Tenant’s possession of the Premises during the Extension Sample Clauses

Tenant’s possession of the Premises during the Extension. Terms shall be under and subject to all the terms, covenants and conditions set forth in the Lease, with the exception that the minimum net rental payable during any Extension Term shall be the then-market rate for similar industrial buildings within the market area for the Premises. In the event the parties are unable in good faith to agree upon the market rent for any Extension Term, the issue shall be determined by three independent MAI appraisers with commercial/industrial rental real estate experience in the area where the Premises is located, one selected by Landlord, one by Tenant, and the third by the other two so chosen. The parties shall each appoint their respective appraiser within ten (10) days after either party declares an impasse by written notice to the other, and the third appraiser shall be selected within ten (10) days after the first two are chosen. The third appraiser shall, within ten (10) days of receipt of the two appraisers’ determinations, select the determination of Landlord’s or Tenant’s appraiser which he or she believes reflects the market rent. The determination of the third appraiser shall be binding upon Landlord and Tenant, and judgment thereon may be entered in any court of competent jurisdiction. Provided however, in no event shall the minimum net rent payable for any Extension Term be less than the minimum net rent payable for the preceding Term or Extension Term regardless of the determination made by any appraiser. The cost of the third appraiser shall be borne equally by Landlord and Tenant.
Sample 1
AutoNDA by SimpleDocs

Related to Tenant’s possession of the Premises during the Extension

  • Condition of the Premises Tenant acknowledges that, except as expressly set forth in this Lease, neither Landlord nor any agent of Landlord has made any representation or warranty with respect to the condition of the Premises, the Building or the Property, or with respect to the suitability of the Premises, the Building or the Property for the conduct of Tenant’s business. Tenant acknowledges that Landlord shall have no obligation to alter, repair or otherwise prepare the Premises for Tenant’s occupancy or to pay for or construct any improvements to the Premises except as otherwise expressly set forth in this Lease or in the Work Letter attached hereto as Exhibit 3.1. Notwithstanding anything to the contrary contained herein, Landlord represents and warrants to Tenant that (a) upon the Commencement Date, the Building and the Premises will be in material compliance with all Applicable Laws (in each case, without regard for any of the Finish Work, Tenant’s particular use (as opposed to the Permitted Use, generally), or the obligations of any other tenants in the Building with respect to their tenant improvements); (b) Landlord has full power and authority to enter into this Lease and has obtained all consents and taken all actions necessary in connection therewith other than to the extent provided in Section 14.6, below; and (c) upon the Commencement Date, the Building systems provided by Landlord and serving the Premises including electrical, HVAC, plumbing and other utility systems shall be in good working order and condition. Subject to the foregoing and Landlord’s obligation to repair latent defects in the Base Building Work as expressly provided in Section 1.1 of Exhibit 3.1, Tenant’s execution of this Lease and taking of possession of the Premises shall conclusively establish that the Premises, the Building and the Property were at such time in good, sanitary and satisfactory condition and repair; provided, nothing in this sentence relieves Landlord of its obligations pursuant to Section 8.1, below.

  • Condition of the Leased Property Lessee acknowledges receipt and delivery of possession of the Leased Property. Lessee has examined and otherwise has knowledge of the condition of the Leased Property and has found the same to be satisfactory for its purposes hereunder. Lessee is leasing the Leased Property “as is” in its present condition. Lessee waives any claim or action against Lessor in respect of the condition of the Leased Property. LESSOR MAKES NO WARRANTY OR REPRESENTATION, EXPRESS OR IMPLIED, IN RESPECT OF THE LEASED PROPERTY, OR ANY PART THEREOF, EITHER AS TO ITS FITNESS FOR USE, DESIGN OR CONDITION FOR ANY PARTICULAR USE OR PURPOSE OR OTHERWISE, AS TO THE QUALITY OF THE MATERIAL OR WORKMANSHIP THEREIN, LATENT OR PATENT, IT BEING AGREED THAT ALL SUCH RISKS ARE TO BE BORNE BY LESSEE. LESSEE ACKNOWLEDGES THAT THE LEASED PROPERTY HAS BEEN INSPECTED BY LESSEE AND IS SATISFACTORY TO IT. Provided, however, to the extent permitted by law, Lessor hereby assigns to Lessee all of Lessor’s rights to proceed against any predecessor in title (other than any Affiliate of Lessee, which conveyed the Property to Lessor) for breaches of warranties or representations or for latent defects in the Leased Property. Lessor shall fully cooperate with Lessee in the prosecution of any such claim, in Lessor’s or Lessee’s name, all at Lessee’s sole cost and expense. Lessee hereby agrees to indemnify, defend and hold harmless Lessor from and against any claims, obligations and liabilities against or incurred by Lessor in connection with such cooperation.

