Termination because of Uncontrollable Circumstance, Government Action or Other Causes Sample Clauses

Termination because of Uncontrollable Circumstance, Government Action or Other Causes. (a) Owners may terminate this Agreement at any time in the event that: (i) an Uncontrollable Circumstance that causes a delay of the Work [***] or that deprives Owners of the ability or authority to construct or operate the Facility; (ii) the action or failure to act of a Government Authority deprives Owners of the ability or authority to construct or operate the Facility (except to the extent the action or failure results from actions or inactions by Owners reasonably calculated to produce such result); (iii) a Georgia PSC Certification Order certifying the Facility on terms and conditions reasonably acceptable to GPC is not obtained on or before [***]; or 103 (iv) [***] Owners’ payment obligations to Contractor as of any given point in time are in excess of [***]. (b) If Owners elect to terminate this Agreement in accordance with this Section 22.4 (except Section 22.4(a)(iii)), Owners shall provide Contractor with written notice and Owners shall pay Contractor for [***]. Upon such termination and payment, the Parties shall have no further liability to one another other than any liability that arose prior to the termination of this Agreement pursuant to this Section 22.4.
Sample 1
AutoNDA by SimpleDocs
Termination because of Uncontrollable Circumstance, Government Action or Other Causes. (a) Owners may terminate this Agreement at any time in the event that: (i) an Uncontrollable Circumstance that causes a delay of the Work in the aggregate more than [***] or that deprives Owners of the ability or authority to construct or operate the Facility; 107 (ii) the action or failure to act of a Government Authority deprives Owners of the ability or authority to construct or operate the Facility (except to the extent the action or failure results from actions or inactions by Owners reasonably calculated to produce such result); (iii) a Georgia PSC Certification Order certifying the Facility on terms and conditions reasonably acceptable to GPC is not obtained on or before June 30, 2009; or (iv) within the first three years following Full Notice to Proceed, Owners’ payment obligations to Contractor as of any given point in time are in excess of [***]. (b) If Owners elect to terminate this Agreement in accordance with this Section 22.4 (except Section 22.4(a)(iii)), Owners shall provide Contractor with written notice and Owners shall pay Contractor for its Termination Costs; provided, however, that [***]. Upon such termination and payment, the Parties shall have no further liability to one another other than any liability that arose prior to the termination of this Agreement pursuant to this Section 22.4.
Sample 1

Related to Termination because of Uncontrollable Circumstance, Government Action or Other Causes

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Termination or Suspension Under Federal Law (i) If the Employee is removed and/or permanently prohibited from participating in the conduct of the Company’s affairs by an order issued under Sections 8(e)(iv) or 8(g)(i) of the Federal Deposit Insurance Act (“FDIA”) (12 U.S.C. 1818(e)(4) and (g)(1)), all obligations of the Company under this Agreement shall terminate, as of the effective date of the order, but vested rights of the Employee shall not be affected. (ii) If the Bank is in default (as defined in Section 3(x)(1) of the FDIA), all obligations under this Agreement shall terminate as of the date of default; but the vested rights of the Employee shall not be affected. (iii) All obligations under this Agreement shall terminate, except to the extent it is determined that the continuation of this Agreement is necessary for the continued operation of the Bank; (A) by the OCC or its designee, at the time that the Federal Deposit Insurance Corporation (“FDIC”) enters into an agreement to provide assistance to or on behalf of the Bank under the authority contained in Section 13(c) of FDIA; or (B) by the OCC, or its designee, at the time that the OCC or its designee approves a supervisory merger to resolve problems related to operation of the Bank or when the Bank is determined by the OCC to be in an unsafe or unsound condition. Such action shall not affect any vested rights of the Employee. (iv) If a notice served under Section 8(e)(3) or (g)(1) of the FDIA suspends and/or temporarily prohibits the Employee from participating in the conduct of the Bank’s affairs, the Bank’s obligations under this Agreement shall be suspended as of the date of such service, unless stayed by appropriate proceedings. However, the vested rights of the Employee as of the date of suspension will not be affected. If the charges in the notice are dismissed, the Bank may in its discretion (A) pay the Employee all or part of the compensation withheld while its contract obligations were suspended, and (B) reinstate (in whole or in part) any of its obligations which were suspended.

