Term of Escrow Unless otherwise provided in this Escrow Agreement, final termination of this Escrow Agreement shall occur on the date that (a) all funds held in the Escrow Account are distributed either to the Company or to Subscribers and the Company has informed the Escrow Agent in writing to close the Escrow Account, (b) all funds held in the Escrow Account are distributed to a successor escrow agent upon written instructions from the Company or (c) the Escrow Agent receives written notice from the Company or the Dealer Manager that the Company terminated the Offering. After the termination of this Escrow Agreement, the Company and the Dealer Manager shall not deposit, and the Escrow Agent shall not accept, any additional amounts representing payments by prospective Subscribers.
TERM OF LEASE This Lease shall commence on the date of ________ and shall continue until its natural termination under this part on the date of ________ at 11:59 PM. After the date of termination, this Lease shall automatically renew and shall continue for the same term amount until Landlord or Tenant undertake cancellation of this Lease in writing. At the expiration of this Lease, Tenant shall be responsible for providing a forwarding address to Landlord to receive any funds owed or other notices.
Term of Engagement (a) This Agreement will remain in effect until April 15, 2010, after which either party shall have the right to terminate it on thirty (30) days prior written notice to the other. The date of termination of this Agreement is referred to herein from time to time as the "Termination Date." The period of time during which this Agreement remains in effect is referred to herein from time to time as the "Term". If, within two years after the Termination Date, the Company completes any private financing of equity or debt or other capital raising activity of the Company (other than the exercise by any person or entity of any options, warrants or other convertible securities other than the warrants issued pursuant to this Agreement) with any of the Investors who were first introduced to the Company in connection with the financing contemplated hereby by Xxxxx and disclosed to the Company in writing prior to its introduction to the Company, the Company will pay to Maxim upon the closing of such financing the compensation set forth in Sections 3(a) as a "Source Fee".
(b) Notwithstanding anything herein to the contrary, subject to the two years limitation described in Section 4(a) above, the obligation to pay the compensation and expenses described in Section 3, this Section 4, Sections 5, 7 and 9-17 and all of Exhibit A attached, hereto (the terms of which are incorporated by reference hereto), will survive any termination or expiration of this Agreement. The termination of this Agreement shall not affect the Company's obligation to pay fees to the extent provided for in Section 3 herein and shall not affect the Company's obligation to reimburse the expenses accruing prior to such termination to the extent provided for herein. All such fees and reimbursements due shall be paid to the Placement Agent on or before the Termination Date (in the event such fees and reimbursements are earned or owed as of the Termination Date) or upon the closing of the Offering or any applicable portion thereof (in the event such fees are due pursuant to the terms of Section 3 hereof).
Term of Agreement; Termination A. The term of this Agreement shall commence on the date hereof.
B. This Agreement shall terminate at the Effective Time of the Merger or the earlier of (i) at any time prior to consummation of the Merger by the written consent of the parties hereto and (ii) termination of the Merger Agreement in accordance with its terms. Upon such termination, no party shall have any further obligations or liabilities hereunder; provided, however, such termination shall not relieve any party from liability for any willful breach of this Agreement prior to such termination.
Lease Term The terms and provisions of this Lease shall be effective as of the date of this Lease. The term of this Lease (the “Lease Term”) shall commence on the “Lease Commencement Date,” as that term is set forth in Section 3.2 of the Summary, and shall terminate on the “Lease Expiration Date,” as that term is set forth in Section 3.3 of the Summary, unless this Lease is sooner terminated as hereinafter provided. Tenant hereby acknowledges that the Premises are currently occupied by another tenant of the Building. If Landlord is unable for any reason to deliver possession of the Premises to Tenant on any specific date , then Landlord shall not be subject to any liability for its failure to do so, and such failure shall not affect the validity of this Lease or the obligations of Tenant hereunder. For purposes of this Lease, the term “Lease Year” shall mean each consecutive twelve (12) month period during the Lease Term. At any time during the Lease Term, Landlord may deliver to Tenant a notice in the form as set forth in Exhibit C, attached hereto, as a confirmation only of the information set forth therein, which Tenant shall execute and return to Landlord within ten (10) business days of receipt thereof; provided, however, Tenant’s failure to execute and return such notice to Landlord within such time shall be conclusive upon Tenant that the information set forth in such notice is as specified therein. In addition to the foregoing, subject to any delays caused by Tenant or any Tenant Parties and events of Force Majeure, if Landlord fails to tender possession of the Premises to Tenant on or before January 2, 2015 (the “Base Rent Delivery Date”), Tenant shall be entitled to one (1) day of per diem Base Rent abatement for each day commencing on the day after the Base Rent Delivery Date and ending on the date Landlord so tenders possession of the Premises to Tenant. Any such Base Rent Abatement shall be separate from and in addition to any Rent Abatement described in Section 3.2 below.