  • TENANT'S USE OF THE PREMISES In consideration of the agreements contained herein, Landlord hereby leases the Premises to Tenant, and Tenant hereby leases the Premises from Landlord, for the Term and upon the terms and conditions hereinafter provided. The Premises are leased subject to, and Tenant agrees not to violate, all present and future covenants, conditions and restrictions of record which affect the Land, all of such documents collectively referred to as the "Restrictions". As an appurtenance to the Premises, Tenant shall have the general and nonexclusive right, together with Landlord and the other tenants of the Project and their respective agents, to use the Common Area subject to the terms and conditions of this Lease. Tenant shall use the Premises solely for the purpose set forth in Tenant's Use Clause as designated in Article 2.n and for no other purpose. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall by reason of the nature of Tenant's use or occupancy of the Promises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Board of Fire Insurance underwriters or any other organization performing a similar function. Tenant shall promptly upon demand reimburse Landlord for any additional premium charged for such policy by reason of Tenant's failure to comply with the provisions of this Article. Tenant shall not do or permit anything to be done in or about the Premises which will in any way obstruct or interfere with the rights of other tenants or occupants of the Building or Project, or injure or annoy them, or use or allow the Premises to be used for any improper, immoral, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance in, on or about the Premises. Tenant shall not commit or suffer to be committed any waste in or upon the Premises. Tenant acknowledges that Tenant assumes all responsibility regarding the Occupational Safety Health Act, the legal use and adaptability of the Premises and the compliance thereof with all applicable laws and regulations in effect during the form of this Lease.

  • Delay of the Substantial Completion of the Premises Except as provided in this Section 5.2, the Lease Commencement Date shall occur as set forth in the Lease and Section 5.1, above. If there shall be a delay or there are delays in the Substantial Completion of the Premises or in the occurrence of any of the other conditions precedent to the Lease Commencement Date, as set forth in the Lease, as a direct, indirect, partial, or total result of:

  • Damage or Destruction of Premises If the Premises, the Unit or the Building or any part thereof shall be damaged or destroyed by fire or other casualty (a “casualty”), or ordered to be demolished by the action of any public authority in consequence of a casualty, or taken by any exercise of the right of eminent domain, Tenant shall immediately give notice thereof to Landlord. Unless this Lease is terminated as provided herein, this Lease shall remain in full force and effect and Landlord shall proceed (or shall cause the Primary Board to proceed) with diligence to repair or cause to be repaired such damage so as to restore the Premises, the Building and access thereto, or what may remain thereof (including the Initial Tenant Work but excluding any other Tenant Work), as nearly as practicable to the condition they were in immediately prior to such damage, destruction or taking, subject to then applicable Legal Requirements and Title Matters, but neither Landlord nor the Primary Board shall be required to expend in such repair or rebuilding more than the proceeds of insurance or award of damages, if any, recovered or recoverable with respect to such damage, destruction or taking (plus, in the case of casualty, the amount of any insurance deductibles (which shall be deemed Operating Costs)), less Landlord’s (or the Primary Board’s) reasonable expenses incurred in collecting such proceeds or award, as the case may be, but in the case of damage or destruction only to the extent Landlord was carrying the insurance required to be carried pursuant to this Lease at the time of such damage or destruction. All such repairs made necessary by any negligent act or omission or any willful misconduct of Tenant shall be made by Landlord (or the Primary Board) at Tenant’s expense to the extent that the cost of such repairs is not covered by insurance proceeds available therefor (including the payment by Tenant of any applicable deductible amount). Landlord shall not be liable for delays in the making of any such repairs that are due to Force Majeure, nor shall Landlord be liable for any inconvenience or annoyance to Tenant or injury to the business of Tenant resulting from delays in repairing such damage. All repairs to and replacements of Tenant Property and any Tenant Work other than the Initial Tenant Work shall be made by and at the expense of Tenant, which work Tenant shall promptly commence as soon as practicable and thereafter prosecute diligently to completion.

