The Construction Advance Loan4. For each Project, Xxxxxx Xxx will make a Construction Advance Loan to the Construction Lender on the following terms and conditions:
The Construction Advance Loan4 Sample Clauses
Related to The Construction Advance Loan4
No Construction Loans No Mortgage Loan was made in connection with (i) the construction or rehabilitation of a Mortgage Property or (ii) facilitating the trade-in or exchange of a Mortgaged Property other than a construction-to-permanent loan which has converted to a permanent Mortgage Loan;
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.
Disbursement of Advance Proceeds All Advances shall be disbursed from whichever office or other place Agent may designate from time to time and, together with any and all other Obligations of Borrowers to Agent or Lenders, shall be charged to Borrowers' Account on Agent's books. During the Term, Borrowers may use the Revolving Advances by borrowing, prepaying and reborrowing, all in accordance with the terms and conditions hereof. The proceeds of each Revolving Advance requested by Borrowers or deemed to have been requested by Borrowers under Section 2.2(a) hereof shall, with respect to requested Revolving Advances to the extent Lenders make such Revolving Advances, be made available to the applicable Borrower on the day so requested by way of credit to such Borrower's operating account at PNC, or such other bank as Borrowing Agent may designate following notification to Agent, in immediately available federal funds or other immediately available funds or, with respect to Revolving Advances deemed to have been requested by any Borrower, be disbursed to Agent to be applied to the outstanding Obligations giving rise to such deemed request.
PRE-CONSTRUCTION PHASE FEE The Pre-Construction Phase Fee is the total compensation payable to Contractor for the performance of Pre-Construction Phase Services, except for Additional Pre-Construction Phase Services approved in advance and in writing by Owner. The Pre-Construction Phase Fee shall be a lump sum amount based on the AACC established in this Agreement. 6.1 Except as specifically allowed by Owner, Contractor shall not be entitled to any increase in the Pre-Construction Phase Fee for any costs, expenses, liabilities or other obligations arising from the performance of Pre-Construction Phase Services. 6.2 Costs associated with the following items are specifically, but not exclusively, included in the establishment of the Pre-Construction Phase Fee: profit and profit sharing; general overhead; salaries and labor; housing and relocation; estimating, scheduling and information management systems and software; contract administration; office expenses; printing and copying; consulting fees; legal or accounting fees; cost of money; taxes; insurance premiums and deductibles; bond costs; purchase or rental of equipment; utilities; travel; per diem; fines or penalties; and damage awards. 6.3 If the scope of the Pre-Construction Phase Services is changed materially, the Pre- Construction Phase Fee shall be equitably adjusted. If the AACC is changed materially before acceptance of the GMP Proposal, the Pre-Construction Phase Fee shall be adjusted in writing in proportion to the change in the AACC. There shall be no adjustments in the Pre-Construction Phase Fee following acceptance of the GMP Proposal. 6.4 For Additional Pre-Construction Phase Services that are approved in advance and in writing by Owner, Contractor shall be entitled to additional compensation computed as follows: 6.4.1 A pre-established lump sum amount; or 6.4.2 The hourly cost of Contractor’s employees or consultants who actually perform the Additional Services based on the employee’s Worker Wage Rate or prorated Monthly Rate plus the actual cost of allowable expenses incurred in the performance of the Additional Pre-Construction Phase Services, plus an overhead and profit markup of ten percent (10%) of the total cost; or 6.4.3 As otherwise agreed in advance and in writing.
Construction Loan Subject to the terms and conditions of this Agreement and in reliance upon the representations and warranties set forth in this Agreement, the Lender has agreed to lend to Borrower and Borrower has agreed to borrow from Lender the lesser of: (i) $27,000,000.00; or (ii) 55% of the Project Costs. Such amount shall be loaned by Lender pursuant to the terms and conditions set forth in this Agreement and the First Supplement to this Agreement.
During Construction Upon request of the Owner the Contractor shall submit written proposals for unit prices to be applied in the event Change Order Work is authorized by the Owner to be performed under Case (b).
Pre-Construction Phase Employer’s Liability, Workers’ Compensation, Comprehensive General Liability and Comprehensive Automobile Liability in the amounts as set forth in the UGSC.
