Interest After Default To the extent permitted by Law, upon the occurrence of an Event of Default and until such time such Event of Default shall have been cured or waived, and at the discretion of the Administrative Agent or upon written demand by the Required Lenders to the Administrative Agent:
Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Payments after Default Upon the occurrence and during the continuance of an Event of Default, (a) interest on the outstanding principal balance of the Loan and, to the extent permitted by Applicable Law, overdue interest and other amounts due in respect of the Loan, shall accrue at the Default Rate, calculated from the date such payment was due without regard to any grace or cure periods contained herein and (b) Lender shall be entitled to receive and Borrower shall pay to Lender on each Payment Date an amount equal to the Net Cash Flow After Debt Service for the prior Monthly Reporting Period, such amount to be applied by Lender to the payment of the Debt in such order as Lender shall determine in its sole discretion, including, without limitation, alternating applications thereof between interest and principal. Interest at the Default Rate and Net Cash Flow After Debt Service shall both be computed from the occurrence of the default until the actual receipt and collection of the Debt (or that portion thereof that is then due). To the extent permitted by Applicable Law, interest at the Default Rate shall be added to the Debt, shall itself accrue interest at the same rate as the Loan and shall be secured by the Pledge Agreement. This paragraph shall not be construed as an agreement or privilege to extend the date of the payment of the Debt, nor as a waiver of any other right or remedy accruing to Lender by reason of the occurrence of any Event of Default; the acceptance of any payment of Net Cash Flow After Debt Service shall not be deemed to cure or constitute a waiver of any Event of Default; and Lender retains its rights under the Note to accelerate and to continue to demand payment of the Debt upon the happening of any Event of Default, despite any payment of Net Cash Flow After Debt Service.
Continuation After Default Even though an event of default may have occurred, this Lease shall continue in effect for so long as Landlord does not terminate Tenant's right to possession under Paragraph 26.B.(1) hereof, and Landlord may enforce all of Landlord's rights and remedies under this Lease and at law or in equity, including without limitation, the right to recover Rent as it becomes due, and Landlord, without terminating this Lease, may exercise all of the rights and remedies of a landlord under Section 1951.4 of the Civil Code of the State of California or any successor code section. Acts of maintenance, preservation or efforts to lease the Premises or the appointment of a receiver under application of Landlord to protect Landlord's interest under this Lease or other entry by Landlord upon the Premises shall not constitute an election to terminate Tenant's right to possession.
Interest After Event of Default If an Event of Default shall have occurred and is continuing, all sums outstanding and unpaid under the Credit Documents, including this Deed of Trust, shall, at Beneficiary’s option, bear interest at the Default Rate until such Event of Default has been cured. Trustor’s obligation to pay such sums and interest shall be secured by this Deed of Trust.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Prepayments After Default Following an Event of Default, if Borrower or anyone on Borrower's behalf makes a tender of payment of all or any portion of the Debt at any time prior to a foreclosure sale (including a sale under the power of sale under the Mortgage), or during any redemption period after foreclosure, (i) the tender of payment shall constitute an evasion of Borrower's obligation to pay any Prepayment Consideration due under this Agreement and such payment shall, therefore, to the maximum extent permitted by law, include a premium equal to the Prepayment Consideration that would have been payable on the date of such tender had the Loan not been so accelerated, or (ii) if at the time of such tender a prepayment of the principal amount of the Loan would have been prohibited under this Agreement had the principal amount of the Loan not been so accelerated, the tender of payment shall constitute an evasion of such prepayment prohibition and shall, therefore, to the maximum extent permitted by law, include an amount equal to the greater of (i) 1% of the then principal amount of the Loan (or the relevant portion thereof being prepaid) and (ii) an amount equal to the excess of (A) the sum of the present values of a series of payments payable at the times and in the amounts equal to the payments of principal and interest (including, but not limited to the principal and interest payable on the Maturity Date) which would have been scheduled to be payable after the date of such tender under this Agreement had the Loan (or the relevant portion thereof) not been accelerated, with each such payment discounted to its present value at the date of such tender at the rate which when compounded monthly is equivalent to the Prepayment Rate, over (B) the then principal amount of the Loan.