  • Removal of Tenant Property by Tenant Upon the expiration of the Lease Term, or upon any earlier termination of this Lease, Tenant shall, subject to the provisions of this Article 15, quit and surrender possession of the Premises to Landlord in as good order and condition as when Tenant took possession and as thereafter improved by Landlord and/or Tenant, reasonable wear and tear and repairs which are specifically made the responsibility of Landlord hereunder excepted. Upon such expiration or termination, Tenant shall, without expense to Landlord, remove or cause to be removed from the Premises all debris and rubbish, and such items of furniture, equipment, business and trade fixtures, free-standing cabinet work, movable partitions and other articles of personal property owned by Tenant or installed or placed by Tenant at its expense in the Premises, and such similar articles of any other persons claiming under Tenant, as Landlord may, in its sole discretion, require to be removed, and Tenant shall repair at its own expense all damage to the Premises and Building resulting from such removal.

  • Possession Of Premises Tenant shall not be entitled to possession of the premises designated for lease until the security deposit and first month’s rent (or prorated portion thereof), less any applicable promotional discount, is paid in full and the premises designated for lease is vacated by the prior tenant.

  • Construction of Tenant Improvements by Tenants Agents Construction Contract; Cost Budget. Prior to Tenant's execution of ---------------------------------- the construction contract and general conditions with Contractor (the "Contract"), Tenant shall submit the Contract to Landlord for its approval, which approval shall not be unreasonably withheld or delayed. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, of the final costs to be incurred, or which have been incurred, as set forth more particularly in Sections 2.2.1.1 through ---------------- 2.2.1.8 above, in connection with the design and construction of the Tenant ------- Improvements to be performed by or at the direction of Tenant or the Contractor (which costs form a basis for the amount of the Contract, if any (the "Final Costs"). Prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with a completion bond in an amount equal to the Final Costs to ensure Landlord of the completion of the Tenant Improvements.

  • Tenant’s Repairs Subject to Landlord’s repair obligations in Sections 7.2 and 11.1 below, Tenant shall, at Tenant’s own expense, keep the Premises, including all improvements, fixtures and furnishings therein, in good order, repair and condition at all times during the Lease Term, which repair obligations shall include, without limitation, the obligation to promptly and adequately repair all damage to the Premises and replace or repair all damaged or broken fixtures and appurtenances, together with all portions of the HVAC, electrical, mechanical plumbing, life safety and lab systems from the point that such systems solely serves the Premises and all portions of all fume hoods and other exhaust systems (all such systems collectively being referred to as the “Premises Systems”), in a first-class condition. Tenant’s obligations shall include restorations, replacements or renewals, including capital expenditures for restorations, replacements or renewals which will have an expected life beyond the Term, when necessary to keep the Premises and all improvements thereon or a part thereof and the Premises Systems in first-class order, condition and repair and in compliance with all applicable laws. Except as expressly set forth in this Lease, it is intended by the parties hereto that Landlord shall have no obligation, in any manner whatsoever, to repair or maintain the Premises, the improvements located therein or the equipment therein, or the nonstructural aspects of the Premises Systems, all of which obligations are intended to be the expense of Tenant (whether or not such repairs, maintenance or restoration shall have an expected life extending beyond the Term). Tenant’s maintenance of the Premises Systems shall comply with the manufacturers’ recommended operating and maintenance procedures. Tenant shall enter into and pay for maintenance contracts (in forms satisfactory to Landlord in its sole discretion) for the Premises Systems in accordance with the manufacturers’ recommended operating and maintenance procedures. Such maintenance contracts shall be with reputable contractors, satisfactory to Landlord in its sole discretion, who shall have not less than ten (10) years of experience in maintaining such systems in biotechnical facilities. Tenant shall be solely responsible for the cost of all interior nonstructural improvements or alterations to the Premises or the Premises Systems required by law. Notwithstanding the foregoing, at Landlord’s option, or if Tenant fails to make such repairs, Landlord may, but need not, make such repairs and replacements, and Tenant shall pay Landlord the cost thereof, including a percentage of the cost thereof (to be uniformly established for the Building) sufficient to reimburse Landlord for all overhead, general conditions, fees and other costs or expenses arising from Landlord’s involvement with such repairs and replacements forthwith upon being billed for same.

  • Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.

Time is Money Join Law Insider Premium to draft better contracts faster.