Termination of the Lease The parties agree that the Management Agreement and the rights and benefits of Manager thereunder shall not be terminated or disturbed in any respect except in accordance with the terms of the Management Agreement, and not as a result of any termination of the Lease. Accordingly, if the Lease is terminated for any reason, including, without limitation, expiration of the term thereof or the "rejection" thereof following Bankruptcy
(a) shall recognize Manager's rights under the Management Agreement, (b) agrees that Manager shall not be named as a party in any eviction or other possessory action or proceeding, and that Manager shall not be disturbed in its right to manage the Inn pursuant to the Management Agreement, and (c) shall at the time of or prior to such Lease Termination either (i) elect not to take either of the actions described in clause (c)(ii) below, in which case all of "Lessee's" rights, benefits, privileges and obligations under the Management Agreement with respect to periods after the Lease Termination shall be assumed directly by Lessor, or (ii) cause an "Approved Lessee" (as defined below) to (x) succeed to and assume Lessee's rights and obligations under the Lease, the Management Agreement, and this Agreement, or (y) enter into a new lease with Lessor in substantially the same form as the Lease, and assume the rights and obligations of the Lessee under the Management Agreement and this Agreement, the intent being that the relationship between any successor Lessee, Lessor and Manager be under the same terms and conditions as the relationship between Lessee, Lessor and Manager hereunder and under the Management Agreement and the Lease. Any successor to Lessee under clause (c)(ii) above shall be subject to Manager's prior written approval, which approval shall not be withheld or delayed if such successor to Lessee is (i) a direct or indirect wholly-owned subsidiary of Lessor, (ii) a person or entity to whom a Sale of the Inn is permitted under Section 10.02.A. of the Management Agreement, or (iii) a person or entity who otherwise is approved by Manager in its sole discretion (an "Approved Lessee").
Termination of the Trust The respective obligations and responsibilities of the Company, the Guarantor and the Trustee with respect to the Trust shall terminate upon the distribution to all Holders of the Certificates and the Trustee of all amounts required to be distributed to them pursuant to this Agreement and the disposition of all property held as part of the Trust Property; PROVIDED, HOWEVER, that in no event shall the Trust continue beyond one hundred ten (110) years following the date of the earliest execution of this Agreement. Notice of any termination, specifying the Regular Distribution Date (or Special Distribution Date, as the case may be) upon which the Certificateholders may surrender their Certificates to the Trustee for payment of the final distribution and cancellation, shall be mailed promptly by the Trustee to Certificateholders not earlier than the 60th day and not later than the 20th day next preceding such final distribution specifying (A) the Regular Distribution Date (or Special Distribution Date, as the case may be) upon which the proposed final payment of the Certificates will be made upon presentation and surrender of Certificates at the office or agency of the Trustee therein specified, (B) the amount of any such proposed final payment, and (C) that the Record Date otherwise applicable to such Regular Distribution Date (or Special Distribution Date, as the case may be) is not applicable, payments being made only upon presentation and surrender of the Certificates at the office or agency of the Trustee therein specified. The Trustee shall give such notice to the Registrar at the time such notice is given to Certificateholders. Upon presentation and surrender of the Certificates, the Trustee shall cause to be distributed to Certificateholders amounts distributable on such Regular Distribution Date (or Special Distribution Date, as the case may be) pursuant to Section 4.02. In the event that all of the Certificateholders shall not surrender their Certificates for cancellation within six months after the date specified in the above-mentioned written notice, the Trustee shall give a second written notice to the remaining Certificateholders to surrender their Certificates for cancellation and receive the final distribution with respect thereto. No additional interest shall accrue on the Certificates after the Regular Distribution Date (or Special Distribution Date, as the case may be). In the event that any money held by the Trustee for the payment of distributions on the Certificates shall remain unclaimed for two years (or such lesser time as the Trustee shall be satisfied, after sixty days' notice from the Company, is one month prior to the escheat period provided under applicable law) after the final distribution date with respect thereto, the Trustee shall pay to each Loan Trustee the appropriate amount of money relating to such Loan Trustee and shall give written notice thereof to the related Owner Trustees and the Company.
Termination of the Agreement In the event of failure by the participant to perform any of the obligations arising from the agreement, and regardless of the consequences provided for under the applicable law, the institution is legally entitled to terminate or cancel the agreement without any further legal formality where no action is taken by the participant within one month of receiving notification by registered letter. If the participant terminates the agreement before its agreement ends or if he/she fails to follow the agreement in accordance with the rules, he/she shall have to refund the amount of the grant already paid, except if agreed differently with the sending organisation. In case of termination by the participant due to "force majeure", i.e. an unforeseeable exceptional situation or event beyond the participant's control and not attributable to error or negligence on his/her part, the participant shall be entitled to receive at least the amount of the grant corresponding to the actual duration of the mobility period. Any remaining funds shall have to be refunded, except if agreed differently with the sending organisation.
