Common use of Termination – Convenience of the County Clause in Contracts

Termination – Convenience of the County. The County may terminate performance of work under this Contract for its convenience in whole, or, from time to time, in part if the County’s Project Manager determines that a termination is in the County’s interest. The County’s Project Manager shall terminate the Contract by giving at least 10 business days and delivering to the Contractor a written notice of termination specifying the extent of the termination and the effective date thereof. The parties agree that, as to the terminated portion of the Contract, the Contract shall be deemed to remain in effect until such time as the termination settlement, if any, is concluded DocuSign Envelope ID: 2DBCA84B-8EFB-40F1-B093-49E90BED0348 and the Contract shall not be void. If Contract is terminated without cause, Company shall be responsible for any demobilization costs. After receipt of a notice of termination and, except as directed by the County’s Project Manager, the Contractor shall immediately proceed with the following obligations, as applicable, regardless of any delay in determining or adjusting any amounts due under this clause. Contractor shall: a. Stop work as specified in the notice of termination; b. Place no further subcontracts or orders for materials, services, or facilities, except as necessary to complete the continued portion of the Contract; c. Terminate all orders and subcontracts to the extent they relate to the work terminated; x. Xxxxxx all outstanding liabilities and termination settlement proposals arising from the termination of any subcontracts, the approval or ratification of which will be final for purposes of this clause; e. As directed by the County’s Project Manager transfer title and deliver to the County (a) work in process, completed work, supplies, and other material produced or acquired for the work terminated, and (b) completed or partially completed plans, information, and other property that, if the Contract had been completed, would be required to be furnished to the County; f. Complete performance of the work not terminated; and At the completion of the Contractor’s termination efforts, the Contractor may submit to the County’s Project Manager a list indicating quantity and quality of termination inventory not previously disposed of and request instructions for disposition of the residual termination inventory. After termination the Contractor shall submit a final termination settlement proposal to the County’s Project Manager in a format acceptable to the County. The Contractor shall submit the proposal promptly, but no later than 60 days from the effective date of the termination, unless extended in writing by the County upon written request of the contractor within the 90-day period. However, if the County’s Project Manager determines that the facts justify it, a termination settlement proposal may be received and acted on after the expiration of the filing period or any extension. The Contractor and the County may agree upon the whole or any part of the amount to be paid because of the termination. The amount may include a reasonable allowance for profit on work done, including a reasonable amount for accounting, legal, clerical and other expenses reasonably necessary for the preparation of termination settlement proposals and supporting data, and storage, transportation and other costs incurred, reasonably necessary for the preservation, protection, or disposition of the termination inventory, if any. However, the agreed amount may not exceed the total Contract price as reduced by (a) the amount of payment previously made and

Termination – Convenience of the County. The County COUNTY may terminate performance of work under this Contract CONTRACT for its convenience in whole, or, from time to time, in part if the County’s Project Manager user agency/department determines that a termination is in the CountyCOUNTY’s interest. The County’s Project Manager agency/department assigned buyer shall terminate the Contract CONTRACT by giving at least 10 business days and delivering to the Contractor SUBRECIPIENT a written notice of termination specifying the extent of the termination and the effective date thereof. The parties agree that, as to the terminated portion of the ContractCONTRACT, the Contract CONTRACT shall be deemed to remain in effect until such time as the termination settlement, if any, is concluded DocuSign Envelope ID: 2DBCA84B-8EFB-40F1-B093-49E90BED0348 and the Contract CONTRACT shall not be void. If Contract is terminated without cause, Company shall be responsible for any demobilization costs. After receipt of a notice of termination and, except as directed by the County’s Project Managerassigned buyer, the Contractor SUBRECIPIENT shall immediately proceed with the following obligations, as applicable, regardless of any delay in determining or adjusting any amounts due under this clause. Contractor The SUBRECIPIENT shall: a. 28.1 Stop work as specified in the notice of termination; b. 28.2 Place no further subcontracts or orders for materials, services, or facilities, except as necessary to complete the continued portion of the ContractCONTRACT; c. 28.3 Terminate all orders and subcontracts to the extent they relate to the work terminated; x. Xxxxxx 28.4 Settle all outstanding liabilities and termination settlement proposals arising from the termination of any subcontracts, the approval or ratification of which will be final for purposes of this clause; e. As directed by the County’s Project Manager transfer title and deliver to the County (a) work in process, completed work, supplies, and other material produced or acquired for the work terminated, and (b) completed or partially completed plans, information, and other property that, if the Contract had been completed, would be required to be furnished to the County; f. 28.5 Complete performance of the work not terminated; and 28.6 Take any action that may be necessary or as the COUNTY may direct for the protection and preservation of the property related to this CONTRACT that is in the possession of the SUBRECIPIENT and in which the COUNTY has or may acquire an interest and to mitigate any potential damages or requests for CONTRACT adjustment or termination settlement to the maximum practical extent. At the completion of the ContractorSUBRECIPIENT’s termination efforts, the Contractor SUBRECIPIENT may submit to the County’s Project Manager assigned buyer a list indicating quantity and quality of termination inventory not