Maintenance Period During the Maintenance Period the Developer shall at its own expense maintain repair and otherwise keep the Works in good working order and repair to the reasonable satisfaction of xxx Xxxxxxxxxx unless xxx Xxxxxxxxxx shall declare that any required maintenance and/or repair is an emergency in which case the Developer shall carry out the said maintenance and/or repair immediately
INTERIM MAINTENANCE PERIOD During the interim maintenance period between obtaining of the completion certificate of such Project and formation and operationalization of the Association the Promoter shall through itself or through a facility management company to run, operate, manage and maintain the Common Areas. The Promoter shall endeavour that the committee responsible for the maintenance and operation of the Common Areas will be required to provide manpower for maintaining the Common Areas, wherever required, and to collect maintenance charges and also guest charges and the user charges for the utilities being provided on “pay by use” basis, if any. The maintenance and management of Common Areas by the committee will primarily include but not limited to maintenance of water works, common electrical installations, DG Sets, landscaping, driveways, parking areas, lobbies, lifts and staircases, AMC’s etc. It will also include safety and security of the Project such as fire detection and protection and management of general security control of the Project. The Rules/ Bye Laws to regulate the use and maintenance of the Common Areas shall during the interim maintenance period shall be framed by the Promoter with such restrictions as may be necessary for proper maintenance and all the Allottees are bound to follow the same. After the Common Areas of the Project are handed over to the Association, the Association may adopt the Rules and the Bye laws framed by the Promoter, with or without amendments, as may be deemed necessary by the Association.
Monthly MWBE Contractor Compliance Report A. In accordance with 5 NYCRR § 142.10, Contractor is required to report Monthly MWBE Contractor Compliance to OGS during the term of the Contract for the preceding month’s activity, documenting progress made towards achievement of the Contract MWBE goals. OGS requests that all Contractors use the New York State Contract System (“NYSCS”) to report subcontractor and supplier payments made by Contractor to MWBEs performing work under the Contract. The NYSCS may be accessed at xxxxx://xx.xxxxxxxxxxxxxx.xxx/. This is a New York State- based system that all State agencies and authorities will be implementing to ensure uniform contract compliance reporting throughout New York State. B. When a Contractor receives a payment from a State agency, it is the Contractor’s responsibility to pay its subcontractors and suppliers in a timely manner. On or after the first day of each month, the Contractor will receive an email or fax notification (“audit notice”) indicating that a representative of its company needs to log-in to the NYSCS to report the company’s MWBE subcontractor and supplier payments for the preceding month. The Contractor must also report when no payments have been made to a subcontractor or supplier in a particular month with entry of a zero dollar value in the NYSCS. Once subcontractor and supplier payments have been entered into the NYSCS, the subcontractor(s) and supplier(s) will receive an email or fax notification advising them to log into the NYSCS to confirm that they actually received the reported payments from the Contractor. It is the Contractor’s responsibility to educate its MWBE subcontractors and suppliers about the NYSCS and the need to confirm payments made to them in the NYSCS. C. To assist in the use of the NYSCS, OGS recommends that all Contractors and MWBE subcontractors and suppliers sign up for the following two webinar trainings offered through the NYSCS: “Introduction to the System – Vendor training” and “Contract Compliance Reporting - Vendor Training” to become familiar with the NYSCS. To view the training schedule and to register visit: xxxxx://xx.xxxxxxxxxxxxxx.xxx/events.asp D. As soon as possible after the Contract is approved, Contractor should visit xxxxx://xx.xxxxxxxxxxxxxx.xxx and click on “Account Lookup” to identify the Contractor’s account by company name. Contact information should be reviewed and updated if necessary by choosing “Change Info.” It is important that the staff member who is responsible for reporting payment information for the Contractor be listed as a user in the NYSCS. Users who are not already listed may be added through “Request New User.” When identifying the person responsible, please add “- MWBE Contact” after his or her last name (i.e., Xxxx Xxx – MWBE Contact) to ensure that the correct person receives audit notices from the NYSCS. NYSCS Technical Support should be contacted for any technical support questions by clicking on the links for “Contact Us & Support” then “Technical Support” on the NYSCS website. E. If Contractor is unable to report MWBE Contractor Compliance via the NYSCS, Contractor must submit a Monthly MWBE Contractor Compliance Report on Form MWBE 102 to OGS, by the 10th day of each month during the term of the Contract, for the preceding month’s activity to: OGS MWBE Office, 00xx Xxxxx Xxxxxxx Xxxxx, Xxxxxx Xxxxx Xxxxx, Xxxxxx, XX 00000. Phone: 000-000-0000; Fax: 000-000-0000. F. It is the Contractor’s responsibility to report subcontractor and supplier payments. Failure to respond to payment audits in a timely fashion through the NYSCS, or by paper to OGS, may jeopardize future payments pursuant to the MWBE liquidated damages provisions in clause IX below.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Authorization Required Prior to Parallel Operation 2.2.1 The NYISO, in consultation with the Connecting Transmission Owner, shall use Reasonable Efforts to list applicable parallel Operating Requirements in Attachment 5 of this Agreement. Additionally, the NYISO, in consultation with the Connecting Transmission Owner, shall notify the Interconnection Customer of any changes to these requirements as soon as they are known. The NYISO and Connecting Transmission Owner shall make Reasonable Efforts to cooperate with the Interconnection Customer in meeting requirements necessary for the Interconnection Customer to commence parallel operations by the in-service date. 2.2.2 The Interconnection Customer shall not operate its Small Generating Facility in parallel with the New York State Transmission System or the Distribution System without prior written authorization of the NYISO. The NYISO, in consultation with the Connecting Transmission Owner, will provide such authorization once the NYISO receives notification that the Interconnection Customer has complied with all applicable parallel Operating Requirements. Such authorization shall not be unreasonably withheld, conditioned, or delayed.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract. a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract. b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
QUANTITY CHANGES PRIOR TO AWARD The Commissioner reserves the right, at any time prior to the award of a specific quantity Contract, to alter in good faith the quantities listed in the Bid Specifications. In the event such right is exercised, the lowest responsible Bidder meeting Bid Specifications will be advised of the revised quantities and afforded an opportunity to extend or reduce its Bid price in relation to the changed quantities. Refusal by the low Bidder to so extend or reduce its Bid price may result in the rejection of its Bid and the award of such Contract to the lowest responsible Bidder who accepts the revised qualifications.
Maintenance, Etc The Company will maintain, preserve and keep, and will cause each Consolidated Subsidiary to maintain, preserve and keep, its properties which are used in the conduct of its business (whether owned in fee or a leasehold interest) in good repair and working order, ordinary wear and tear excepted, and from time to time will make all necessary repairs, replacements and renewals as the Company may determine to be appropriate to the conduct of its business.
Amendments - Changes/Extra Work The Subrecipient shall make no changes to this Contract without the County’s written consent. In the event that there are new or unforeseen requirements, the County has the discretion with the Subrecipient’s concurrence, to make changes at any time without changing the scope or price of the Contract. If County-initiated changes or changes in laws or government regulations affect price, the Subrecipient’s ability to deliver services, or the project schedule, the Subrecipient will give County written notice no later ten (10) days from the date the law or regulation went into effect or the date the change was proposed and Subrecipient was notified of the change. Such changes shall be agreed to in writing and incorporated into a Contract amendment. Said amendment shall be issued by the County-assigned Contract Administrator, shall require the mutual consent of all Parties, and may be subject to approval by the County Board of Supervisors. Nothing herein shall prohibit the Subrecipient from proceeding with the work as originally set forth or as previously amended in this Contract.
