Termination If No Default or Erroneous Default Sample Clauses

Termination If No Default or Erroneous Default. If, after a Notice of Termination for Cause is issued by the Town, it is thereafter determined that the Contractor was not in default under the provisions of this Contract, or that any delay hereunder was an Excusable Delay, the termination shall be converted to a Termination for Convenience and the rights and obligations of the parties shall be the same as if the notice of termination had been issued pursuant to the termination for convenience clause contained herein. The Contractor shall have no further recourse of any nature for wrongful termination.
Sample 1
AutoNDA by SimpleDocs
Termination If No Default or Erroneous Default. If, after a Notice of Termination for Cause is issued by the Village, it is thereafter determined that the Design/Builder was not in default under the provisions of this Agreement, or that any delay hereunder was an Excusable Event of Delay, the termination shall be converted to a Termination for Convenience and the rights and obligations of the parties shall be the same as if the notice of termination had been issued pursuant to the termination for convenience clause contained in Section 16.1 . The Design/Builder shall have no further recourse of any nature for wrongful termination.
Sample 1

Related to Termination If No Default or Erroneous Default

  • Erroneous Termination for Default If, after notice of termination of Vendor’s right to proceed under the provisions of this clause, it is determined for any reason that the contract was not in default, or that the delay was excusable under the provisions of the prior paragraph (Excuse for Nonperformance or Delayed Performance), the rights and obligations of the parties shall be the same as if the notice of termination had been one of termination for convenience.

  • Termination of Default An Event of Default shall be deemed to have been terminated upon the earliest to occur of:

  • Termination due to Event of Default (a) Termination due to Parties Event of Default

  • Act or default of agents contractors You agree that we have the discretion to use such agents, contractors or correspondents as we deem fit to carry out or procure any of the matters or transactions governed by or contemplated in this agreement, and save where expressly provided in this agreement we are not liable to you for any act, omission or neglect on the part of such agents, contractors and/ or correspondents.

  • H DEFAULT, DISRUPTION AND TERMINATION H1 Termination on insolvency and change of control H1.1 The Client may terminate the Contract with immediate effect by notice in writing where the Contractor is a company and in respect of the Contractor:

  • Termination for Default The County may, by written notice to the Contractor terminate this contract for default in whole or in part (delivery orders, if applicable) if the Contractor fails to:

  • Compensation for default by the Authority Subject to the provisions of Clause 31.5, in the event of the Authority being in material default or breach of this Agreement at any time after the Appointed Date, it shall pay to the Concessionaire by way of compensation, all direct costs suffered or incurred by the Concessionaire as a consequence of such material default or breach within 30 (thirty) days of receipt of the demand supported by necessary particulars thereof; provided that no such compensation shall be payable for any material breach or default in respect of which Damages have been expressly specified in this Agreement. For the avoidance of doubt, compensation payable may include interest payments on debt, O&M Expenses, any increase in capital costs on account of inflation and all other costs directly attributable to such material breach or default but shall not include loss of Fee revenues, debt repayment obligations or other consequential losses, and for determining such compensation, information contained in the Financial Package and the Financial Model may be relied upon to the extent it is relevant.

  • SUSPENSION & TERMINATION FOR DEFAULT Enterprise Services may suspend Contractor’s operations under this Master Contract immediately by written cure notice of any default. Suspension shall continue until the default is remedied to Enterprise Services’ reasonable satisfaction; Provided, however, that, if after thirty (30) days from such a suspension notice, Contractor remains in default, Enterprise Services may terminate Contractor’s rights under this Master Contract. All of Contractor’s obligations to Enterprise Services and Purchasers survive termination of Contractor’s rights under this Master Contract, until such obligations have been fulfilled.

  • Default Events (a) Any material breach of the Funding Agreement by the Recipient, including those set out below, will be an event of default (“Default Event”):

  • Suspension or Termination Upon Default Either Party may suspend or terminate this Agreement, in whole or in part, in the event of a Default by the other Party so long as the non-Defaulting Party notifies the Defaulting Party in writing of the Default and the Defaulting Party does not cure the Default within thirty (30) Days of receipt of the written notice, provided however, that any requirements for written notice and opportunity to cure with respect to the failure to make timely payment of undisputed charges shall be governed separately under Section 51. Following CenturyLink’s notice to CLEC of its Default, CenturyLink shall not be required to process new Service Orders until the Default is timely cured.

Time is Money Join Law Insider Premium to draft better contracts faster.