Termination Rights Liquidated Damages
Termination Rights Liquidated Damages Sample Clauses
Related to Termination Rights Liquidated Damages
Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Termination Rights This Agreement may be terminated at any time prior to the Closing:
Termination Right The Representative shall have the right to terminate this Agreement at any time prior to any Closing Date, (i) if any domestic or international event or act or occurrence has materially disrupted, or in its opinion will in the immediate future materially disrupt, general securities markets in the United States; or (ii) if trading on any Trading Market shall have been suspended or materially limited, or minimum or maximum prices for trading shall have been fixed, or maximum ranges for prices for securities shall have been required by FINRA or by order of the Commission or any other government authority having jurisdiction, or (iii) if the United States shall have become involved in a new war or an increase in major hostilities, or (iv) if a banking moratorium has been declared by a New York State or federal authority, or (v) if a moratorium on foreign exchange trading has been declared which materially adversely impacts the United States securities markets, or (vi) if the Company shall have sustained a material loss by fire, flood, accident, hurricane, earthquake, theft, sabotage or other calamity or malicious act which, whether or not such loss shall have been insured, will, in the Representative’s opinion, make it inadvisable to proceed with the delivery of the Securities, or (vii) if the Company is in material breach of any of its representations, warranties or covenants hereunder, or (viii) if the Representative shall have become aware after the date hereof of such a material adverse change in the conditions or prospects of the Company, or such adverse material change in general market conditions as in the Representative’s judgment would make it impracticable to proceed with the offering, sale and/or delivery of the Securities or to enforce contracts made by the Underwriters for the sale of the Securities.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Additional Termination Rights In addition to any right to terminate this Agreement under the provisions of this Section 16, either party shall have the further right to terminate this Agreement, upon delivery of written notice to the Agent, upon the occurrence of any of the following:
Buyer’s Termination Right If, prior to Closing and the delivery of possession of the Property to Buyer in accordance with this Contract, (a) any condemnation proceeding shall be pending against a substantial portion of the Hotel or (b) there is any substantial casualty loss or damage to the Hotel, Buyer shall have the option to terminate this Contract, provided Buyer delivers written notice to Seller of its election within twenty (20) days after the date Seller has delivered Buyer written notice of any such loss, damage or condemnation as provided above, and in such event, the Xxxxxxx Money Deposit, and any interest thereon, shall be delivered to Buyer and thereafter, except as expressly set forth herein, no party shall have any further obligation or liability to the other under this Contract. In the context of condemnation, “substantial” shall mean condemnation of such portion of a Hotel (or access thereto) as could, in Buyer’s reasonable judgment, render use of the remainder impractical or unfeasible for the uses herein contemplated, and, in the context of casualty loss or damage, “substantial” shall mean a loss or damage in excess of One Hundred Thousand and No/100 Dollars ($100,000.00) in value.
Early Termination Right Tenant shall have the right, subject to the provisions of this Section 39, to terminate this Lease (“Termination Right”) with respect to the entire Premises only as of July 31, 2021 (“Early Termination Date”), so long as Tenant delivers to Landlord (i) a written notice (“Termination Notice”), of its election to exercise its Termination Right no less than 12 months in advance of the Early Termination Date, and (ii) concurrent with Tenant’s delivery of the Termination Notice to Landlord, an early termination payment equal to the sum of (1) the unamortized amount of the Tenant Improvement Allowance actually disbursed by Landlord as of the Early Termination Date with amortization calculated on a straight line basis from the Commencement Date through the Base Term, (2) all of the unamortized leasing commissions paid by Landlord in connection with this Lease as of the Early Termination Date, with amortization calculated on a straight line basis from the Commencement Date through the Base Term, (3) the unamortized amount as of the Early Termination Date of the Additional Tenant Improvement Allowance actually disbursed by Landlord to Tenant, if any, with amortization calculated on a straight line basis from the Commencement Date through the Base Term, (4) the unamortized amount of the Base Rent that would have been payable during the Abatement Period had such amounts not been abated, with amortization calculated on a straight line basis from the Commencement Date through the Base Term, and (5) an amount equal to 4 months of Base Rent that would have been payable for the 4 months immediately following the Early Termination Date (collectively, the “Early Termination Payment”). If Tenant timely and properly exercises the Termination Right, Tenant shall vacate the Premises and deliver possession thereof to Landlord in the condition required by the terms of this Lease on or before the Early Termination Date and Tenant shall have no further obligations under this Lease except for those accruing prior to the Early Termination Date and those which, pursuant to the terms of this Lease, survive the expiration or early termination of this Lease. If Tenant does not deliver to Landlord the Termination Notice and the Early Termination Payment within the time period provided in this paragraph, Tenant shall be deemed to have waived its Termination Right and the provisions of this Section 39 shall have no further force or effect.
Termination; Rights on Termination Employee's employment may be ---------------------------------- terminated in any one of the followings ways, prior to the expiration of the Term:
