Terms of Purchase The closing of the transactions contemplated by Section 10.6 (the "Purchase Closing") shall occur (a) on the Termination Date if this Agreement expires pursuant to the terms of Sections 10.1 and 10.2, or (b) on a date mutually acceptable to the parties hereto that shall be within 180 days after receipt of a Termination Notice. The parties shall enter into an asset purchase agreement containing representations, warranties and conditions customary to a transaction of this size involving the purchase and sale of similar businesses. Subject to the conditions set forth below, at the Purchase Closing, Administrator and/or its Affiliates, as the case may be, shall transfer and assign the Purchase Assets to the Group, and in consideration therefor, the Group shall (a) pay to Administrator, Parent and/or their Affiliates an amount in cash or, at the option of the Group (subject to the conditions set forth below), Parent Common Stock (valued pursuant to Section 10.6(c) hereof), or some combination of cash and Parent Common Stock equal to the Purchase Price and (b) assume the Practice Related Liabilities. The structure of the transaction set forth in this Section 10.7 shall, if possible, be structured as a tax-free transaction under applicable law. Each party shall execute such documents or instruments as are reasonably necessary, in the opinion of each party and its counsel, to effect the foregoing transaction. The Group shall, and shall use its best efforts to cause each shareholder of the Group to, execute such documents or instruments as may be necessary to cause the Group to assume the Practice Related Liabilities and to release Administrator, Parent and/or their Affiliates, as the case may be, from any liability or obligation with respect thereto. In the event the Group desires to pay all or a portion of the Purchase Price in shares of Parent Common Stock, such transaction shall be subject to the satisfaction of each of the following conditions:
43 49 (a) The holders of such shares of Parent Common Stock shall transfer to Administrator, Parent and/or their Affiliates good, valid and marketable title to the shares of Parent Common Stock, free and clear of all adverse claims, security interests, liens, claims, proxies, options, stockholders' agreements and encumbrances (not including any applicable securities restrictions and lock-up arrangements with the Parent or any underwriter); and
Conditions of Purchase Purchaser's obligation to purchase and pay for Eligible Loans in a Portfolio hereunder shall be subject to the following conditions precedent:
(a) the Eligible Loans in the Portfolio, aggregated with the other Eligible Loans that have been sold to Purchaser by Seller if appropriate, shall meet the requirements described in Section 3.1 hereof;
(b) all representations, warranties and statements by or on behalf of Seller contained in this Agreement are true on the Scheduled Sale Date;
(c) any notification to or approval by the Secretary or Guarantee Agency required by the Higher Education Act or the Guarantee Agreement as a condition to the assignment of Eligible Loans shall have been made or received and evidence thereof delivered to both Purchaser and the Trustee;
(d) the entire interest of Seller in each Eligible Loan shall have been duly assigned by endorsement, such endorsement to be without recourse except as provided in Article V hereof;
(e) the Seller shall, at its own expense, indicate in its files that the Student Loans sold on such date have been sold to the Purchaser pursuant to this Agreement and pledged and assigned by the Purchaser to the Trustee for the benefit of the Registered Owners, and the Seller shall deliver to the Purchaser a Schedule of Student Loans certified by the Chairman, the President, the Vice President or the Treasurer of the Seller to be true, correct and complete as of the date thereof. Further, the Seller hereby agrees that the computer files maintained by the Seller as Servicer will bear an indication reflecting that the Student Loans sold to the Purchaser pursuant to this Agreement are owned by the Purchaser; and
(f) prior to or on each Scheduled Sale Date, the Seller shall record and file, at its own expense, appropriate UCC-3 termination statements with respect to any previous liens on such Student Loans being sold and purchased hereunder.
Terms of Plan This Agreement is entered into pursuant to the Plan (a copy of which has been delivered to the Grantee). This Agreement is subject to all of the terms and provisions of the Plan, which are incorporated into this Agreement by reference, and the actions taken by the Committee pursuant to the Plan. In the event of a conflict between this Agreement and the Plan, the provisions of the Plan shall govern. All determinations by the Committee shall be in its sole discretion and shall be binding on the Company and the Grantee.
Conditions of Purchases SECTION 3.01.
Terms of Purchase and Sale a. For residential customers, the RFG capacity may not exceed twenty (20) kilowatts alternating current, and for non-residential customers, the RFG capacity may not exceed one (1) megawatt alternating current. The total connected capacity of all generators shall not exceed 1.0% of the Cooperative’s Virginia peak-load forecast for the previous year.
b. For general purposes, the Customer’s tariff shall be that tariff under which Customer would be served if Customer were not a net energy metering customer (the Customer’s standard tariff). Time-of-use net metering is not permitted under an electricity supply service tariff having no demand charges.
c. Over the Billing Period, electricity generated by Customer’s RFG shall be metered and shall be netted against the electricity supplied to Customer by Cooperative. Customer shall receive a Billing Period Credit in any Billing Period in which the quantity of electricity generated and fed back into the electric grid by Customer’s RFG exceeds the electricity supplied to Customer for the Billing Period.
d. For any Billing Period in which generation exceeds consumption, producing a Billing Period Credit, the monthly charge shall be based only on the fixed charges of Customer’s standard tariff. Customer must pay only the nonusage sensitive charges for any Billing Period in which a Billing Period Credit exists. If Customer is under a time-of-use tariff with net metering, Excess Generation is determined separately for each time-of-use tier. Customer must pay only the demand charges and the nonusage sensitive charges in any Billing Period when there are credits in all tiers for that Billing Period.
e. Billing Period Credits will be carried forward and applied to offset future consumption charges within the Net Metering Period. Billing Period Credits shall be accumulated, carried forward, and applied at the first opportunity to any Billing Periods having positive net consumptions (by tiers, in the case of time-of-use customers).
f. Customer shall be solely responsible for complying with any and all other requirements of federal, state, or local law or regulation regarding the operation or maintenance of its RFG. Cooperative shall not be responsible for any additional costs related to ensuring the RFG’s compliance with any legal or regulatory requirements.
