Event of Delay definition

Event of Delay means an event or cause beyond the reasonable control of the Landlord or the Tenant, as the case may be, including acts of God, labour or industrial disturbances, civil disturbances, wars, interruptions by Government Body or court orders, transportation disruptions, or shortages of materials.
Sample 1Sample 2Sample 3
Event of Delay means any event the effect of which is to cause a delay to the Depot Works Programme;
Sample 1

Examples of Event of Delay in a sentence

  • Notwithstanding anything to the contrary in the foregoing, the Contractor shall not be entitled to an extension of time unless the event or circumstance giving rise to a delay constitutes an Excusable Event of Delay and the Contractor can demonstrate to the reasonable satisfaction of the Owner that the activity delayed will result in a delay of the Scheduled Completion Date for a building or any other improvements comprising a part of the Work.

  • Neither the Landlord nor the Tenant will be entitled to compensation for any inconvenience, nuisance, or discomfort caused by such an Event of Delay, or to cancel this Lease.

  • If the anticipated delay results from an Excusable Event of Delay under the Agreement, Contractor will be entitled to compensation for costs actually incurred as a direct result of such acceleration.

  • If either the Landlord or the Tenant is unable to provide any service, utility, work, or repair by reason of an Event of Delay, the time for performing the obligation will be extended by that period of time which is equal to the length of the delay, and the Landlord or the Tenant, as the case may be, will use all reasonable efforts to overcome any such Event of Delay.

  • To the extent the delay at issue constitutes an Excusable Event of Delay, in whole or in part, the Special Project Delay Report shall indicate the costs associated with the components of the Recovery Plan related to any Excusable Events of Delay, which costs shall be determined in accordance with Section 46.2 of the General Conditions below (the “Recovery Costs”).

  • Each Special Project Delay Report shall also indicate whether Contractor considers the delay to constitute an Excusable Event of Delay as defined in Section 45.10 below.

  • If a delay or failure to perform obligations is caused by an Event of Delay, the performance of a party's obligations will be suspended.

  • Neither the Landlord nor the Tenant will be entitled to compensation for any inconvenience, nuisance or discomfort caused by such an Event of Delay, or to cancel this Lease.

  • If a party (Affected Party) is unable to perform an obligation under this Agreement due to an Event of Delay for a period exceeding 90 days, the other party may terminate this Agreement immediately by giving written notice to the Affected Party to this effect.

  • If either the Landlord or the Tenant is unable to provide any service, utility, work, or repair by reason of an Event of Delay, the time for performing the obligation will be extended by that period of time which is equal to the length of the delay, and the Landlord or the Tenant, as the case may be, will use all reasonable efforts to overcome any such Event of Delay provided however that nothing herein will relieve the Tenant from its obligation to pay Rent at the times herein provided.

Related to Event of Delay

  • Owner Event of Default has the meaning specified in Section 16.2.

  • Triggering Event of Default means (i) any Event of Default with respect to an obligation of the Mortgage Loan Borrower to pay money due under the Mortgage Loan or (ii) any non-monetary Event of Default as a result of which the Mortgage Loan becomes a Specially Serviced Mortgage Loan (which, for clarification, shall not include any imminent Event of Default (i.e., subclause (vii) of the definition of Special Servicing Loan Event)).

  • Specified Event of Default means any Event of Default under Section 8.01(a), (f) or (g).

  • PTC Event of Default means, with respect to each Trust Agreement, the failure to pay within 10 Business Days after the due date thereof: (i) the outstanding Pool Balance of the applicable Class of Certificates on the Final Legal Distribution Date for such Class or (ii) interest due on such Certificates on any Distribution Date (unless the Subordination Agent shall have made an Interest Drawing or a withdrawal from the Cash Collateral Account relating to a Liquidity Facility for such Class, with respect thereto in an aggregate amount sufficient to pay such interest and shall have distributed such amount to the Trustee entitled thereto).

  • Event of Default wherever used herein, means any one of the following events (whatever the reason for such Event of Default and whether it shall be voluntary or involuntary or be effected by operation of law or pursuant to any judgment, decree or order of any court or any order, rule or regulation of any administrative or governmental body):

  • Material Event of Default means any Event of Default arising under Section 10.01(a), 10.01(b) (solely with respect to a default related to Section 8.01, 8.20 or 9.13), 10.01(f), 10.01(i), 10.01(j), 10.01(n) or 10.01(o).

  • Senior Event of Default means an Event of Default under (and as defined in) the Senior Facilities Agreement.

  • Acceleration Event of Default means an Event of Default under Section 5.1(a), (d), (e) or (f), whatever the reason for such Acceleration Event of Default and whether it shall be voluntary or involuntary or be effected by operation of law or pursuant to any judgment, decree or order of any court or any order, rule or regulation of any administrative or governmental body.

  • Event of Force Majeure means one of the following events:

  • Event shall have the meaning set forth in Section 2(d).

  • Note Event of Default means any “Event of Default” specified in Section 5.1 of the Indenture.

  • Declaration Event of Default means an “Event of Default” as defined in the Declaration.

  • Potential Event of Default means any event which, with the giving of notice or the lapse of time or both, would constitute an Event of Default.

  • Lease Event of Default shall have the meaning specified in Section 17.1 of the Lease.

  • Loan Event of Default An “Event of Default” as defined in the Loan Agreement.

  • Insurance Agreement Event of Default means an "Event of Default" as defined in the Insurance Agreement.

  • Termination Event means an Illegality, a Tax Event or a Tax Event Upon Merger or, if specified to be applicable, a Credit Event Upon Merger or an Additional Termination Event.

  • Issuer Event of Default means the occurrence of any of the following events:

  • Company Event of Default bears the meaning ascribed thereto in Section 13.1; “Company Notice of Default” bears the meaning ascribed thereto in Section 13.2;

  • Liquidity Event of Default with respect to any Liquidity Facility, has the meaning assigned to such term in such Liquidity Facility.

  • Payment Event of Default means an Event of Default specified in Section 7.1(a).

  • Potential Issuer Event of Default means any condition, event or act which, with the lapse of time and/or the issue, making or giving of any notice, certification, declaration, demand, determination and/or request and/or the taking of any similar action and/or the fulfilment of any similar condition, would constitute an Issuer Event of Default;

  • Termination Events means each of the events specified in Clause 10.3 of this Contract.

  • Bond Event of Default means the occurrence of any of the following (or such event or condition which with notice or lapse of time or both would constitute any of the following):

  • Servicer Event of Default wherever used herein, means any one of the following events:

  • Event of dissociation means any of the events listed in Section 8.1 upon which the Member ceases to be a Member.