Rates Applicable After Default Notwithstanding anything to the contrary contained in Section 2.9 or 2.10, during the continuance of a Default or Unmatured Default the Required Lenders may, at their option, by notice to the Borrower (which notice may be revoked at the option of the Required Lenders notwithstanding any provision of Section 8.2 requiring consent of affected Lenders to changes in interest rates), declare that no Advance may be made as, converted into or continued as a LIBOR Rate Advance. During the continuance of a Default the Required Lenders may, at their option, by notice to the Borrower (which notice may be revoked at the option of the Required Lenders notwithstanding any provision of Section 8.2 requiring consent of affected Lenders to changes in interest rates), declare that (i) each LIBOR Rate Advance shall bear interest for the remainder of the applicable Interest Period at the LIBOR Rate otherwise applicable to such LIBOR Rate Advance for such Interest Period plus 4% per annum and (ii) each Floating Rate Advance shall bear interest at a rate per annum equal to the Floating Rate otherwise applicable to the Floating Rate Advance plus 4% per annum; provided, however, that the Default Rate shall become applicable automatically if a Default occurs under Section 7.1 or 7.2, unless waived by the Required Lenders.
Payments After Event of Default Except as otherwise provided in Section 3.04 hereof, all payments received and amounts held or realized by the Mortgagee (including any amounts realized by the Mortgagee from the exercise of any remedies pursuant to Section 15 of the Lease or Article IV hereof) after an Event of Default shall have occurred and be continuing and after the declaration specified in Section 4.04(b) hereof, as well as all payments or amounts then held by the Mortgagee as part of the Trust Indenture Estate, shall be promptly distributed by the Mortgagee in the following order of priority: First,so much of such payments or amounts as shall be required to (i) reimburse the Mortgagee or WTC for any tax (except to the extent resulting from a failure of the Mortgagee to withhold taxes pursuant to Section 2.04(b) hereof), expense or other loss (including, without limitation, all amounts to be expended at the expense of, or charged upon the rents, revenues, issues, products and profits of, the property included in the Trust Indenture Estate (all such property being herein called the “Mortgaged Property”) pursuant to Section 4.05(b) hereof) incurred by the Mortgagee or WTC (to the extent not previously reimbursed), the expenses of any sale, or other proceeding, reasonable attorneys’ fees and expenses, court costs, and any other expenditures incurred or expenditures or advances made by the Mortgagee, WTC or the Note Holders in the protection, exercise or enforcement of any right, power or remedy or any damages sustained by the Mortgagee, WTC or any Note Holder, liquidated or otherwise, upon such Event of Default shall be applied by the Mortgagee as between itself, WTC and the Note Holders in reimbursement of such expenses and any other expenses for which the Mortgagee, WTC or the Note Holders are entitled to reimbursement under any Operative Agreement and (ii) all amounts payable to the other Indenture Indemnitees hereunder and under the Participation Agreement and the Lease; and in the case the aggregate amount to be so distributed is insufficient to pay as aforesaid in clauses (i) and (ii), then ratably, without priority of one over the other, in proportion to the amounts owed each hereunder; Second,so much of such payments or amounts remaining as shall be required to reimburse the then existing or prior Note Holders for payments made pursuant to Section 5.03 hereof (to the extent not previously reimbursed) shall be distributed to such then existing or prior Note Holders ratably, without priority of one over the other, in accordance with the amount of the payment or payments made by each such then existing or prior Note Holder pursuant to said Section 5.03 hereof; Third,(i) so much of such payments or amounts remaining as shall be required to pay in full the aggregate unpaid Original Amount of all Series A Equipment Notes, and the accrued but unpaid interest and other amounts due thereon (other than Make-Whole Amount which shall not be due and payable) and all other Secured Obligations in respect of the Series A Equipment Notes (other than Make-Whole Amount) to the date of distribution, shall be distributed to the Note Holders of Series A, and in case the aggregate amount so to be distributed shall be insufficient to pay in full as aforesaid, then ratably, without priority of one over the other, in the proportion that the aggregate unpaid Original Amount of all Series A Equipment Notes held by each holder plus the accrued but unpaid interest and other amounts due hereunder or thereunder (other than Make-Whole Amount, if any) to the date of distribution, bears to the aggregate unpaid Original Amount of all Series A Equipment Notes held by all such holders plus the accrued but unpaid interest and other amounts due thereon (other than Make-Whole Amount) to the date of distribution;
Form of Payment After Default Following the occurrence of an event of default by Tenant, Landlord shall have the right to require that any or all subsequent amounts paid by Tenant to Landlord hereunder, whether to cure the default in question or otherwise, be paid in the form of cash, money order, cashier’s or certified check drawn on an institution acceptable to Landlord, or by other means approved by Landlord, notwithstanding any prior practice of accepting payments in any different form.