  • Contract Renegotiation, Suspension, or Termination Due to Change in Funding If the funds DSHS relied upon to establish this Contract or Program Agreement are withdrawn, reduced or limited, or if additional or modified conditions are placed on such funding, after the effective date of this contract but prior to the normal completion of this Contract or Program Agreement: a. At DSHS’s discretion, the Contract or Program Agreement may be renegotiated under the revised funding conditions. b. At DSHS’s discretion, DSHS may give notice to Contractor to suspend performance when DSHS determines that there is reasonable likelihood that the funding insufficiency may be resolved in a timeframe that would allow Contractor’s performance to be resumed prior to the normal completion date of this contract. (1) During the period of suspension of performance, each party will inform the other of any conditions that may reasonably affect the potential for resumption of performance. (2) When DSHS determines that the funding insufficiency is resolved, it will give Contractor written notice to resume performance. Upon the receipt of this notice, Contractor will provide written notice to DSHS informing DSHS whether it can resume performance and, if so, the date of resumption. For purposes of this subsubsection, “written notice” may include email. (3) If the Contractor’s proposed resumption date is not acceptable to DSHS and an acceptable date cannot be negotiated, DSHS may terminate the contract by giving written notice to Contractor. The parties agree that the Contract will be terminated retroactive to the date of the notice of suspension. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the retroactive date of termination. c. DSHS may immediately terminate this Contract by providing written notice to the Contractor. The termination shall be effective on the date specified in the termination notice. DSHS shall be liable only for payment in accordance with the terms of this Contract for services rendered prior to the effective date of termination. No penalty shall accrue to DSHS in the event the termination option in this section is exercised.

  • Independence from Material Breach Determination Except as set forth in Section X.D.1.c, these provisions for payment of Stipulated Penalties shall not affect or otherwise set a standard for OIG’s decision that Xxxxx has materially breached this IA, which decision shall be made at OIG’s discretion and shall be governed by the provisions in Section X.D, below.

  • Withdrawal of Property from Market or Termination of Discussions Potential Investor acknowledges that the Property has been offered for sale subject to withdrawal of the Property from the market at any time or rejection of any offer because of the terms thereof, or for any other reason whatsoever, without notice, as well as the termination of discussions with any party at any time without notice for any reason whatsoever.

  • Termination Due To Lack Of Funding Appropriation If, in the judgment of the Director of Accounts and Reports, Department of Administration, sufficient funds are not appropriated to continue the function performed in this agreement and for the payment of the charges hereunder, State may terminate this agreement at the end of its current fiscal year. State agrees to give written notice of termination to contractor at least 30 days prior to the end of its current fiscal year, and shall give such notice for a greater period prior to the end of such fiscal year as may be provided in this contract, except that such notice shall not be required prior to 90 days before the end of such fiscal year. Contractor shall have the right, at the end of such fiscal year, to take possession of any equipment provided State under the contract. State will pay to the contractor all regular contractual payments incurred through the end of such fiscal year, plus contractual charges incidental to the return of any such equipment. Upon termination of the agreement by State, title to any such equipment shall revert to contractor at the end of the State's current fiscal year. The termination of the contract pursuant to this paragraph shall not cause any penalty to be charged to the agency or the contractor.

  • Payment in the Event Losses Fail to Reach Expected Level On the date that is 45 days following the last day (such day, the “True-Up Measurement Date”) of the calendar month in which the tenth anniversary of the calendar day following the Bank Closing occurs, the Assuming Bank shall pay to the Receiver fifty percent (50%) of the excess, if any, of (i) twenty percent (20%) of the Stated Threshold less (ii) the sum of (A) twenty-five percent (25%) of the asset premium (discount) plus (B) twenty-five percent (25%) of the Cumulative Shared-Loss Payments plus (C) the Cumulative Servicing Amount. The Assuming Bank shall deliver to the Receiver not later than 30 days following the True-Up Measurement Date, a schedule, signed by an officer of the Assuming Bank, setting forth in reasonable detail the calculation of the Cumulative Shared-Loss Payments and the Cumulative Servicing Amount.

  • Termination After a Change in Control You will receive Severance Benefits under this Agreement if, during the Term of this Agreement and after a Change in Control has occurred, your employment is terminated by the Company without Cause (other than on account of your Disability or death) or you resign for Good Reason.

  • Obligation after the termination of personal data processing services

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!