Damage, Destruction or Condemnation (a) In the event of damage to or destruction of any portion of the Project resulting from fire or other casualty during the Term, or in the event any portion of the District is condemned or taken for any public or quasi-public use or title thereto is found to be deficient during the Term, the net proceeds of any insurance relating to such damage or destruction, the net proceeds of such condemnation or taking or the net proceeds of any realization on title insurance shall be paid into, and used in accordance with a construction escrow agreement reasonably satisfactory to the City and Developer ("Casualty Escrow").
(b) If, at any time during the Term, the Project or any part thereof shall be damaged or destroyed by a casualty (the "Damaged Facilities"), Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the Damaged Facilities as nearly as possible to their condition immediately prior to the casualty and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(c) If at any time during the Term, title to the whole or substantially all of the Project which has previously been conveyed to Developer shall be taken in condemnation proceedings or by right of eminent domain, Developer, at its sole discretion, may terminate this Agreement as of the date of such taking. For purposes of this Section 6.07(c), "substantially all of the District" shall be deemed to have been taken if the City and Developer, each acting reasonably and in good faith, determine that the untaken portion of the District, including the parking improvements, cannot be practically and economically used by Developer for the purposes and at the times contemplated by this Agreement.
(d) In the event of condemnation of less than the whole or substantially all of the District which has previously been conveyed to Developer during the Term, Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the remaining part of the Project, as nearly as possible, to its former condition, and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(e) Nothing in this section will require the Developer to expend funds in excess of the Casualty Escrow for the repair, restoration and/or replacement of the Damaged Facilities.
Damage or Destruction Condemnation (a) In the event of partial damage or destruction of the Property of a type which can, under the circumstances, be expected in the reasonable judgment of Seller and Buyer to be restored or repaired at a cost of $500,000 or less, then, this Contract shall be consummated on the Closing Date at the Purchase Price, and unless such damage has been repaired by Seller prior to Closing, Seller shall assign to Buyer the casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts expended by Seller for partial restoration and with a credit to Buyer for the amount of any deductible and/or uninsured damage.
(b) In the event that the Property shall have been damaged by fire or casualty, the cost of repair or restoration of which would, in the reasonable judgment of Seller and Buyer, exceed the sum of $500,000, then unless Seller has previously repaired or restored the Property to its former condition, at Buyer’s election, Seller shall either (i) pay over or assign to Buyer, on delivery of the Deed all casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts reasonably expended by Seller for partial restoration, with a credit to Buyer for the amount of any deductible and/or uninsured damage, or (ii) direct Escrow Agent to return the Deposit to Buyer in which case, except for the Surviving Obligation, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto. Notwithstanding the foregoing, if Buyer elects to proceed with the transaction under clause (i) of this paragraph (b), in no event shall Seller be obligated to incur any out of pocket cost above $500,000 (whether attributable to a casualty being uninsured, underinsured or to any deductible).
(c) If all or part of the Property is taken by condemnation, eminent domain or by agreement in lieu thereof, or any proceeding to acquire, take or condemn all or part of the Property is threatened or commenced, Buyer may either terminate this Contract (in which event Buyer shall be entitled to a return of the Deposit and accrued interest thereon, if any, and, except for the Surviving Obligations, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto) or close title to the Property in accordance with the terms hereof, without reduction in the Purchase Price, together with an assignment of Seller's rights to any award paid or payable by or on behalf of the condemning authority. If Seller has received payments from the condemning authority and if Buyer elects to close title to the Property, Seller shall credit the amount of said payment against the Purchase Price at the Closing.
Damage, Destruction and Condemnation (a) Seller will bear the risk of loss for any damage, destruction, or condemnation that may occur prior to Closing. If any portion of the Property is damaged or destroyed prior to Closing, Purchaser may elect to terminate this Agreement, unless prior to Closing all that damage has been repaired and the Improvements restored or replaced to their condition prior to the damage. If any material portion of the Property is condemned or taken prior to Closing, Purchaser may elect to terminate this Agreement.
(b) Purchaser's election under this Section with respect to any condemnation or taking will be exercised by written notice to Seller within twenty (20) days after written notice from Seller of the condemnation or taking. Purchaser's election under this Section with respect to any damage or destruction not repaired prior to Closing will be exercised by written notice to seller within twenty (20) days of the later to occur of:
(i) written notice from Seller of the damage or destruction and Seller's inability to repair and restore prior to Closing; or
(ii) written notice from Seller's insurance carrier regarding the estimated cost of repair, replacement, or reconstruction and the portion of the repair, replacement, or reconstruction for which insurance proceeds will be made available. The Closing Date will be extended as necessary to give Purchaser time to make the election.
