Tenant’s Insurance Obligations Tenant, at all times during the Term and during any early occupancy period, at Tenant’s sole cost and expense, will maintain the insurance this Section 10.1 describes.
Tenant’s Insurance Tenant shall maintain the following coverages in the following amounts.
TENANT’S DEFAULTS In addition to any other event of default set forth in this Lease, the occurrence of any one or more of the following events shall constitute a default by Tenant:
Landlord’s Default and Tenant’s Remedies In the event Landlord fails to perform its obligations under this Lease, Landlord shall nevertheless not be in default under the terms of this Lease until such time as Tenant shall have first given Landlord written notice specifying the nature of such failure to perform its obligations, and then only after Landlord shall have had thirty (30) days following its receipt of such notice within which to perform such obligations; provided that, if longer than thirty (30) days is reasonably required in order to perform such obligations, Landlord shall have such longer period. In the event of Landlord’s default as above set forth, then, and only then, Tenant may then proceed in equity or at law to compel Landlord to perform its obligations and/or to recover damages proximately caused by such failure to perform (except as and to the extent Tenant has waived its right to damages as provided in this Lease).
Tenant’s Lease Default Notwithstanding any provision to the contrary contained in the Lease, if an event of default by Tenant as described in Section 12.01 of the Lease or any default by Tenant under this Work Letter (which, for purposes hereof, shall include, without limitation, the delivery by Tenant to Landlord of any oral or written, including electronic, notice instructing Landlord to cease the design and/or construction of the Tenant Improvements and/or that Tenant does not intend to occupy the Premises, and/or any other anticipatory breach of the Lease) has occurred at any time on or before the Substantial Completion of the Premises, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to withhold payment of all or any portion of the Tenant Improvement Allowance and/or Landlord may cause Contractor to cease the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as a Tenant Delay as set forth in Section 5.01 above), and (ii) all other obligations of Landlord under the terms of this Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such inaction by Landlord as a Tenant Delay). In addition, if the Lease is terminated prior to the Lease Commencement Date, for any reason due to an event of default by Tenant as described in Section 12.01 of the Lease or under this Work Letter (including, without limitation, any anticipatory breach described above in this Section 6.05), then (A) Tenant shall be liable to Landlord for all damages available to Landlord pursuant to the Lease and otherwise available to Landlord at law and/or in equity by reason of a default by Tenant under the Lease or this Work Letter, and (B) Tenant shall pay to Landlord, as Additional Rent under the Lease, within five (5) Business Days after Tenant’s receipt of a statement therefor, any and all costs incurred by Landlord (including any portion of the Tenant Improvement Allowance disbursed by Landlord) and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant Improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto.
Tenant’s Default The occurrence of any one or more of the following events shall constitute a default and breach of this Lease by Tenant:
Tenant’s Remedies Notwithstanding any other provision of this Lease, if any default hereunder by Landlord is not cured within the applicable cure period provided in Paragraph 20(c) or any other applicable CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. cure period provided in this Lease (including any Mortgagee’s additional cure period), Tenant’s exclusive remedies shall be (i) an action for specific performance, or (ii) an action for actual damages. Notwithstanding any other provision of this Lease, the liability of Landlord to Tenant for any breach or default by Landlord under the terms of this Lease, or for any other matter related to this Lease or to the Premises or Project, shall be limited to Tenant’s actual direct, but not consequential, damages therefor, and any judgment against Landlord in connection therewith shall be recoverable only from the interest of Landlord in the Buildings. Tenant hereby waives any claim for damages for any disturbance, loss of business, nuisance, injury or inconvenience to or interference with Tenant’s business, any loss of occupancy or quiet enjoyment of the Premises, and any other loss arising from Landlord’s entry and acts pursuant to Paragraph 18 or otherwise with respect to any act, omission or breach of Landlord. Without limiting the preceding sentence, in no event shall Landlord be liable to Tenant for any consequential damages, including, without limitation, any losses arising from any interruption of Tenant’s business, or for lost profits, or for charges or expenses which continue but would have been earned if the business had gone on without interruption, or for any other loss, claim, cost, expense or damage which would be covered by a standard policy of business interruption insurance. Landlord, or if Landlord is a partnership its partners whether general or limited, or if Landlord is a corporation its directors, officers or shareholders, or if Landlord is a limited liability company its members or managers, shall never be personally liable for any such judgment. Any lien obtained to enforce such judgment and any levy of execution thereon shall be subject and subordinate to any Mortgage (excluding any Mortgage which was created as part of an effort to defraud creditors, i.e., a fraudulent conveyance); provided, however that any such judgment and any such levy of execution thereon shall not be subject or subordinated to any Mortgage that is created or recorded in the official records of the county in which the Project is located after the date of the judgment giving rise to such lien. Landlord’s interest in the Buildings shall include any insurance proceeds received by Landlord which are not controlled by any Mortgagee or other lender. Tenant hereby waives the benefit of any Laws granting it (A) the right to perform Landlord’s obligations, or (B) the right to terminate this Lease or withhold Rent on account of any Landlord default, including, without limitation, Sections 1932(1), 1941 and 1942 of the California Civil Code.
