Landlord Default shall have the meaning given such term in Article 14.
Lease Event of Default shall have the meaning specified in Section 17.1 of the Lease.
Minor Default means any Event of Default that is not a Major Default.
Lease Default means any event or condition which, with the lapse of time or the giving of notice, or both, would constitute a Lease Event of Default.
Default means any event which is, or after notice or passage of time or both would be, an Event of Default.
Major Default means any Event of Default occurring under Sections 4.1(a), 4.1(c), 4.1(l), or 4.1(p).
O & M Default means any default on the part of the Power Producer for a continuous period of ninety (90) days to (i) operate and/or (ii) maintain (in accordance with Prudent Utility Practices), the Project at all times.
Customer Default has the meaning set out in clause 8.3.
Potential Event of Default means any event which, with the giving of notice or the lapse of time or both, would constitute an Event of Default.
Owner Event of Default shall have the meaning set forth in Section 18.3.
MI Default has the meaning given to it in paragraph 6.1 of Framework Schedule 9 (Management Information);
PTC Event of Default means, with respect to each Trust Agreement, the failure to pay within 10 Business Days after the due date thereof: (i) the outstanding Pool Balance of the applicable Class of Certificates on the Final Legal Distribution Date for such Class or (ii) interest due on such Certificates on any Distribution Date (unless the Subordination Agent shall have made an Interest Drawing or a withdrawal from the Cash Collateral Account relating to a Liquidity Facility for such Class, with respect thereto in an aggregate amount sufficient to pay such interest and shall have distributed such amount to the Trustee entitled thereto).
Contractor Default shall have the meaning set forth in Clause 23.1;
Landlord Delay means a delay in the construction of the Tenant Improvements or Compliance Work resulting directly from the acts or omissions of Landlord, Landlord’s employees, agents, or contractors including, but not limited to (i) failure of Landlord to timely approve or disapprove any plans; (ii) interference by Landlord, its employees, agents or contractors with the completion of the Tenant Improvements or Compliance Work (including the impairment of Tenant’s contractors’ or vendors’ or employees’ access to the Premises for any reason (including due to the presence of Landlord’s contractors, vendors or personnel), failure to provide reasonable access to the Building’s loading docks or other facilities necessary for the construction of the Tenant Improvements or Compliance Work and/or the movement of materials and personnel to the Premises for such purpose) and (iii) delays due to the acts or failures to act of Landlord, its agents or contractors with respect to payment of the Tenant Improvement Allowance. If Tenant contends that a Force Majeure Construction Delay or a Landlord Delay has occurred, Tenant acknowledges and agrees that it has inspected the Building and the Site and in no event shall the physical character or condition of the Building and/or Site existing as of the Effective Date constitute a basis for a Landlord Delay (this agreement does not apply to the failure of any Building component to properly operate). Further, in no event shall any delay of Landlord constitute a Landlord Delay unless such delay results in a full day of delay in the construction of the Tenant Improvements or Compliance Work. Tenant shall notify Landlord in writing (the “Delay Notice”) of the event which constitutes such Force Majeure Construction Delay or Landlord Delay; such notice may be via electronic mail to Landlord’s construction representative described above. Tenant will additionally use reasonable efforts to mitigate the effects of any Force Majeure Construction Delay or Landlord Delay through the re-sequencing or re-scheduling of work, if feasible, but this sentence will not be deemed to require Tenant to incur overtime or after-hours costs unless Landlord agrees in writing to bear such costs. If the actions or inactions or circumstances described in the Delay Notice constitute a Landlord Delay, and are not cured by Landlord within one (1) business day after Landlord’s receipt of the Delay Notice, then a Landlord Delay shall be deemed to have occurred commencing as of the expiration of such one (l)-business day period. The Lease Commencement Date and the Lease Expiration Date will each be delayed on a day for day basis for each day of Force Majeure Construction Delay or Landlord Delay.
Lender Default means (a) the refusal or failure (which has not been cured) of a Lender to make available its portion of any Borrowing or to fund its portion of any Unpaid Drawing under Section 3.4 that it is required to make hereunder, (b) a Lender having notified the Administrative Agent and/or the Borrower that it does not intend to comply with its funding obligations under this Agreement or has made a public statement to that effect with respect to its funding obligations under this Agreement, (c) a Lender has failed to confirm (within one Business Day after a request for such confirmation is received by such Lender) in a manner reasonably satisfactory to the Administrative Agent, the Borrower and, in the case of a Revolving Credit Lender, each Revolving Letter of Credit Issuer that it will comply with its funding obligations under this Agreement, (d) a Lender being deemed insolvent or becoming the subject of a bankruptcy or insolvency proceeding or has admitted in writing that it is insolvent; provided that a Lender Default shall not be deemed to have occurred solely by virtue of the ownership or acquisition of any Stock in the applicable Lender or any direct or indirect parent company thereof by a Governmental Authority so long as such ownership interest does not result in or provide the applicable Lender with immunity from the jurisdiction of courts within the United States or from the enforcement of judgments or writs of attachment on its assets or permit the applicable Lender (or such Governmental Authority) to reject, repudiate, disavow or disaffirm any contracts or agreements made with the applicable Lender, or (e) a Lender that has, or has a direct or indirect parent company that has, become the subject of a Bail-In Action.
Event of Default has the meaning specified in Section 8.01.
Seller Default has the meaning set forth in Section 12.1.
Material Event of Default means the occurrence of an Event of Default (as defined in the Senior Unsecured Loan Agreement) under any of the following sections of the Senior Unsecured Loan Agreement:
Note Event of Default means any “Event of Default” specified in Section 5.1 of the Indenture.
Loan Event of Default means any of the events specified in Section 5.1 of the Loan Agreement, provided that any requirement for the giving of notice, the lapse of time, or both, or any other condition, event or act has been satisfied.
Senior Default means any Senior Payment Default or Senior Covenant Default.
Employer default means having an outstanding balance or liability to the old fund or to the uninsured employers' fund or being in policy default, as defined in W. Va. Code § 23-2c-2, failure to maintain mandatory workers' compensation coverage, or failure to fully meet its obligations as a workers' compensation self-insured employer. An employer is not in employer default if it has entered into a repayment agreement with the Insurance Commissioner and remains in compliance with the obligations under the repayment agreement.
Acceleration Event of Default means an Event of Default under Section 5.1(a), (d), (e) or (f), whatever the reason for such Acceleration Event of Default and whether it shall be voluntary or involuntary or be effected by operation of law or pursuant to any judgment, decree or order of any court or any order, rule or regulation of any administrative or governmental body.
Swap Default Any of the circumstances constituting an “Event of Default” under the Swap Agreement.
Financial Covenant Event of Default has the meaning specified in Section 8.01(b).
Declaration Event of Default means an “Event of Default” as defined in the Declaration.