Landlord's Damages definition

Landlord's Damages means the sum of (i) the present value of the Base Rent and additional rent specified in this lease for the residue of the stated term following termination of the lease or of Tenant's rights to possession less the present value of fair market rental value of the demised premises for such residue and (ii) any other sums then due to Landlord hereunder. In calculating the amount of Landlord's damages (x) present value shall be computed on the basis of a discount of ten percent (10%) per year and (y) the additional rent due Landlord for the rest of the lease term shall be deemed to equal the additional rent payable for the last calendar year of the lease term prior to termination of this lease or of Tenant's right to possession (or the additional rent which would have been paid for the calendar year in which such termination occurred, if no additional rent had previously been paid).
Sample 1
Landlord's Damages means the sum of (i) the Rent specified in this Lease for the remainder of the stated Term following termination of this Lease or of Tenant's right to possession, (ii) any other sums or damages then due to Landlord hereunder, and (iii) any other expenses, costs or damages (including, without limitation, reasonable attorneys' fees and court costs and any damages or deficiency in the reletting of the Premises) incurred by Landlord in connection with any default hereunder or any corresponding default under the Master Lease.
Sample 1
Landlord's Damages means an amount equal to the present value of the amount by which the Remainder Rent exceeds the Fair Market Rent for the remainder of the stated Term of this Lease. The present value shall be computed on the basis of a discount rate equal to the then-current yield on United States Treasury obligations having a maturity approximately equal to the residue of the stated Term of the Lease (had there been no Default), as determined by Landlord.
Sample 1

Related to Landlord's Damages

  • Premises Building Partial Damage means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is less than fifty percent (50%) of the then Replacement Cost of the building.

  • Sublandlord means the holder of sublandlord’s interest under this Sublease. In the event of any assignment or transfer of the Sublandlord’s interest under this Sublease, which assignment or transfer may occur at any time during the Term in Sublandlord’s sole discretion, Sublandlord shall be and hereby is entirely relieved of all covenants and obligations of Sublandlord hereunder accruing subsequent to the date of the transfer and it shall be deemed and construed, without further agreement between the parties hereto, that any transferee has assumed and shall carry out all covenants and obligations thereafter to be performed by Sublandlord hereunder. Sublandlord may transfer and deliver the then existing Letter of Credit to the transferee of Sublandlord’s interest under this Sublease, and thereupon Sublandlord shall be discharged from any further liability with respect thereto. In addition. Sublandlord shall comply with all of its obligations as “Tenant” under the Master Lease except to the extent that any such obligation is the obligation of Subtenant pursuant to the terms of this Sublease. Notwithstanding any other term or provision of this Sublease, the liability of Subtenant to Sublandlord for any default in Subtenant’s obligations under this Sublease shall be limited to actual, direct damages, and under no circumstances shall Sublandlord, its partners, members, shareholders, directors, agents, officers, employees, contractors, sublessees, successors and/or assigns be entitled to recover from Subtenant (or otherwise be indemnified by Subtenant) for lost revenues, lost profit or other consequential, special or punitive damages arising in connection with this Sublease for any reason, except for any breach by Subtenant under Section 12 of the Master Lease. Notwithstanding any other term or provision of this Sublease, no personal liability shall at any time be asserted or enforceable against Subtenant’s shareholders, directors, officers, or partners on account of any of Subtenant’s obligations or actions under this Sublease.

  • Landlord Parties means Landlord and Property Manager and their respective officers, directors, partners, shareholders, members and employees.

  • Major Damage means damage that in the estimation of the surveyor exceeds USD

  • Landlord Party or “Landlord Parties” shall mean Landlord, any affiliate of Landlord, Landlord’s managing agents for the Building, each mortgagee (if any), each ground lessor (if any), and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents or representatives. For the purposes of this Lease, the term “Tenant Party” or “Tenant Parties” shall mean Tenant, any affiliate of Tenant, any permitted subtenant or any other permitted occupant of the Premises, and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents, invitees or representatives.

