Notice of Damage Upon the loss of, destruction of, or damage to any of the property, Contractor shall notify the HCA Contract Manager thereof within one (1) Business Day and shall take all reasonable steps to protect that property from further damage.
Notice to Landlord (1) If Tenant shall, on one or more occasions, mortgage Tenant’s Leasehold Estate and if the holder of such Permitted Leasehold Mortgage shall provide Landlord with written notice of such Permitted Leasehold Mortgage together with a true copy of such Permitted Leasehold Mortgage and the name and address of the Permitted Leasehold Mortgagee, Landlord and Tenant agree that, following receipt of such written notice by Landlord, the provisions of this Section 17.1 shall apply in respect to each such Permitted Leasehold Mortgage.
(2) In the event of any assignment of a Permitted Leasehold Mortgage or in the event of a change of address of a Permitted Leasehold Mortgagee or of an assignee of such Mortgage, written notice of the new name and address shall be provided to Landlord.
(ii) Landlord shall promptly upon receipt of a communication purporting to constitute the notice provided for by subsection (b)(i) above acknowledge by an executed and notarized instrument receipt of such communication as constituting the notice provided for by subsection (b)(i) above and confirming the status of the Permitted Leasehold Mortgagee as such or, in the alternative, notify the Tenant and the Permitted Leasehold Mortgagee of the rejection of such communication as not conforming with the provisions of this Section 17.1 and specify the specific basis of such rejection.
(iii) After Landlord has received the notice provided for by subsection (b)(i) above, the Tenant, upon being requested to do so by Landlord, shall with reasonable promptness provide Landlord with copies of the note or other obligation secured by such Permitted Leasehold Mortgage and of any other documents pertinent to the Permitted Leasehold Mortgage as specified by the Landlord. If requested to do so by Landlord, Tenant shall thereafter also provide the Landlord from time to time with a copy of each amendment or other modification or supplement to such instruments. All recorded documents shall be accompanied by the appropriate recording stamp or other certification of the custodian of the relevant recording office as to their authenticity as true and correct copies of official records and all nonrecorded documents shall be accompanied by a certification by Tenant that such documents are true and correct copies of the originals. From time to time upon being requested to do so by Landlord, Tenant shall also notify Landlord of the date and place of recording and other pertinent recording data with respect to such instruments as have been recorded.
Landlord’s Option to Repair Notwithstanding the terms of Section 11.1 of this Lease, Landlord may elect not to rebuild and/or restore the Premises, Building and/or Project, in which event this Lease shall terminate, by notifying Tenant in writing of such termination within sixty (60) days after the date of discovery of the damage, such notice will include a termination date giving Tenant sixty (60) days to vacate the Premises, but this Lease may be so terminated Landlord may so elect only if the Building or Project shall be damaged by fire or other casualty or cause, whether or not the Premises are affected, and one or more of the following conditions is present: (i) in Landlord’s reasonable judgment, repairs cannot reasonably be completed within one hundred eighty (180) days after the date of discovery of the damage (when such repairs are made without the payment of overtime or other premiums); (ii) the holder of any mortgage on the Building or Project or ground lessor with respect to the Building or Project shall require that the insurance proceeds or any portion thereof be used to retire the mortgage debt, or shall terminate the ground lease, as the case may be; (iii) the damage is not fully covered by Landlord’s insurance policies or that portion of the proceeds from Landlord’s insurance policies allocable to the Building or the Project, as the case may be; (iv) Landlord decides to rebuild the Building or Common Areas so that they will be substantially different structurally or architecturally; (v) the damage occurs during the last twelve (12) months of the Lease Term; or (vi) any owner of any other portion of the Project, other than Landlord, does not intend to repair the damage to such portion of the Project; provided, however, that if such fire or other casualty shall have damaged the Premises or a portion thereof or Common Areas necessary to Tenant’s occupancy and as a result of such damage the Premises are unfit for occupancy, and provided that Landlord does not elect to terminate this Lease pursuant to Landlord’s termination right as provided above, and either (a) the repairs cannot, in the reasonable opinion of Landlord’s contractor, be completed within two hundred seventy (270) days after being commenced, or (b) the damage occurs during the last twelve months of the Lease Term and will reasonably require in excess of ninety (90) days to repair, Tenant may elect, no earlier than sixty (60) days after the date of the damage and not later than ninety (90) days after the date of such damage, to terminate this Lease by written notice to Landlord effective as of the date specified in the notice, which date shall not be less than thirty (30) days nor more than sixty (60) days after the date such notice is given by Tenant.
Notice to Tenants Seller and Purchaser shall each execute, and Purchaser shall deliver to each tenant immediately after the Closing, a notice regarding the sale in substantially the form of Exhibit D attached hereto, or such other form as may be required by applicable state law. This obligation on the part of Purchaser shall survive the Closing.
Notice to Tenant After notice is given to Tenant by Lender that the Landlord is in default under the Note and the Security Instrument and that the rentals under the Lease should be paid to Lender pursuant to the terms of the assignment of leases and rents executed and delivered by Landlord to Lender in connection therewith, Tenant shall thereafter pay to Lender or as directed by the Lender, all rentals and all other monies due or to become due to Landlord under the Lease and Landlord hereby expressly authorizes Tenant to make such payments to Lender and hereby releases and discharges Tenant from any liability to Landlord on account of any such payments.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
ABATEMENT OF RENT; LESSEE'S REMEDIES (a) In the event of (i) Premises Partial Damage or (ii) Hazardous Substance Condition for which Lessee is not legally responsible, the Base Rent, Common Area Operating Expenses and other charges, if any, payable by Lessee hereunder for the period during which such damage or condition, its repair, remediation or restoration continues, shall be abated in proportion to the degree to which Lessee's use of the Premises is impaired, but not in excess of proceeds from insurance required to be carried under Paragraph 8.3(b). Except for abatement of Base Rent, Common Area Operating Expenses and other charges, if any, as aforesaid, all other obligations of Lessee hereunder shall be performed by Lessee, and Lessee shall have no claim against Lessor for any damage suffered by reason of any such damage, destruction, repair, remediation or restoration.
