TENANT'S REMEDIES FOR LANDLORD DELAY IN COMPLETION OF INITIAL IMPROVEMENTS Sample Clauses

TENANT'S REMEDIES FOR LANDLORD DELAY IN COMPLETION OF INITIAL IMPROVEMENTS. Subject to the conditions herein set forth, the anticipated Delivery Date is September 1, 1998, meaning that, as provided in Section 1.2(a), the Initial Improvements are to be Substantially Completed by such date. In the event that, due to causes other than Permitted Delays, the Initial Improvements are not Substantially Completed on September 1, 1998, then Contractor, but not Landlord, shall be liable to Tenant for liquidated damages in the amount of Two Thousand Five Hundred and 00/100ths Dollars ($2,500.00) for each day between (i) September 1, 1998, and (ii) the first to occur of (y) the Delivery Date, and (z) June 1, 1999. The effect of a Permitted Delay (determined pursuant to Section 2.4 hereof) shall cause the Delivery Date and the aforesaid June 1, 1999 date to be extended by the duration so determined. The parties hereto have fully negotiated the provisions of this Section 2.6 with respect to liquidated damages, as well as the balance of the terms, provisions and conditions of this Lease, free from any duress or other undue influence. Having determined that the actual amount of any losses which Tenant would incur as a result of any delay in the Initial Term Commencement Date, would be difficult, if not impossible, to ascertain, the parties have, independently and in good faith, determined that the foregoing liquidated damages are a fair and reasonable estimation of and basis for any such losses, and that the liability thereof shall be borne solely by Contractor, and not by Landlord. Accordingly, in the event of any such delay, subject to the conditions set forth above, and anything in this Lease to the contrary notwithstanding, the foregoing liquidated damages shall be the sole obligation of Contractor (and Landlord shall have no liability) in the event of any such delay, and shall be in lieu of any other rights or remedies which Tenant would otherwise have at law or in equity. Anything in this Lease to the contrary notwithstanding, Landlord shall have no liability or obligation in the event of any such delay. Notwithstanding the foregoing, if the Initial Improvements are not Substantially Completed prior to August 31, 1999 (which date shall be subject to extensions resulting only from a Tenant Extension, only, and not for other Permitted Delays), Tenant, pursuant to written notice thereafter to Landlord and Contractor, may terminate this Lease, in which event this Lease shall thereafter become null and void and of no further force and effect, ex...
Sample 1
AutoNDA by SimpleDocs

Related to TENANT'S REMEDIES FOR LANDLORD DELAY IN COMPLETION OF INITIAL IMPROVEMENTS

  • Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.

  • Tenant’s Remedies Notwithstanding any other provision of this Lease, if any default hereunder by Landlord is not cured within the applicable cure period provided in Paragraph 20(c) or any other applicable CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. cure period provided in this Lease (including any Mortgagee’s additional cure period), Tenant’s exclusive remedies shall be (i) an action for specific performance, or (ii) an action for actual damages. Notwithstanding any other provision of this Lease, the liability of Landlord to Tenant for any breach or default by Landlord under the terms of this Lease, or for any other matter related to this Lease or to the Premises or Project, shall be limited to Tenant’s actual direct, but not consequential, damages therefor, and any judgment against Landlord in connection therewith shall be recoverable only from the interest of Landlord in the Buildings. Tenant hereby waives any claim for damages for any disturbance, loss of business, nuisance, injury or inconvenience to or interference with Tenant’s business, any loss of occupancy or quiet enjoyment of the Premises, and any other loss arising from Landlord’s entry and acts pursuant to Paragraph 18 or otherwise with respect to any act, omission or breach of Landlord. Without limiting the preceding sentence, in no event shall Landlord be liable to Tenant for any consequential damages, including, without limitation, any losses arising from any interruption of Tenant’s business, or for lost profits, or for charges or expenses which continue but would have been earned if the business had gone on without interruption, or for any other loss, claim, cost, expense or damage which would be covered by a standard policy of business interruption insurance. Landlord, or if Landlord is a partnership its partners whether general or limited, or if Landlord is a corporation its directors, officers or shareholders, or if Landlord is a limited liability company its members or managers, shall never be personally liable for any such judgment. Any lien obtained to enforce such judgment and any levy of execution thereon shall be subject and subordinate to any Mortgage (excluding any Mortgage which was created as part of an effort to defraud creditors, i.e., a fraudulent conveyance); provided, however that any such judgment and any such levy of execution thereon shall not be subject or subordinated to any Mortgage that is created or recorded in the official records of the county in which the Project is located after the date of the judgment giving rise to such lien. Landlord’s interest in the Buildings shall include any insurance proceeds received by Landlord which are not controlled by any Mortgagee or other lender. Tenant hereby waives the benefit of any Laws granting it (A) the right to perform Landlord’s obligations, or (B) the right to terminate this Lease or withhold Rent on account of any Landlord default, including, without limitation, Sections 1932(1), 1941 and 1942 of the California Civil Code.