  • Environmental Damages means all liabilities (including strict liability), losses, damages (excluding consequential, special, exemplary or punitive damages except to the extent such damages were imposed upon an Indemnitee as a result of any claims made against such Indemnitee by a governmental entity or any other third party), judgments, penalties, fines, costs and expenses (including fees, costs and expenses of attorneys, consultants, contractors, experts and laboratories), of any and every kind or character, at law or in equity, contingent or otherwise, matured or unmatured, foreseeable or unforeseeable, made, incurred, suffered, brought, or imposed at any time and from time to time, whether before or after the Release Date and arising in whole or in part from:

  • Subleased Premises means all that portion of the Leased Premises referred to as airport lot as outlined on the site diagram attached as Schedule "A" to this Sublease; and

  • Premises Partial Damage means damage or destruction to the Premises, other than Lessee-Owned Alterations and Utility Installations, the repair cost of which damage or destruction is less than fifty percent (50%) of the then Replacement Cost (as defined in Paragraph 9.1(d)) of the Premises (excluding Lessee-Owned Alterations and Utility Installations and Trade Fixtures) immediately prior to such damage or destruction.

  • Loss or Damage means any loss or damage to the Vehicle, including that caused by theft of the Vehicle or by adverse weather events, that requires repair or replacement including the loss of use of the Vehicle (demurrage), legal expenses, assessment fees, towing and recovery costs, storage, service charges and any appraisal fees of the Vehicle;

  • Landlord Delay means a delay in the construction of the Tenant Improvements or Compliance Work resulting directly from the acts or omissions of Landlord, Landlord’s employees, agents, or contractors including, but not limited to (i) failure of Landlord to timely approve or disapprove any plans; (ii) interference by Landlord, its employees, agents or contractors with the completion of the Tenant Improvements or Compliance Work (including the impairment of Tenant’s contractors’ or vendors’ or employees’ access to the Premises for any reason (including due to the presence of Landlord’s contractors, vendors or personnel), failure to provide reasonable access to the Building’s loading docks or other facilities necessary for the construction of the Tenant Improvements or Compliance Work and/or the movement of materials and personnel to the Premises for such purpose) and (iii) delays due to the acts or failures to act of Landlord, its agents or contractors with respect to payment of the Tenant Improvement Allowance. If Tenant contends that a Force Majeure Construction Delay or a Landlord Delay has occurred, Tenant acknowledges and agrees that it has inspected the Building and the Site and in no event shall the physical character or condition of the Building and/or Site existing as of the Effective Date constitute a basis for a Landlord Delay (this agreement does not apply to the failure of any Building component to properly operate). Further, in no event shall any delay of Landlord constitute a Landlord Delay unless such delay results in a full day of delay in the construction of the Tenant Improvements or Compliance Work. Tenant shall notify Landlord in writing (the “Delay Notice”) of the event which constitutes such Force Majeure Construction Delay or Landlord Delay; such notice may be via electronic mail to Landlord’s construction representative described above. Tenant will additionally use reasonable efforts to mitigate the effects of any Force Majeure Construction Delay or Landlord Delay through the re-sequencing or re-scheduling of work, if feasible, but this sentence will not be deemed to require Tenant to incur overtime or after-hours costs unless Landlord agrees in writing to bear such costs. If the actions or inactions or circumstances described in the Delay Notice constitute a Landlord Delay, and are not cured by Landlord within one (1) business day after Landlord’s receipt of the Delay Notice, then a Landlord Delay shall be deemed to have occurred commencing as of the expiration of such one (l)-business day period. The Lease Commencement Date and the Lease Expiration Date will each be delayed on a day for day basis for each day of Force Majeure Construction Delay or Landlord Delay.

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Landlord means the owner, lessor or sublessor of the dwelling unit or the building of which such

  • Sublessor means one who conveys real property by sublease."

  • Structural damage means a covered building, regardless of the date of its construction, has experienced the following.

  • Environmental Damage means any material injury or damage to persons, living organisms or property or any material pollution or impairment of the environment resulting from the discharge, emission, escape or migration of any substance, energy, noise or vibration;

  • Subtenant means any Person entitled to occupy, use, or possess any Premises under a Sublease.

  • Tenant means a person entitled under a rental agreement to occupy a dwelling unit to the exclusion of others.

  • Additional Rent means all amounts payable by the Tenant under this Lease except Base Rent, whether or not specifically designated as Additional Rent elsewhere in this Lease;

  • Leased Premises means the Leased Premises as defined in Paragraph 1.

  • Direct Damage has the meaning given to it in clause 26.2;

  • The Building means any building of which the Property forms part.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).

  • Tenants means the tenants under the Leases.

  • Sublessee means any party to whom Lessee grants the right to possess all or any portion of the Premises according to a Sublease.

  • Rent means “eligible rent” to which regulation 12 of the Housing Benefit (Persons who have attained the qualifying age for state pension credit) Regulations 2006 refer, less any deductions in respect of non-dependants which fall to be made under paragraph 30 (non-dependant deductions);