's abandoned property and Landlord shall have no liability to Tenant with respect to any such abandoned property. Landlord agrees to apply the proceeds of any sale of any such property to any amounts due to Landlord under this Lease from Tenant (including Landlord's attorneys' fees and other costs incurred in the removal, storage and/or sale of such items), with any remainder to be paid to Tenant.