  • Construction of Tenant Improvements by Tenants Agents Construction Contract; Cost Budget. Prior to Tenant's execution of ---------------------------------- the construction contract and general conditions with Contractor (the "Contract"), Tenant shall submit the Contract to Landlord for its approval, which approval shall not be unreasonably withheld or delayed. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, of the final costs to be incurred, or which have been incurred, as set forth more particularly in Sections 2.2.1.1 through ---------------- 2.2.1.8 above, in connection with the design and construction of the Tenant ------- Improvements to be performed by or at the direction of Tenant or the Contractor (which costs form a basis for the amount of the Contract, if any (the "Final Costs"). Prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with a completion bond in an amount equal to the Final Costs to ensure Landlord of the completion of the Tenant Improvements.

  • Repair of Damage to Premises by Landlord Tenant shall promptly notify Landlord of any damage to the Premises resulting from fire or any other casualty. If the Premises or any Common Areas serving or providing access to the Premises shall be damaged by fire or other casualty, Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment or other matters beyond Landlord’s reasonable control, and subject to all other terms of this Article 11, restore the Base Building and such Common Areas. Such restoration shall be to substantially the same condition of the Base Building and the Common Areas prior to the casualty, except for modifications required by zoning and building codes and other laws or by the holder of a mortgage on the Building or Project or any other modifications to the Common Areas deemed desirable by Landlord, which are consistent with the character of the Project, provided that access to the Premises and any common restrooms serving the Premises shall not be materially impaired. Upon the occurrence of any damage to the Premises, upon notice (the “Landlord Repair Notice”) to Tenant from Landlord, Tenant shall assign to Landlord (or to any party designated by Landlord) all insurance proceeds payable to Tenant under Tenant’s insurance required under Section 10.3 of this Lease, and Landlord shall repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original condition; provided that if the cost of such repair by Landlord exceeds the amount of insurance proceeds received by Landlord from Tenant’s insurance carrier, as assigned by Tenant, the cost of such repairs shall be paid by Tenant to Landlord prior to Landlord’s commencement of repair of the damage. In the event that Landlord does not deliver the Landlord Repair Notice within sixty (60) days following the date the casualty becomes known to Landlord, Tenant shall, at its sole cost and expense, repair any injury or damage to the Tenant Improvements and the Original Improvements installed in the Premises and shall return such Tenant Improvements and Original Improvements to their original condition. Whether or not Landlord delivers a Landlord Repair Notice, prior to the commencement of construction, Tenant shall submit to Landlord, for Landlord’s review and approval, all plans, specifications and working drawings relating thereto, and Landlord shall select the contractors to perform such improvement work. Landlord shall not be liable for any inconvenience or annoyance to Tenant or its visitors, or injury to Tenant’s business resulting in any way from such damage or the repair thereof; provided however, that if such fire or other casualty shall have damaged the Premises or Common Areas necessary to Tenant’s occupancy, and the Premises are not occupied by Tenant as a result thereof, then during the time and to the extent the Premises are unfit for occupancy, the Rent shall be abated in proportion to the ratio that the amount of rentable square feet of the Premises which is unfit for occupancy for the purposes permitted under this Lease bears to the total rentable square feet of the Premises. In the event that Landlord shall not deliver the Landlord Repair Notice, Tenant’s right to rent abatement pursuant to the preceding sentence shall terminate as of the date which is reasonably determined by Landlord to be the date Tenant should have completed repairs to the Premises assuming Tenant used reasonable due diligence in connection therewith.