Tenant’s Property Insurance Tenant shall maintain at all times during the Lease Term, and during such earlier time as Tenant may be performing work in or to the Premises or have property, fixtures, furniture, equipment, machinery, goods, supplies, wares or merchandise on the Premises, and continuing thereafter so long as Tenant is in occupancy of any part of the Premises, business interruption insurance and (insurance against loss or damage covered by the so-called “all risk” type insurance coverage with respect to (i) Tenant’s property, fixtures, furniture, equipment, machinery, goods, supplies, wares and merchandise, and (ii) any other improvements which exist in the Premises as of the Lease Commencement Date (excluding the Base Building) (the “Original Improvements”), and all alterations, improvements and other modifications made by or on behalf of the Tenant in the Premises, and (iii) other property of Tenant located at the Premises (collectively “Tenant’s Property”). The business interruption insurance required by this Section shall be in minimum amounts typically carried by prudent tenants engaged in similar operations, but in no event shall be in an amount less than the Base Rent then in effect during any Lease Year, plus any Additional Rent due and payable for the immediately preceding Lease Year. The “all risk” insurance required by this Section shall be in an amount at least equal to the full replacement cost of Tenant’s Property. In addition, during such time as Tenant is performing work in or to the Premises, Tenant, at Tenant’s expense, shall also maintain, or shall cause its contractor(s) to maintain, builder’s risk insurance for the full insurable value of such work. Landlord and such additional persons or entities as Landlord may reasonably request shall be named as loss payees, as their interests may appear, on the policy or policies required by this section. In the event of loss or damage covered by the “all risk” insurance required by this section, the responsibilities for repairing or restoring the loss or damage shall be determined in accordance with Article 11 of this Lease, below. To the extent that Landlord is obligated to pay for the repair or restoration of the loss or damage covered by the policy, Landlord shall be paid the proceeds of the “all risk” insurance covering the loss or damage. To the extent Tenant is obligated to pay for the repair or restoration of the loss or damage, covered by the policy, Tenant shall be paid the proceeds of the “all risk” insurance covering the loss or damage. If both Landlord and Tenant are obligated to pay for the repair or restoration of the loss or damage covered by the policy, the insurance proceeds shall be paid to each of them in the pro rata proportion of their obligations to repair or restore the loss or damage. If the loss or damage is not repaired or restored (for example, if the Lease is terminated pursuant to Section 11.2 of this Lease, below), the insurance proceeds shalt be paid to Landlord and Tenant in the pro rata proportion of their relative contributions to the cost of the leasehold improvements covered by the policy.
Landlord’s Insurance Tenant shall not cause or permit or suffer any action or condition that would (i) invalidate or conflict with Landlord’s insurance policies which contemplate a live entertainment use for the Music Hall, (ii) violate applicable rules, regulations and guidelines of the Fire Department, Fire Insurance Rating Organization or any other authority having jurisdiction over the Center, (iii) cause an increase in the premiums for fire insurance then covering the Buildings over that payable with respect to comparable first-class office buildings or theaters, or (iv) result in insurance companies of good standing refusing to insure the Buildings or any property therein in amounts and against risks as reasonably determined by Landlord. If the fire insurance premiums increase as a result of Tenant’s failure to comply with the provisions of this Article, Tenant shall promptly cure such failure and shall reimburse Landlord for the increased fire insurance premiums paid by Landlord as a result of such failure by Tenant, provided that Landlord shall furnish reasonable supporting documentation therefor. If it is not practicable for Tenant to cure such failure and continue to operate the Premises for the Permitted Uses and the only result of such failure is an increase in Landlord’s insurance premium, then provided Tenant pays such increased premium, Tenant shall not be required to cease such action so long as the increased premium is the only effect of such failure and, provided further, in the event that (A) Landlord’s insurance carrier refuses to provide certain insurance as a result of Tenant’s failure to comply with the provisions of this Article and (B) a separate insurance carrier of comparable rating or which is otherwise satisfactory to Landlord is willing to provide such insurance, Tenant shall pay any increased cost payable by Landlord by reason of its purchase of such insurance from such separate insurance carrier. In any action or proceeding to which Landlord and Tenant are parties, a schedule or “make up” of rates for the Buildings or the Premises issued by the appropriate Fire Insurance Rating Organization, or other body fixing such fire insurance rates, shall be conclusive evidence of the fire insurance rates then applicable to the Buildings.
LESSEE'S PROPERTY INSURANCE Subject to the requirements of Paragraph 8.5, Lessee at its cost shall either by separate policy or, at Lessor's option, by endorsement to a policy already carried, maintain insurance coverage on all of Lessee's personal property, Trade Fixtures and Lessee-Owned Alterations and Utility Installations in, on, or about the Premises similar in coverage to that carried by Lessor as the Insuring Party under Paragraph 8.3(a). Such insurance shall be full replacement cost coverage with a deductible not to exceed $1,000 per occurrence. The proceeds from any such insurance shall be used by Lessee for the replacement of personal property and the restoration of Trade Fixtures and Lessee-Owned Alterations and Utility Installations. Upon request from Lessor, Lessee shall provide Lessor with written evidence that such insurance is in force.
