Common use of Termination, Suspension and/or Delay of Work Clause in Contracts

Termination, Suspension and/or Delay of Work. It is understood and agreed that the City, at its sole option, may change, terminate, delay and/or suspend any and all portions of the covered work at any time. Further, the City may prohibit some or all work on certain days or during certain hours of the day to comply with applicable codes, laws or regulations, permits or to accommodate the ongoing operations of the City’s facilities and/or to mitigate the effect of the ongoing Projects’ work on the businesses and residents in the neighborhood of the Project sites; and/or require such other operational or schedule changes that may be deemed necessary, in its sole judgment, to effectively maintain the primary purpose of the City’s facilities and to remain a good neighbor to the residents and businesses in the area of any Projects. In order to permit the Contractors and Unions to make appropriate scheduling plans, the City will provide the affected Contractor and Union(s) with reasonable notice of any changes it requires pursuant to this Section.

Termination, Suspension and/or Delay of Work. It is understood and agreed that the City, at its sole option, may change, terminate, delay and/or suspend any and all portions of the covered work at any time. Further, the City may prohibit some or all work on certain days or during certain hours of the day to comply with applicable codes, laws or regulations, permits or to accommodate the ongoing operations of the City’s facilities and/or to mitigate the effect of the ongoing Projects’ work on the businesses and residents in the neighborhood of the Project sites; and/or require such other operational or schedule changes that it may be deemed necessary, in its sole judgment, to effectively maintain the primary purpose of the City’s facilities and to remain a good neighbor to the residents and businesses in the area of any Projects. In order to permit the Contractors and Unions to make appropriate scheduling plans, the City will provide the affected Contractor and Union(s) with reasonable notice of any changes it requires pursuant to this Section.