  • Tenant’s Repairs Subject to Landlord’s repair obligations in Sections 7.2 and 11.1 below, Tenant shall, at Tenant’s own expense, keep the Premises, including all improvements, fixtures and furnishings therein, in good order, repair and condition at all times during the Lease Term, which repair obligations shall include, without limitation, the obligation to promptly and adequately repair all damage to the Premises and replace or repair all damaged or broken fixtures and appurtenances, together with all portions of the HVAC, electrical, mechanical plumbing, life safety and lab systems from the point that such systems solely serves the Premises and all portions of all fume hoods and other exhaust systems (all such systems collectively being referred to as the “Premises Systems”), in a first-class condition. Tenant’s obligations shall include restorations, replacements or renewals, including capital expenditures for restorations, replacements or renewals which will have an expected life beyond the Term, when necessary to keep the Premises and all improvements thereon or a part thereof and the Premises Systems in first-class order, condition and repair and in compliance with all applicable laws. Except as expressly set forth in this Lease, it is intended by the parties hereto that Landlord shall have no obligation, in any manner whatsoever, to repair or maintain the Premises, the improvements located therein or the equipment therein, or the nonstructural aspects of the Premises Systems, all of which obligations are intended to be the expense of Tenant (whether or not such repairs, maintenance or restoration shall have an expected life extending beyond the Term). Tenant’s maintenance of the Premises Systems shall comply with the manufacturers’ recommended operating and maintenance procedures. Tenant shall enter into and pay for maintenance contracts (in forms satisfactory to Landlord in its sole discretion) for the Premises Systems in accordance with the manufacturers’ recommended operating and maintenance procedures. Such maintenance contracts shall be with reputable contractors, satisfactory to Landlord in its sole discretion, who shall have not less than ten (10) years of experience in maintaining such systems in biotechnical facilities. Tenant shall be solely responsible for the cost of all interior nonstructural improvements or alterations to the Premises or the Premises Systems required by law. Notwithstanding the foregoing, at Landlord’s option, or if Tenant fails to make such repairs, Landlord may, but need not, make such repairs and replacements, and Tenant shall pay Landlord the cost thereof, including a percentage of the cost thereof (to be uniformly established for the Building) sufficient to reimburse Landlord for all overhead, general conditions, fees and other costs or expenses arising from Landlord’s involvement with such repairs and replacements forthwith upon being billed for same.

  • Landlord’s Remedies (a) Upon the occurrence of any Default by Tenant, then in addition to any other remedies available to Landlord, Landlord may exercise the following remedies:

  • Maintenance and Repairs by Tenant Tenant, at its expense, shall --------------------------------- maintain and repair the interior of the Leased Premises, and all heating, air conditioning, ventilating, electrical, mechanical, sprinkler and plumbing systems, equipment, machinery or fixtures exclusively servicing the Leased Premises, together with all pipes, conduits, ducts and drains therefor. Furthermore Tenant, at its expense, shall replace any broken glass in the interior or exterior of the Leased Premises, and shall maintain and repair all entryway doors to the Leased Premises. Landlord shall assign to Tenant all assignable manufacturers' warranties with respect to equipment and fixtures installed in the Leased Premises. Tenant further agrees to keep the Leased Premises in good, tenantable, sanitary, sightly and clean condition and to keep all lobbies and entryways which are part of the Leased Premises clean and free from debris, refuse, obstructions or hazardous conditions. Tenant agrees to notify Landlord in the event an excessive amount of snow accumulates on the roof of the Leased Premises. Tenant shall be responsible for all maintenance or repairs wholly or partially (to the extent of Tenant's part) caused by the negligence or fault of Tenant or any of its agents, visitors or licensees, or by Tenant's breach of any provision of this Agreement. If Tenant does not make the repairs or perform the maintenance required hereunder in a prompt and adequate manner, then after notice to Tenant and opportunity cure as provided herein, Landlord may make such repairs or perform such maintenance and pay the costs thereof, and such costs shall be so much Additional Rent which shall become immediately due and payable by Tenant to Landlord.