Term of the Lease The lease begins at p.m. on (the “Check-in Date”) and ends at a.m. on (the “Checkout Date”).
Initial Lease Term The Initial Lease Term is for a minimum of ten (10) years; however, the State will consider a longer lease term if economic benefits are deemed to be in the State’s best interest. Please propose a fixed, or flat, rental rate for a Gross Lease: including all expenses – taxes, insurance, janitorial services, maintenance, etc. The State may elect to pay for utilities separately so please include a cost per square foot to reduce the rental rate if such occurs.
Commencement of Term (a) The Premises shall be deemed substantially completed upon the issuance of a certificate of substantial completion by Landlord's architect or a certificate of occupancy by the local building authority, notwithstanding that minor or insubstantial details of construction, mechanical adjustment or decoration remain to be performed. If the substantial completion of the Premises by Landlord is delayed in any way by Tenant or Tenant's Representatives, the Premises shall be deemed substantially completed for purposes of this Section on the date when they would have been substantially completed but for such delay.
(b) Tenant's taking possession of the Premises shall be conclusive evidence that the Premises were in good order, condition and repair when Tenant took possession, except for those matters (for which Landlord is responsible as provided in this Lease) of which Tenant gives Landlord notice within 10 days after taking possession. Landlord shall complete or repair such matters as soon as reasonably possible.
(c) If Landlord is unable to deliver possession of the Premises to Tenant within 180 days after the Expected Commencement Date (the Outside Commencement Date), then Tenant, as its sole remedy, may terminate this Lease by notice to Landlord given within 10 days after the Outside Commencement Date. The Outside Commencement Date shall be extended by the period of any delay described in Section 1(a). Landlord shall not be liable to Tenant or any third party for its failure to deliver possession of the Premises to Tenant. If the Commencement Date does not occur within one year after the Expected Commencement Date, this Lease shall terminate and Landlord and Tenant shall have no further obligations to the other, except as may otherwise be provided in this Lease.
(d) After the Commencement Date has been determined, Landlord and Tenant shall execute a supplemental agreement specifying the Commencement Date, Termination Date and such other information as Landlord shall reasonably require.
Release of Escrow Subject to the provisions of Section 4.2, the Escrow Agent shall release the Company Documents and Subscriber Documents as follows:
(a) On the Closing Date, the Escrow Agent will simultaneously release the Company Documents to the Subscriber and release the Subscriber Documents to the Company except that the Due Diligence Fee will be released to the Due Diligence Fee Recipient and the Legal Fees will be released to the Subscriber’s attorneys.
(b) All funds to be delivered to the Company shall be delivered on the Closing Date pursuant to the wire instructions to be provided in writing by the Company to the Escrow Agent.
(c) Notwithstanding the above, upon receipt by the Escrow Agent of joint written instructions ("Joint Instructions") signed by the Company and the Subscriber, it shall deliver the Company Documents and Subscriber Documents in accordance with the terms of the Joint Instructions.
(d) Notwithstanding the above, upon receipt by the Escrow Agent of a final and non-appealable judgment, order, decree or award of a court of competent jurisdiction (a "Court Order"), the Escrow Agent shall deliver the Company Documents and Subscriber Documents in accordance with the Court Order. Any Court Order shall be accompanied by an opinion of counsel for the party presenting the Court Order to the Escrow Agent (which opinion shall be satisfactory to the Escrow Agent) to the effect that the court issuing the Court Order has competent jurisdiction and that the Court Order is final and non-appealable.
Tenant’s Compliance With Landlord’s Fire and Casualty Insurance Tenant shall, at Tenant’s expense, comply with all insurance company requirements pertaining to the use of the Premises. If Tenant’s conduct or use of the Premises causes any increase in the premium for such insurance policies then Tenant shall reimburse Landlord for any such increase. Tenant, at Tenant’s expense, shall comply with all rules, orders, regulations or requirements of the American Insurance Association (formerly the National Board of Fire Underwriters) and with any similar body.
