Our Liability to You 8.1 We will not be liable to You in respect of any losses You or the Card User may suffer in connection with or arising from the Card, except where such losses are due to a breach by us of this Agreement or due to Our negligence. In addition, We will not be liable for disputes concerning the quality of goods or services purchased from any merchant that accepted a Card or for any additional fees charged by the operator of POS or ATM terminals (e.g. when You are offered dynamic currency conversion at a point of sale). In particular, We will not be liable for any loss due to: (i) any failure due to events outside Our reasonable control; (ii) any system failure or industrial dispute outside Our control; (iii) any ATM or retailer refusing to or being unable to accept the Card;
Your liability to us (alleged) illegal use, etc
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Warranty of Ability to Perform The Contractor warrants that, to the best of its knowledge, there is no pending or threatened action, proceeding, or investigation, or any other legal or financial condition, that would in any way prohibit, restrain, or diminish the Contractor’s ability to satisfy its Contract obligations. The Contractor warrants that neither it nor any affiliate is currently on the convicted vendor list maintained pursuant to section 287.133 of the Florida Statutes, or on any similar list maintained by any other state or the federal government. The Contractor shall immediately notify the Customer in writing if its ability to perform is compromised in any manner during the term of the Contract.
WARRANTY OF CONTRACTOR’S ABILITY TO PERFORM The Contractor warrants that, to the best of its knowledge, there is no pending or threatened action, proceeding, or investigation, or any other legal or financial condition, that would in any way prohibit, restrain, or diminish the Contractor’s ability to satisfy its Contract obligations. The Contractor warrants that neither it nor any affiliate is currently on the Suspended Vendor List, Convicted Vendor List, or the Discriminatory Vendor List, or on any similar list maintained by any other state or the federal government. The Contractor shall immediately notify the Department in writing if its ability to perform is compromised in any manner during the term of the Contract. Information Technology Staff Augmentation Services Contract No. 80101507-21-STC-ITSA Contract Exhibit F Resume Self-Certification Form Contractor’s candidates shall complete this Resume Self-Certification Form. Completed Resume Self-Certification Forms shall be submitted within the Contractor’s response to Customer’s requests for quote. “I the undersigned do hereby certify, under the penalty of perjury, that information in my resume submitted for consideration of the State of Florida contract position is true, correct, complete, and made in good faith to the best of my knowledge and belief. If an omission, falsification, misstatement, or misrepresentation has been made regarding my education, work ability, experience, employment history, and/or fitness for employment as a contractor, I may be disqualified as a contractor, and the matter will be reported to appropriate agency or law enforcement personnel. I understand that there may be civil and/or criminal penalties for misrepresenting pertinent information in connection with contract positions, including, but not limited to, penalties available under sections 287.133 or 817.566, Florida Statutes. I further understand that if I am not a United States citizen, violation cases may be reported to the US Department of Homeland Security for potential deportation.” “In addition, I the undersigned do hereby consent to the release of my information by employers, educational institutions, law enforcement agencies, and other individuals and organizations to investigators and other authorized agents of Florida for verification and investigation purposes. I understand that any documents submitted to procure a contract(s) with the State of Florida, including resumes, are public records.” Print Full Legal Name of Candidate Candidate’s Signature Date Candidate’s Form of Identification Presented Identification number Contractor’s Witness Signature One Date Contractor’s Witness Signature Two Date Print Name Contractor’s Witness One Print Name Contractor’s Witness Two Information Technology Staff Augmentation Services Contract No. 80101507-21-STC-ITSA Contract Exhibit G Contractor Selection Justification Form Customers shall complete this Contractor Selection Justification Form for each candidate selected and attach all completed forms to the purchase order. Date: Contractor’s Name: _ Contractor’s Contact Information: Candidate’s Name: Address: _ Phone: _ Email: _ Date Candidate will be available: _ Hourly rate of candidate: $ Position candidate recommended for: _ Justification for selection of candidate: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Agency: Division/Section/Unit: _ Printed Name: _ Title: _ Signature _ Date: Information Technology Staff Augmentation Services Contract No. 80101507-21-STC-ITSA Contract Exhibit H Contractor Performance Survey Note: This is an example of the questions contained in the Contractor Performance Survey. The actual survey will be provided in electronic form. Customers shall complete this Contractor Performance Survey for each Contractor on a quarterly basis. Customers will electronically submit the completed Contractor Performance Survey(s) to the Department Contract Manager no later than the due date indicated the Scope of Work. Contractor's Name: Quarter: Purchase Order (PO) Number: PO Total $ Amount: PO Starting Date Ending Date Please review the attached Rating Definitions and provide your opinion by rating the following: Quality of Service
Assignment Liability Indemnity Force Majeure Consequential Damages and Default Notwithstanding any other provision of this Agreement, the liability, indemnification and insurance provisions of the Transmission Operating Agreement (“TOA”) or other applicable operating agreements shall apply to the relationship between the System Operator and the Interconnection Transmission Owner and the liability, indemnification and insurance provisions of the Tariff apply to the relationship between the System Operator and the Interconnection Customer and between the Interconnecting Transmission Owner and the Interconnection Customer.
Liability to Third Parties The Member shall not be liable for the debts, obligations or liabilities of the Company, including under a judgment, decree or order of a court.
Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