  • Repairs by Tenant Tenant shall, at its sole cost and expense, promptly perform all maintenance, repairs, refurbishing and replacement work to the Leased Premises that are not Landlord’s express responsibility under this Lease, and shall keep the Leased Premises in good condition and repair, reasonable wear and tear excepted. Tenant’s repair obligations include repairs to: (a) floor covering, (b) interior partitions, (c) doors, (d) the interior side of demising walls, (e) electronic, phone and data cabling and related equipment that is installed by or for the exclusive benefit of Tenant and located in the Leased Premises or other portions of the Building, (f) supplemental air conditioning units, private showers and kitchens, including hot water heaters, plumbing and similar facilities serving Tenant exclusively, and (g) alterations performed by contractors retained by Tenant, including related HVAC balancing. All Tenant’s work shall be performed in accordance with the rules and procedures described in Section 5.2 hereof. Upon termination of this Lease, Tenant will surrender and deliver the Leased Premises to Landlord in the same condition in which the Leased Premises existed on the Commencement Date, subject, however, to (i) the provisions of Article VI hereof, (ii) the alterations permitted pursuant to this Lease, (iii) the provisions of Section 5.3, and (iv) except for ordinary wear and tear. If Tenant should fail or refuse to make such repairs, refurbishings or replacements or perform said maintenance as and when reasonably required, Landlord may, at its option, but without any obligation to do so, cure such failure or refusal and Landlord’s costs shall be reimburseable by Tenant as additional rent, by Tenant, immediately upon invoicing by Landlord. Notwithstanding the foregoing, Landlord agrees to perform, as Above Standard Services, Tenant’s repair and maintenance obligations with respect to the Leased Premises. Tenant shall notify Landlord of the need for any such repair and maintenance and Landlord shall endeavor to respond timely to each such request.

  • Tenant’s Repairs and Maintenance Tenant covenants and agrees that, from and after the date that possession of the Premises is delivered to Tenant and until the end of the Lease Term, Tenant will keep neat and clean and maintain in good order, condition and repair the Premises and every part thereof, excepting only for those repairs for which Landlord is responsible under the terms of Article VII of this Lease and damage by fire or casualty and as a consequence of the exercise of the power of eminent domain. Tenant shall not permit or commit any waste, and Tenant shall be responsible for the cost of repairs which may be made necessary by reason of damages to common areas in the Building or Prudential Center by Tenant, Tenant’s agents, employees, contractors, sublessees, licensees, concessionaires or invitees. Tenant shall maintain all its equipment, furniture and furnishings in good order and repair. If repairs are required to be made by Tenant pursuant to the terms hereof, Landlord may demand that Tenant make the same forthwith, and if Tenant refuses or neglects to commence such repairs and complete the same with reasonable dispatch after such demand, Landlord may (but shall not be required to do so) make or cause such repairs to be made and shall not be responsible to Tenant for any loss or damage that may accrue to Tenant’s stock or business by reason thereof. If Landlord makes or causes such repairs to be made, Tenant agrees that Tenant will forthwith on demand, pay to Landlord as Additional Rent the cost thereof together with interest thereon at the rate specified in Section 16.21, and if Tenant shall default in such payment, Landlord shall have the remedies provided for non-payment of rent or other charges payable hereunder.

  • Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.

Time is Money Join Law Insider Premium to draft better contracts faster.