(c) If Purchaser elects to terminate this Agreement under this Section, neither party will have any further rights, duties, or obligations. If Purchaser does not elect to terminate this Agreement, this Agreement will remain in full force and the purchase contemplated in this Agreement, less any interest taken by condemnation, will be effected, and at the Closing, Seller will pay the Purchaser the amount of any deductible under Seller's insurance policy and will assign, transfer, and set over to Purchaser all of Seller's right, title, and interest to any condemnation awards or insurance proceeds that have been or that may later be made for the taking or destruction.
Casualty or Condemnation If, prior to the Closing, the Improvements or any material portion thereof (having a replacement cost equal to or in excess of $100,000 are damaged or destroyed by fire or casualty, or are taken by eminent domain by any governmental entity, and Seller is unable to restore such damage or destruction prior to the Closing Date in the case of a casualty, then Buyer shall have the option, exercisable by written notice given to Seller at or prior to the Closing, to terminate this Agreement, whereupon all obligations of all parties hereto shall cease, the Deposit shall be returned to Buyer, and this Agreement shall be void and without recourse to the parties hereto except for provisions which are expressly stated to survive such termination. If Buyer does not elect to terminate this Agreement as aforesaid or if such damage or destruction or taking has a replacement cost or is in an amount of less than $100,000, Buyer shall proceed with the consummation of the Closing (to the extent then otherwise obligated to do so) without reduction or offset of the Purchase Price, and in such case, unless the Seller shall have previously restored the Real Property to its condition prior to the occurrence of any such damage or destruction, Seller shall pay over or assign to Buyer all amounts received or due from, and all claims against, any insurance company or governmental entity as a result of such destruction or taking, and Seller shall pay the applicable deductible amount under the insurance maintained by Seller. In the event of any such casualty or condemnation, Seller agrees to (a) provide Buyer with copies of all written communications between Seller or the Partnership and their insurance carriers or the applicable governmental authorities, as applicable, the subject matter of which is the adjustment of insurance proceeds or condemnation awards, and (b) allow Buyer to review and make comments to any proposed settlement arrangement proposed to be entered into by Seller or the Partnership with any such third party; provided, that after the Inspection Period, if Buyer has not terminated this Agreement, Seller shall not enter into any settlement arrangement concerning casualty or condemnation in excess of $50,000 without obtaining the prior written consent of Buyer, which consent may be granted or withheld in Buyer’s sole discretion.
Casualty; Condemnation (a) If any condemnation or conveyance in lieu thereof of all or any portion of the Real Property occurs or is threatened prior to Closing (written notice of which shall be given to Purchaser by Seller promptly upon its receipt), Purchaser may at its option, either (i) terminate this Agreement by written notice to Seller given within twenty (20) days after Purchaser is notified of such actual or possible proceedings (but before the Closing), in which case all of the Escrow Funds shall be returned to Purchaser and all further rights and obligations of the parties under this Agreement shall terminate, except those expressly stated to survive termination, or (ii) proceed to Closing without abatement of the Purchase Price, in which case all proceeds or award (less any expenses incurred by Seller) shall be assigned to Purchaser. If any condemnation or conveyance in lieu thereof is presently pending or occurs after the date hereof, Seller shall not settle or agree to accept any compensation for same without Purchaser’s prior written consent, not to be unreasonably withheld.
(b) In the event of loss or damage to the Property or any portion thereof which is not “major” (as hereinafter defined), this Agreement shall remain in full force and effect, and neither Purchaser nor Seller shall have the right to terminate this Agreement and the parties shall nonetheless consummate this transaction in accordance with this Agreement, without any abatement of the Purchase Price or any liability or obligation on the part of Seller by reason of said damage except as set forth in the next sentence. In such event, the transaction shall proceed as contemplated herein, Seller shall provide a credit against the Purchase Price equal to Seller’s interest in insurance proceeds that have been collected by Seller and assign to Purchaser all of Seller’s right, title and interest in the proceeds to be paid on the claim of loss, less any sums expended by Seller prior to Closing in connection with its insurance claim (including any deductibles paid) or for the restoration or repair of the damaged Property.