previously disposed of and request instructions for disposition of the residual termination inventory. After termination the Contractor shall submit a final termination settlement proposal to the County’s Project Manager in a format acceptable to the County. The Contractor shall submit the proposal promptly, but no later than 60 days from the effective date of the termination, unless extended in writing by the County upon written request of the contractor within the 90OC Community Resources FY 0000-day period. However, if the County’s Project Manager determines that the facts justify it, a termination settlement proposal may be received and acted on after the expiration of the filing period or any extension. The Contractor and the County may agree upon the whole or any part of the amount to be paid because of the termination. The amount may include a reasonable allowance for profit on work done, including a reasonable amount for accounting, legal, clerical and other expenses reasonably necessary for the preparation of termination settlement proposals and supporting data, and storage, transportation and other costs incurred, reasonably necessary for the preservation, protection, or disposition of the termination inventory, if any. However, the agreed amount may not exceed the total 000000-00 Contract price as reduced by (a) the amount of payment previously made andPS Contract #1618-

Termination – Convenience of the County. The County may terminate performance of work under this Contract for its convenience in whole, or, from time to time, in part if the County’s Project Manager determines that a termination is in the County’s interest. The County’s Project Manager shall terminate the Contract by giving at least 10 business days and delivering to the Contractor a written notice of termination specifying the extent of the termination and the effective date thereof. The parties agree that, as to the terminated portion of the Contract, the Contract shall be deemed to remain in DocuSign Envelope ID: 6F3A15BA-C997-4A2F-85B8-61ADC00D23BB effect until such time as the termination settlement, if any, is concluded DocuSign Envelope ID: 2DBCA84B-8EFB-40F1-B093-49E90BED0348 and the Contract shall not be void. If Contract is terminated without cause, Company shall be responsible for any demobilization costs. After receipt of a notice of termination and, except as directed by the County’s Project Manager, the Contractor shall immediately proceed with the following obligations, as applicable, regardless of any delay in determining or adjusting any amounts due under this clause. Contractor shall: a. Stop work as specified in the notice of termination; b. Place no further subcontracts or orders for materials, services, or facilities, except as necessary to complete the continued portion of the Contract; c. Terminate all orders and subcontracts to the extent they relate to the work terminated; x. Xxxxxx all outstanding liabilities and termination settlement proposals arising from the termination of any subcontracts, the approval or ratification of which will be final for purposes of this clause; e. As directed by the County’s Project Manager transfer title and deliver to the County (a) work in process, completed work, supplies, and other material produced or acquired for the work terminated, and (b) completed or partially completed plans, information, and other property that, if the Contract had been completed, would be required to be furnished to the County; f. Complete performance of the work not terminated; and At the completion of the Contractor’s termination efforts, the Contractor may submit to the County’s Project Manager a list indicating quantity and quality of termination inventory not previously disposed of and request instructions for disposition of the residual termination inventory. After termination the Contractor shall submit a final termination settlement proposal to the County’s Project Manager in a format acceptable to the County. The Contractor shall submit the proposal promptly, but no later than 60 days from the effective date of the termination, unless extended in writing by the County upon written request of the contractor within the 90-day period. However, if the County’s Project Manager determines that the facts justify it, a termination settlement proposal may be received and acted on after the expiration of the filing period or any extension. The Contractor and the County may agree upon the whole or any part of the amount to be paid because of the termination. The amount may include a reasonable allowance for profit on work done, including a reasonable amount for accounting, legal, clerical and other expenses reasonably necessary for the preparation of termination settlement proposals and supporting data, and storage, transportation and other costs incurred, reasonably necessary for the preservation, protection, or disposition of the termination inventory, if any. However, the agreed amount may not exceed the total Contract price as reduced by (a) the amount of payment previously made and

Termination – Convenience of the County. The County may terminate performance of work under this Contract contract for its convenience in whole, or, from time to time, in part if the County’s Project Manager determines that a termination is in the County’s interestthe 1. The County’s Project Manager shall terminate the Contract by giving at least 10 business days and delivering to the Contractor a written notice of termination specifying the extent of the termination and the effective date thereof. The parties agree that, as to the terminated portion of the Contract, the Contract shall be deemed to remain in effect until such time as the termination settlement, if any, is concluded DocuSign Envelope ID: 2DBCA84B-8EFB-40F1-B093-49E90BED0348 and the Contract shall not be void. If Contract is terminated without cause, Company shall be responsible for any demobilization costs. After receipt of a notice of termination and, except as directed by the County’s Project Manager, the Contractor shall immediately proceed with the following obligations, as applicable, regardless of any delay in determining or adjusting any amounts due under this clause. Contractor shall: a. Stop work as specified in the notice of termination; b. 2. Place no further subcontracts or orders for materials, services, or facilities, except as necessary to complete the continued portion of the Contractcontract; c. 3. Terminate all orders and subcontracts to the extent they relate to the work terminated; x. Xxxxxx 4. Settle all outstanding