Termination Due to Failure to Satisfy Performance Test
Termination Due to Failure to Satisfy Performance Test Sample Clauses
Related to Termination Due to Failure to Satisfy Performance Test
Failure to Satisfy Conditions If the Secured Party or its Custodian fails to satisfy any conditions for holding Posted Collateral, then upon a demand made by the Pledgor, the Secured Party will, not later than five Local Business Days after the demand, Transfer or cause its Custodian to Transfer all Posted Collateral held by it to a Custodian that satisfies those conditions or to the Secured Party if it satisfies those conditions.
Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Lenders’ Failure to Perform All Advances (other than Swing Loans and Agent Advances) shall be made by the Lenders contemporaneously and in accordance with their Pro Rata Shares. It is understood that (i) no Lender shall be responsible for any failure by any other Lender to perform its obligation to make any Advance (or other extension of credit) hereunder, nor shall any Commitment of any Lender be increased or decreased as a result of any failure by any other Lender to perform its obligations hereunder, and (ii) no failure by any Lender to perform its obligations hereunder shall excuse any other Lender from its obligations hereunder.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Covenants of Performance Measurement No interference. Registry Operator shall not interfere with measurement Probes, including any form of preferential treatment of the requests for the monitored services. Registry Operator shall respond to the measurement tests described in this Specification as it would to any other request from an Internet user (for DNS and RDDS) or registrar (for EPP). ICANN testing registrar. Registry Operator agrees that ICANN will have a testing registrar used for purposes of measuring the SLRs described above. Registry Operator agrees to not provide any differentiated treatment for the testing registrar other than no billing of the transactions. ICANN shall not use the registrar for registering domain names (or other registry objects) for itself or others, except for the purposes of verifying contractual compliance with the conditions described in this Agreement. PUBLIC INTEREST COMMITMENTS Registry Operator will use only ICANN accredited registrars that are party to the Registrar Accreditation Agreement approved by the ICANN Board of Directors on 27 June 2013 in registering domain names. A list of such registrars shall be maintained by ICANN on ICANN’s website. (Intentionally omitted. Registry Operator has not included commitments, statements of intent or business plans provided for in its application to ICANN for the TLD.) Registry Operator agrees to perform the following specific public interest commitments, which commitments shall be enforceable by ICANN and through the Public Interest Commitment Dispute Resolution Process established by ICANN (posted at xxxx://xxx.xxxxx.xxx/en/resources/registries/picdrp), which may be revised in immaterial respects by ICANN from time to time (the “PICDRP”). Registry Operator shall comply with the PICDRP. Registry Operator agrees to implement and adhere to any remedies ICANN imposes (which may include any reasonable remedy, including for the avoidance of doubt, the termination of the Registry Agreement pursuant to Section 4.3(e) of the Agreement) following a determination by any PICDRP panel and to be bound by any such determination. Registry Operator will include a provision in its Registry-Registrar Agreement that requires Registrars to include in their Registration Agreements a provision prohibiting Registered Name Holders from distributing malware, abusively operating botnets, phishing, piracy, trademark or copyright infringement, fraudulent or deceptive practices, counterfeiting or otherwise engaging in activity contrary to applicable law, and providing (consistent with applicable law and any related procedures) consequences for such activities including suspension of the domain name. Registry Operator will periodically conduct a technical analysis to assess whether domains in the TLD are being used to perpetrate security threats, such as pharming, phishing, malware, and botnets. Registry Operator will maintain statistical reports on the number of security threats identified and the actions taken as a result of the periodic security checks. Registry Operator will maintain these reports for the term of the Agreement unless a shorter period is required by law or approved by ICANN, and will provide them to ICANN upon request. Registry Operator will operate the TLD in a transparent manner consistent with general principles of openness and non-discrimination by establishing, publishing and adhering to clear registration policies.
Performance Delay Time is of the essence in the Vendor’s performance of this Agreement. If at any time it appears to Vendor that it may not meet any of the performance schedules or the scheduled completion date of the services to be performed for any reason, including labor disputes, Vendor shall immediately by verbal means (to be confirmed in writing) notify Customer of the reasons for and the estimated duration of such delay. If requested by Customer, Vendor shall make every effort to avoid or minimize the delay to the maximum extent possible including the expenditure of premium time. Any additional cost caused by these requirements of Customer shall be borne by Vendor, unless the delay in performance arises out of causes beyond the control and without the fault or negligence of Vendor or its subcontractors within the meaning of the Cancellation- Default clause herein. The foregoing requirements are in addition to any of Customer’s other rights and remedies as may be provided by law or this Agreement.
Termination for Failure to Pay If Company fails to make any payment due hereunder, Hospital shall have the right to terminate this Agreement upon ten (10) business days written notice, unless Company makes such payments plus any interest due, as set forth in Section 4.7, within said ten (10) day notice period. If payments are not made, Hospital may immediately terminate this Agreement at the end of said ten (10) day period. Company shall be entitled to only one such cure period in a calendar year; for a second failure to make payment on time, Hospital shall have the right to terminate this Agreement immediately upon written notice.
Continuing Performance (a) The obligations under this Agreement continue until satisfied in full and do not merge with any action performed or document executed by any Party for the purposes of performance of this Agreement. (b) Any representation in this Agreement survives the execution of any document for the purposes of, and continues after, performance of this Agreement. (c) Any indemnity given by any Party under this Agreement: (i) constitutes a liability of that Party separate and independent from any other liability of that Party under this Agreement or any other agreement; and (ii) survives and continues after performance of this Agreement.
Ongoing Performance Measures The Department intends to use performance-reporting tools in order to measure the performance of Contractor(s). These tools will include the Contractor Performance Survey (Exhibit H), to be completed by Customers on a quarterly basis. Such measures will allow the Department to better track Vendor performance through the term of the Contract(s) and ensure that Contractor(s) consistently provide quality services to the State and its Customers. The Department reserves the right to modify the Contractor Performance Survey document and introduce additional performance-reporting tools as they are developed, including online tools (e.g. tools within MFMP or on the Department's website).