(c) In the event of a “major” loss or damage to the Property or any portion thereof, Purchaser may terminate this Agreement by written notice to Seller, in which event the Escrow Funds shall be returned to Purchaser. If Purchaser does not give written notice of termination of this Agreement within twenty (20) days after Seller sends Purchaser written notice of the occurrence of major loss or damage, then Purchaser shall be deemed to have elected to proceed with Closing, in which event, the transaction shall proceed as contemplated herein, Seller shall provide a credit against the Purchase Price equal to Seller’s interest in insurance proceeds that have been collected by Seller and assign to Purchaser all of Seller’s right, title and interest in the proceeds to be paid on the claim of loss, less any sums expended by Seller prior to Closing in connection with its insurance claim (including any deductibles paid) or for the restoration or repair of the damaged Property.
(d) For purposes of this Section 12, “major” loss or damage refers to loss or damage to the Property or any portion thereof: (i) such that the cost of repair or restoration of the damage to a condition substantially identical to that prior to the event of damage would be, either be equal to or greater than $500,000 or require more than 120 days after the loss or damage to repair and restore, as determined by an independent appraiser chosen by Purchaser and reasonably acceptable to Seller, or (ii) having a material adverse impact upon the ability or feasibility of operating a nursing home facility on the Property, in substantially the same manner as the Property is being operated by Seller on the date hereof. Within ten (10) days after its occurrence, Seller shall give Purchaser written notice of any casualty and, if then available, an estimate of the restoration costs and time for restoration.
EMINENT DOMAIN/CONDEMNATION 7.1 Lessor to notify Lessee 7.2 Whole taking, rents prorated 7.3 Taking
DAMAGE OR DESTRUCTION OF PREMISES a. In the event the Premises are damaged by fire or other perils or casualty covered by fire and extended coverage insurance, Landlord may, in its sole and absolute discretion, repair or rebuild the same within a reasonable time after the event causing such damage. This Lease shall remain in full force and effect, except that Tenant shall be entitled to a proportionate reduction of the rent from the date of damage and while such repairs are being made, such proportionate reduction to be based upon the extent to which the damage and making of such repairs shall reasonably interfere with the business carried on by Tenant in the Premises as determined by Landlord. If the damage is due to the fault or neglect of Tenant or its employees, as determined by Landlord in its sole discretion, there shall be no reduction of rent. Landlord may authorize or direct construction of an alternative structure or may elect to retain any insurance proceeds received by it if Landlord deems reconstruction or construction of an alternative structure to be impractical or unreasonable in its sole discretion.
b. In the event the Premises are damaged to any extent as a result of any cause other than the perils covered by fire and extended coverage insurance, Landlord shall in its sole discretion have the option to: (1.) to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage, in which case this Lease shall continue in full force and effect, but the rent shall be proportionately reduced as provided above in 11a. during the period of such repair, reconstruction or restoration, or (2.) to give notice to Tenant at any time within sixty (60) days after such damage occurs, terminating this Lease as of the date specified in such notice, which date shall be no more than thirty (30) days after the giving of such notice. In the event of giving to Tenant such notice of termination, this Lease shall terminate and all interests of Tenant in the Premises shall cease on the date so specified in such notice and Tenant shall pay the rent, as proportionately reduced, based upon the extent, if any, to which such damage interfered with the business carried on by Tenant in the Premises, up to the date of such termination.
c. With regard to Landlord’s duty or option to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage as provided in 11a. and b. above, Landlord shall act promptly and with due diligence, but Landlord shall not be responsible for delays caused by factors beyond Landlord’s control, including but not limited to delays because of strikes, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other authority to act in a timely manner, or delays caused by contractors. If such delays occur, Tenant agrees that Landlord shall not be responsible for damages, nor shall Landlord be deemed to be in default under this Lease.
d. Landlord shall not be required to repair any damage by fire or other casualty, or to make any repair or replacements of any leasehold improvements, fixtures, or other personal property of Tenant.