liabilities and termination settlement proposals arising from the termination of any subcontracts, the approval or ratification of which will be final for purposes of this clause; e. As directed by the County’s Project Manager transfer title and deliver to the County (a) work in process, completed work, supplies, and other material produced or acquired for the work terminated, and (b) completed or partially completed plans, information, and other property that, if the Contract had been completed, would be required to be furnished to the County; f. 5. Complete performance of the work not terminated; and 6. Take any action that may be necessary or as the County may direct for the protection and preservation of the property related to this contract that is in the possession of the contractor and in which the County has or may acquire an interest and to mitigate any potential damages or requests for contract adjustment or termination settlement to the maximum practical extent. At the completion of the Contractorcontractor’s termination efforts, the Contractor contractor may submit to the County’s Project Manager assigned buyer a list indicating quantity and quality of termination inventory not previously disposed of and request instructions for disposition of the residual termination inventory. After termination the Contractor contractor shall submit a final termination settlement proposal to the County’s Project Manager user agency/department in a format acceptable to the County. The Contractor contractor shall submit the proposal promptly, but no later than 60 days from the effective date of the termination, unless extended in writing by the County upon written request of the contractor within the 90-day period. However, if the County’s Project Manager agency/department determines that the facts justify it, a termination settlement proposal may be received and acted on after the expiration of the filing period or any extension. The Contractor contractor and the County may agree upon the whole or any part of the amount to be paid because of the termination. The amount may include a reasonable allowance for profit on work done, including a reasonable amount for accounting, legal, clerical and other expenses reasonably necessary for the preparation of termination settlement proposals and supporting data, and storage, transportation and other costs incurred, reasonably necessary for the preservation, protection, or disposition of the termination inventory, if any. However, the agreed amount may not exceed the total Contract contract price as reduced by (a) the amount of payment previously made and (b) the contract price of work not terminated. The contract shall be amended and the contractor paid the agreed amount. If the contractor and the County fail to agree on the whole amount to be paid because of the termination of work, the County shall pay the contractor the amounts determined by the County as follows, but without duplication of any amounts agreed on as set forth above: 1. The contract price for completed supplies or services accepted by the County (or sold or acquired) not previously paid for, adjusted for any savings of freight and other charges; and 2. Except for normal spoiling and except to the extent that the County expressly assumes the risk of loss, the County shall exclude from the amounts payable to the contractor the fair value, as determined by the agency/department, of property that is destroyed, lost, stolen, or damaged so as to become undeliverable to the County. The contractor shall use generally accepted accounting principles and sound business practices in determining all costs claimed, agreed to, or determined under this clause. Such costs shall be allocable to the terminated contract or portion thereof, allowable under applicable laws, regulations, generally accepted accounting principles and good business judgment and objectively reasonable. The contractor shall have the right to appeal, under the County’s protest procedure, any determination made by the County, except that if the contractor failed to submit the termination settlement proposal within the time provided and failed to request a time extension, there is no right of appeal. In arriving at the amount due the contractor under this clause, there shall be deducted: 1. All payment to the contractor under the terminated portion of this contract; 2. Any claim which the County has against the contractor under this or any other contract; and 3. The agreed price for or proceeds of sale of materials, supplies, or other things acquired by the contractor or sold under the provisions of this clause and not recovered by or credited to the County. If the termination is partial, the contractor may file a proposal with the agency/department for an equitable adjustment of the price(s) of the continued portion of the contract. The agency/department shall make any equitable adjustment agreed upon. Any proposal by the contractor for an equitable adjustment under this clause shall be requested within 30 days from the effective date of termination unless extended in writing by the agency/department. The County may: 1. Under the terms and conditions it prescribes, make partial payment and payments against costs incurred by the contractor for their terminated portion of the contract, if the County believes that the total of these payments will not exceed the amount to which the contactor will be entitled; and 2. If the total payments exceed the amount finally determined to be due, the contractor shall repay the excess to the County upon demand. In determining the amount payable to the contractor and notwithstanding any other provision, if it appears that the contractor would have sustained a loss on the entire contract had it been completed, the County shall allow no profit and shall reduce the settlement to reflect the indicated rate of loss. Unless otherwise provided in this contract or by statute, the contractor shall maintain all records and documents relating to the terminated portion of this contract for three years after final settlement. This includes all books and other evidence bearing on the contractor’s costs and expenses under this contract. The contractor shall make these records and documents available to the County, at the contractor’s office, at all reasonable times, without any direct charge, with thirty (30) days prior written notice by County. If approved by the County, photographs, microphotographs, electronic storage, or other authentic reproductions may be maintained instead of original records and documents.