Equipment Advances (i) Subject to and upon the terms and conditions of this Agreement, Bank agrees to make Equipment Advances to Borrower. Borrower may request Equipment Advances at any time during the Draw Period, provided that the initial Equipment Advance shall not exceed One Million Five Hundred Thousand Dollars ($1,500,000) (the “Initial Equipment Advance”). The aggregate outstanding amount of Equipment Advances shall not exceed the Equipment Line. Each Equipment Advance shall not exceed sixty percent (60%) of the invoice amount of equipment and software listed in that certain Machinery and Equipment 2013 Projection delivered to Bank on or about the Closing Date (which Borrower shall, in any case, have purchased, (i) with respect to the Initial Equipment Advance, within one hundred eighty (180) days and (ii) with respect to all subsequent Equipment Advances, within ninety (90) days, of the date of the corresponding Equipment Advance), excluding taxes, shipping, warranty charges, freight discounts and installation expense. Each Equipment Advance must be in an amount equal to the lesser of One Hundred Fifty Thousand Dollars ($150,000) or the amount that has not yet been drawn under the Equipment Line. (ii) Interest shall accrue from the date of each Equipment Advance at the rate specified in Section 2.3(a), and shall be payable in accordance with Section 2.3(c). Any Equipment Advances that are outstanding on June 30, 2013 shall be payable in twenty seven (27) equal monthly installments of principal, plus all accrued interest, beginning on July 1, 2013, and continuing on the same day of each month thereafter through the Equipment Maturity Date. Any Equipment Advances made by Bank after June 30, 2013 shall immediately amortize and be payable in equal monthly installments of principal, plus all accrued interest, beginning on the first (1st) day of the month immediately following such Equipment Advance and continuing on the same day of each month thereafter through the Equipment Maturity Date, at which time all amounts due in connection with the Equipment Advances made under this Section 2.1(b) shall be immediately due and payable. Equipment Advances, once repaid, may not be reborrowed. Except as set forth in the Pricing Addendum, Borrower may prepay the Equipment Advances prior to the Equipment Maturity Date, provided that on the date of such prepayment Borrower shall, (i) prepay all but not less than all of the Equipment Advances and (ii) in connection with such prepayment, pay to the Bank to the Prepayment Fee, if applicable. (iii) When Borrower desires to obtain an Equipment Advance, Borrower shall notify Bank (which notice shall be irrevocable) by facsimile transmission to be received no later than 3:00 p.m. Pacific time three (3) Business Days before the day on which the Equipment Advance is to be made. Such notice shall be substantially in the form of Exhibit C. The notice shall be signed by a Responsible Officer or its designee and include a copy of the invoice for any Equipment to be financed. Bank shall be entitled to rely on any facsimile notice given by a person who Bank reasonably believes to be a Responsible Officer or a designee thereof, and Borrower shall indemnify and hold Bank harmless for any damages or loss suffered by Bank as a result of such reliance.” 2. Section 2.1(c) of the Agreement hereby is amended and restated in its entirety to read as follows:
Disbursement of Loan Proceeds (a) The Trustee, as the agent of the Trust, shall disburse the amounts on deposit in the Project Loan Account to the Borrower upon receipt of a requisition executed by an Authorized Officer of the Borrower, and approved by the Trust, in a form meeting the requirements of Section 5.02(3) of the Bond Resolution. (b) The Trust and Trustee shall not be required to disburse any Loan proceeds to the Borrower under this Loan Agreement, unless: (i) the proceeds of the Trust Bonds shall be available for disbursement, as determined solely by the Trust; (ii) in accordance with the Bond Act, and the Regulations, the Borrower shall have timely applied for, shall have been awarded and, prior to or simultaneously with the Loan Closing, shall have closed a Fund Loan for a portion of the Allowable Costs (as defined in such Regulations) of the Project in an amount not in excess of the amount of Allowable Costs of the Project financed by the Loan from the Trust; (iii) the Borrower shall have on hand moneys to pay for the greater of (A) that portion of the total Costs of the Project that is not eligible to be funded from the Fund Loan or the Loan, or (B) that portion of the total Costs of the Project that exceeds the actual amounts of the loan commitments made by the State and the Trust, respectively, for the Fund Loan and the Loan; and (iv) no Event of Default nor any event that, with the passage of time or service of notice or both, would constitute an Event of Default shall have occurred and be continuing hereunder.