Condemnation or Casualty Seller agrees to give Purchaser prompt written notice of any fire or other casualty occurring to all or any portion of the improvements at the Real Property and/or Personalty between the date hereof and the date of closing. If prior to the closing, there shall occur:
(i) damage to the improvements at the Property caused by fire or other casualty which would cost 5% of the Purchase Price of the Property or more to repair based on the estimate of a reputable third party contractor chosen by Seller; or
(ii) the taking or condemnation of all or any portion of the Real Property and/or the improvements as aforesaid as would materially interfere with the use thereof; then, if any of such events set forth in (i) or (ii) above occurs, Buyer or Seller, at its option, may terminate its obligations under this Agreement by written notice given to the other within seven (7) days after Buyer has received the notice referred to above or at the closing, whichever is earlier. If Buyer or Seller does not elect to terminate its obligations as aforesaid, the closing shall take place as provided herein without an abatement of the purchase price (except that Buyer shall be allowed a credit for any deductible under Seller's insurance) and there shall be assigned to the Buyer at closing, all interest of the Seller in and to any insurance proceeds or condemnation awards which may be payable to Seller on account of such occurrence. If, prior to the closing, there shall occur:
(i) damage to the Property caused by fire or other casualty which would cost less than 5% of the Purchase Price of the Property based on the estimate of a reputable third party contractor chosen by Seller to which Buyer has no reasonable objection; or
(ii) the taking or condemnation of all or any portion of the said Real Property and/or improvements as aforesaid which is not material to the use, thereof; then, if any of such events set forth in (i) or (ii) above occurs, Buyer shall have no right to terminate its obligations under this Agreement, but there shall be assigned to Buyer at closing all interest of Seller in and to any insurance proceeds or condemnation awards which may be payable to Seller on account of any such occurrence, and in addition, Buyer shall be allowed a credit for any deductible under Seller's insurance policy. Seller shall be responsible for maintaining fire and extended coverage insurance prior to closing as is currently in place.
Total Condemnation If all of the Premises is condemned by eminent domain, inversely condemned or sold under threat of condemnation for any public or quasi-public use or purpose ("Condemned"), this Lease shall terminate as of the earlier of the date the condemning authority takes title to or possession of the Premises, and Rent shall be adjusted to the date of termination.
Partial Condemnation In the event of a Condemnation of less than the whole of any Property such that such Property is still suitable for its Permitted Use, Tenant shall, to the extent of the Award and any additional amounts disbursed by Landlord as hereinafter provided, commence (or cause to be commenced) promptly and continue diligently to restore (or cause to be restored) the untaken portion of the applicable Leased Improvements so that such Leased Improvements shall constitute a complete architectural unit of the same general character and condition (as nearly as may be possible under the circumstances) as such Leased Improvements existing immediately prior to such Condemnation, in material compliance with all Legal Requirements, subject to the provisions of this Section 11.2. If the cost of the repair or restoration of the affected Property exceeds the amount of the Award, Tenant shall give Landlord Notice thereof which notice shall set forth in reasonable detail the nature of such deficiency and whether Tenant shall pay and assume the amount of such deficiency (Tenant having no obligation to do so, except that if Tenant shall elect to make such funds available, the same shall become an irrevocable obligation of Tenant pursuant to this Agreement). In the event Tenant shall elect not to pay and assume the amount of such deficiency, Landlord shall have the right (but not the obligation), exercisable at Landlord’s sole election by Notice to Tenant given within sixty (60) days after Tenant’s Notice of the deficiency, to elect to make available for application to the cost of repair or restoration the amount of such deficiency; provided, however, in such event, upon any disbursement by Landlord thereof, the Minimum Rent shall be adjusted as provided in Section 3.1.1(c). In the event that neither Landlord nor Tenant shall elect to make such deficiency available for restoration, either Landlord or Tenant may terminate this Agreement with respect to the affected Property and the entire Award shall be allocated as set forth in Section 11.5. Subject to the terms hereof, Landlord shall contribute to the cost of restoration that part of the Award necessary to complete such repair or restoration, together with severance and other damages awarded for the taken Leased Improvements and any deficiency Landlord has agreed to disburse, to Tenant regularly during the restoration period so as to permit payment for the cost of such repair or restoration. Landlord may, at its option, condition advancement of such Award and other amounts on (a) the absence of any Event of Default, (b) its approval of plans and specifications of an architect satisfactory to Landlord (which approval shall not be unreasonably withheld, delayed or conditioned), (c) general contractors’ estimates, (iv) architect’s certificates, (d) conditional lien waivers of general contractors, if available, (e) evidence of approval by all governmental authorities and other regulatory bodies whose approval is required, (f), if Tenant has elected to advance deficiency funds pursuant to the preceding paragraph, Tenant depositing the amount thereof with Landlord and (g) such other certificates as Landlord may, from time to time, reasonably require. Landlord’s obligation under this Section 11.2 to disburse the Award and such other amounts shall be subject to (x) the collection thereof by Landlord and (y) the satisfaction of any applicable requirements of any Facility Mortgage, and the release of such Award by the applicable Facility Mortgagee. Tenant’s obligation to restore the Leased Property shall be subject to the release of the Award by the applicable Facility Mortgagee to Landlord.