(b) If Lessor shall be obligated to repair or restore the Premises under the provisions of this Paragraph 9 and shall not commence, in a substantial and meaningful way, the repair or restoration of the Premises within ninety (90) days after such obligation shall accrue, Lessee may, at any time prior to the commencement of such repair or restoration, give written notice to Lessor and to any Lenders of which Lessee has actual notice of Lessee's election to terminate this Lease on a date not less than sixty (60) days following the giving of such notice. If Lessee gives such notice to Lessor and such Lenders and such repair or restoration is not commenced within thirty (30) days after receipt of such notice, this Lease shall terminate as of the date specified in said notice. If Lessor or a Lender commences the repair or restoration of the Premises within thirty (30) days after the receipt of such notice, this Lease shall continue in full force and effect. "Commence" as used in this Paragraph 9.6 shall mean either the unconditional authorization of the preparation of the required plans, or the beginning of the actual work on the Premises, whichever occurs first.
Landlord’s Default and Tenant’s Remedies In the event Landlord fails to perform any of its obligations under this Lease, Landlord shall nevertheless not be in default under the terms of this Lease until such time as Tenant shall have first given Landlord written notice specifying the nature of such failure to perform its obligations, and then only after Landlord shall have had a reasonable period of time following its receipt of such notice within which to perform such obligations. In the event of Landlord’s default as above set forth, then, and only then, Tenant shall have the following remedies only:
A. Tenant may then proceed in equity or at law to compel Landlord to perform its obligations and/or to recover damages proximately caused by such failure to perform (except as and to the extent Tenant has waived its right to damages as provided in this Lease).
B. Tenant, at its option, may then cure any default of Landlord at Landlord’s cost. If, pursuant to this Subarticle, Tenant reasonably pays any sum to any third party or does any act that requires the payment of any sum to any third part at any time by reason of Landlord’s default, the sum paid by, Tenant shall be immediately due from Landlord to Tenant at the time Tenant supplies Landlord with an invoice therefor (provided such invoice sets forth and is accompanied by a written statement of Tenant setting forth in reasonable detail the amount paid, the party to whom it was paid, the date it was paid, and the reasons giving rise to such payment), together with interest at twelve percent per annum from the date of such invoice until Tenant is reimbursed by Landlord. Tenant may not offset such sums against any installment of rent due Landlord under the terms of this Lease.
Landlord Liability Tenant, its successors, and assigns shall not assert nor seek to enforce any claim for breach of this Lease against any of Landlord’s assets other than Landlord’s interest in the Industrial Center. Tenant agrees to look solely to such interest for the satisfaction of any liability or claim against Landlord under this Lease. In no event whatsoever shall Landlord (which term shall include, without limitation, any general or limited partner, trustees, beneficiaries, officers, directors, or stockholders of Landlord) ever be personally liable for any such liability.
Tenant’s Remedies Notwithstanding any other provision of this Lease, if any default hereunder by Landlord is not cured within the applicable cure period provided in Paragraph 20(c) or any other applicable cure period provided in this Lease (including any Mortgagee’s additional cure period), Tenant’s exclusive remedies shall be (i) an action for specific performance, or (ii) an action for actual damages. Notwithstanding any other provision of this Lease, the liability of Landlord to Tenant for any breach or default by Landlord under the terms of this Lease, or for any other matter related to this Lease or to the Premises or Project, shall be limited to Tenant’s actual direct, but not consequential, damages therefor, and any judgment against Landlord in connection therewith shall be recoverable only from the interest of Landlord in the Buildings. Tenant hereby waives any claim for damages for any disturbance, loss of business, nuisance, injury or inconvenience to or interference with Tenant’s business, any loss of occupancy or quiet enjoyment of the Premises, and any other loss arising from Landlord’s entry and acts pursuant to Paragraph 18 or otherwise with respect to any act, omission or breach of Landlord. Without limiting the preceding sentence, in no event shall Landlord be liable to Tenant for any consequential damages, including, without limitation, any losses arising from any interruption of Tenant’s business, or for lost profits, or for charges or expenses which continue but would have been earned if the business had gone on without interruption, or for any other loss, claim, cost, expense or damage which would be covered by a standard policy of business interruption insurance. Landlord, or if Landlord is a partnership its partners whether general or limited, or if Landlord is a corporation its directors, officers or shareholders, or if Landlord is a limited liability company its members or managers, shall never be personally liable for any such judgment. Any lien obtained to enforce such judgment and any levy of execution thereon shall be subject and subordinate to any Mortgage (excluding any Mortgage which was created as part of an effort to defraud creditors, i.e., a fraudulent conveyance); provided, however that any such judgment and any such levy of execution thereon shall not be subject or subordinated to any Mortgage that is created or recorded in the official records of the county in which the Project is located after the date of the judgment giving rise to such lien. Landlord’s interest in the Buildings shall include any insurance proceeds received by Landlord which are not controlled by any Mortgagee or other lender. Tenant hereby waives the benefit of any Laws granting it (A) the right to perform Landlord’s obligations, or (B) the right to terminate this Lease or withhold Rent on account of any Landlord default, including, without limitation, Sections 1932(1), 1941 and 1942 of the California Civil Code.