Termination Provisions In this Agreement:
Where by reason of the provisions of paragraph 1 an individual is a resident of both Contracting States, then his status shall be determined as follows:
a) he shall be deemed to be a resident only of the State in which he has a permanent home available to him; if he has a permanent home available to him in both States, he shall be deemed to be a resident only of the State with which his personal and economic relations are closer (centre of vital interests);
b) if the State in which he has his centre of vital interests cannot be determined, or if he has not a permanent home available to him in either State, he shall be deemed to be a resident only of the State in which he has an habitual abode;
c) if he has an habitual abode in both States or in neither of them, he shall be deemed to be a resident only of the State of which he is a national;
d) if he is a national of both States or of neither of them, the competent authorities of the Contracting States shall settle the question by mutual agreement.
Termination of the Contract 1. The Contractor may terminate the contract if the Partner has inadequately discharged or failed to discharge any of the contractual obligations, insofar as this is not due to force majeure, after notification of the Partner by registered letter has remained without effect for one month.
2. The Partner shall immediately notify the Contractor, supplying all relevant information, of any event likely to prejudice the performance of this contract.
Term Termination and Survival 9.1 This Agreement shall commence as of the Effective Date and shall continue thereafter until the completion of the Services under all Statements of Work unless sooner terminated pursuant to Section 9.2 or Section 9.3.
9.2 Either Party may terminate this Agreement, effective upon written notice to the other Party (the “Defaulting Party”) if the Defaulting Party:
(a) Materially breaches this Agreement, and such breach is incapable of cure, or with respect to a material breach capable of cure, the Defaulting Party does not cure such breach within 30 days after receipt of written notice of such breach.
(b) Becomes insolvent or admits its inability to pay its debts generally as they become due.
(c) Becomes subject, voluntarily or involuntarily, to any proceeding under any domestic or foreign bankruptcy or insolvency law, which is not fully stayed within seven business days or is not dismissed or vacated within 45 business days after filing.
(d) Is dissolved or liquidated or takes any corporate action for such purpose.
(e) Makes a general assignment for the benefit of creditors.
(f) Has a receiver, trustee, custodian, or similar agent appointed by order of any court of competent jurisdiction to take charge of or sell any material portion of its property or business.
9.3 Notwithstanding anything to the contrary in Section 9.2(a), TAI may terminate this Agreement upon written notice to XXX upon the occurrence of any of the following events (each of the following, a “Specified Event of Default”):
(a) XXX fails to pay any undisputed amount when due hereunder and such failure continues for 30 days after XXX’s receipt of written notice of nonpayment;
(b) XXX fails to timely achieve, complete, or pass any of the XXX Caravan STC Milestone Requirements by the applicable XXX Completion Date (subject to the applicable cure period) as set forth in Exhibit A as determined in the good faith discretion of TAI; provided that, the applicable XXX Completion Dates shall be equitably adjusted to the extent XXX is not able to achieve, complete or pass any XXX Caravan STC Milestone Requirement or such XXX Caravan STC Milestone Requirement is not otherwise met, in each case as a result of (a) the material breach of TAI of its obligations hereunder or (b) the occurrence of a Force Majeure Event, with an extension to the corresponding XXX Completion Date commensurate with the delay caused by such TAI breach or Force Majeure Event, provided, however, that no extension related to a Force Majeure Event shall be longer than 45 days;
(c) the occurrence of a “Change of Control”, which means (i) the acquisition by any Person of ownership or power to vote more than 49% of the voting stock of XXX by means of any transaction or series of related transactions (including any reorganization, merger or consolidation, but excluding any business combination with a SPAC by XXX or its Affiliate completed prior to the one (1) year anniversary of the date hereof), (ii) the acquisition of ownership or power to vote more than 10% of the voting stock of XXX by a TAI competitor, (iii) a sale of all or substantially all of the assets of XXX, (iv) a material change of XXX’s senior leadership occurring prior to the five (5) year anniversary of the date hereof, in each case of the foregoing clauses (i) – (iv), directly or indirectly, including as to any successor of XXX;
Termination of the Option The Option shall terminate and may no longer be exercised after the first to occur of (a) the close of business on the Option Expiration Date, (b) the close of business on the last date for exercising the Option following termination of the Participant’s Service as described in Section 7, or (c) a Change in Control to the extent provided in Section 8.
EFFECT OF OPTIONAL TERMINATION Upon the exercise of the option to terminate pursuant to Section 7.2, this Agreement shall terminate and be of no further force or effect; provided, however, that:
A. the Parties respective rights and obligations under this Agreement with respect to the Tax Year or Tax Years (as the case may be) through and including the Tax Year during which such notification is delivered to the District, shall not be impaired or modified as a result of such termination and shall survive such termination unless and until satisfied and discharged; and
B. the provisions of this Agreement regarding payments (including liquidated damages and tax payments), records and dispute resolution shall survive the termination or expiration of this Agreement.