Definitions of Key Terms Relating to Additional Rent As used in this Article 4, the following terms shall have the meanings hereinafter set forth:
Prices and Terms of Payment (a) In consideration of the sale of Products and/or the performance of Services by Signify, Customer shall pay all prices and fees (“Prices”) in accordance with the Agreement and this section 2. Prices are in euro and unless agreed otherwise based on Ex Works – Signify facility (INCOTERMS latest version). Unless stipulated otherwise by the applicable INCOTERMS, Prices do not include any taxes, duties or other governmental fees, now or hereafter enacted, including value-added or similar taxes levied by any government, and Signify may add these to the Price or invoice separately, and Customer will reimburse Signify promptly on first request.
(b) Subject to notice to Customer, Signify reserves the right to adjust Prices for Products and/or Services not yet delivered or performed to reflect variations in individual costs of more than five percent (5%) including any foreign exchange rate fluctuations, raw materials and other costs of manufacturing and distribution, and labor costs, that take effect between the date of the Agreement and delivery of Products and/or performance of Services. In addition, if an Agreement has a term longer than twelve (12) months, Signify may adjust Prices as of each 1st April (i) for the change in the most recently published producer price index (PPI) compared to twelve (12) months earlier; and (ii) to reflect variations in the foreign exchange rate between the foreign currency and the Euro currency of more than 5% since the date of an Offer.
(c) Any cancellation, delay or other change by Customer of a purchase order previously accepted by Signify will require the prior approval of Signify and the approval will be without prejudice to any rights or remedies Signify may have under the Agreement or at law. If, on request of Customer, Signify agrees to any such change in purchase order or a change in an Agreement, including an (partial) cancellation, delay or suspension, the addition, omission, alteration, substitution or modification of the design, quality, standard, quantity, manufacturing site or performance (including sequence, quantities or timing) of Products and/or Services (each, a “Variation”), or a Variation is required due to (i) changes in applicable laws, regulations or industry standards, (ii) emergency situations, (iii) incorrect or incomplete information provided by Customer, or (iv) non-compliance by Customer of any of its obligations under an Agreement, Customer shall reimburse Signify for all costs and expenses incurred in respect of such Variation promptly on first request.
(d) Signify may invoice Customer upon shipment of Products, or when Services have been performed. Signify may require (i) Customer to pay on fixed payment days; (ii) an advance payment of (part of) the Price; and/or (iii) invoice per separate specified phase, time period or milestone of performance. Customer shall make net payment within thirty (30) days of date of invoice to the designated bank account of Signify. Customer shall pay all amounts due to Signify in full without any set-off, counterclaim, deduction or (tax) withholding.
(e) In the event Customer fails to make any payment due under an Agreement on the due date, then, whether or not Signify has made a formal demand for payment and in addition to any other rights and remedies available to Signify, to the extent permitted by applicable law: (i) all amounts due from Customer will be considered payable and non-disputed, admitted debt; (ii) Customer shall pay Signify interest on all due amounts from the due date until Signify has received full payment thereof, at the rate of eighteen percent (18%) per annum or the applicable statutory rate, whichever is higher, and shall pay Signify all costs of payment collection, including attorneys’ fees; and (iii) Signify may cancel any credit issued to Customer and require, to its satisfaction, that Customer provides (additional) security, pre-payments or deposits, and may implement additional conditional payment terms or accelerate payments schedules for any outstanding performance.
(f) Signify may set off against and deduct from any amount that Signify (or any of its affiliates) owes to Customer under any agreement any amount that Customer owes to Signify or against any advance payments or deposits made by Customer. In the event that Signify sets off amounts in different currency it will use a commonly used currency conversion rate.
Terms of Public Offering The Company is advised by you that the Underwriters propose to make a public offering of their respective portions of the Shares as soon after the Registration Statement and this Agreement have become effective as in your judgment is advisable. The Company is further advised by you that the Shares are to be offered to the public initially at $_____________ a share (the "PUBLIC OFFERING PRICE") and to certain dealers selected by you at a price that represents a concession not in excess of $______ a share under the Public Offering Price, and that any Underwriter may allow, and such dealers may reallow, a concession, not in excess of $_____ a share, to any Underwriter or to certain other dealers.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Price and Terms of Payment To be valid, Supplier's invoices must contain Twitter's Order number and part number, the manufacturer's part number, a full description of the Deliverables, the quantity, unit price and total price, and the delivery address, as applicable. Valid Supplier invoices will become due for payment by Twitter, net thirty (30) days from Twitter's receipt of the Deliverables or the date of receipt of a correct invoice (whichever is later) unless otherwise indicated on the face of the Order. The date of invoice will not predate the date of delivery of the relevant Deliverables. Supplier will send invoices to Twitter's address designated on the face of the Order or to such other address as Twitter may specify in writing. Notwithstanding anything to the contrary contained in the Agreement, (a) Invoices submitted more than six (6) months after Twitter’s receipt of Deliverables will be rejected and no payment shall be made and (b) Twitter shall have no liability whatsoever under the Agreement for amounts due under any such invoice. Currency shall be in United States dollars unless otherwise identified on the face of the Order.
