Conveyance of the Receivables and the Other Conveyed Property to the Issuer Seller acknowledges that Purchaser intends, pursuant to the Sale and Servicing Agreement, to convey the Receivables and the Other Conveyed Property, together with its rights under this Agreement, to the Issuer on the Closing Date. Seller acknowledges and consents to such conveyance and pledge and waives any further notice thereof and covenants and agrees that the representations and warranties of Seller contained in this Agreement and the rights of Purchaser hereunder are intended to benefit the Issuer, the Owner Trustee, the Trust Collateral Agent, the Noteholders and the Certificateholder. In furtherance of the foregoing, Seller covenants and agrees to perform its duties and obligations hereunder, in accordance with the terms hereof for the benefit of the Issuer, the Owner Trustee, the Trust Collateral Agent, the Noteholders and the Certificateholder and that, notwithstanding anything to the contrary in this Agreement, Seller shall be directly liable to the Issuer, the Owner Trustee, the Trust Collateral Agent, the Noteholders and the Certificateholder (notwithstanding any failure by the Servicer or the Purchaser to perform its respective duties and obligations hereunder or under Related Documents) and that the Trust Collateral Agent may enforce the duties and obligations of Seller under this Agreement against Seller for the benefit of the Owner Trustee, the Trust Collateral Agent, the Noteholders and the Certificateholder.
The Trustee and the Collateral Agent Neither the Trustee nor the Collateral Agent make any representation or warranty as to the validity or sufficiency of this Supplemental Indenture or with respect to the recitals contained herein, all of which recitals are made solely by the other parties hereto.
Conveyance of the Receivables and the Other Conveyed Property (a) Subject to the terms and conditions of this Agreement, Seller hereby sells, transfers, assigns, and otherwise conveys to Purchaser without recourse (but without limitation of its obligations in this Agreement), and Purchaser hereby purchases, all right, title and interest of Seller in and to the following described property (collectively, the “Receivables and the Other Conveyed Property”): (i) the Receivables and all moneys received thereon after the Cutoff Date; (ii) the security interests in the Financed Vehicles granted by Obligors pursuant to the Receivables and any other interest of the Seller in such Financed Vehicles; (iii) any proceeds and the right to receive proceeds with respect to the Receivables from claims on any physical damage, credit life or disability insurance policies covering Financed Vehicles or Obligors and any proceeds from the liquidation of the Receivables; (iv) any proceeds from any Receivable repurchased by a Dealer pursuant to a Dealer Agreement as a result of a breach of representation or warranty in the related Dealer Agreement; (v) all rights under any Service Contracts on the related Financed Vehicles; (vi) the related Receivable Files; (vii) all of the Seller’s (A) Accounts, (B) Chattel Paper, (C) Documents, (D) Instruments and (E) General Intangibles (as such terms are defined in the UCC) relating to the property described in (i) through (vi); and (viii) all proceeds and investments with respect to items (i) through (vii). It is the intention of Seller and Purchaser that the transfer and assignment contemplated by this Agreement shall constitute a sale of the Receivables and the Other Conveyed Property from Seller to Purchaser, conveying good title thereto free and clear of any Liens, and the beneficial interest in and title to the Receivables and the Other Conveyed Property shall not be part of Seller’s estate in the event of the filing of a bankruptcy petition by or against Seller under any bankruptcy or similar law. (b) Simultaneously with the conveyance of the Receivables and the Other Conveyed Property to Purchaser, Purchaser has paid or caused to be paid to or upon the order of Seller an amount equal to the book value of the Receivables sold by Seller, as set forth on the books and records of Seller, by wire transfer of immediately available funds and the remainder as a contribution to the capital of the Purchaser (a wholly-owned subsidiary of Seller).
Landlord and Storage Agreements Upon request, provide Agent with copies of all existing agreements, and promptly after execution thereof provide Agent with copies of all future agreements, between an Obligor and any landlord, warehouseman, processor, shipper, bailee or other Person that owns any premises at which any Collateral may be kept or that otherwise may possess or handle any Collateral.
Concerning the Collateral and the Related Loan Documents Each Lender authorizes and directs the Agent to enter into this Agreement and the other Loan Documents relating to the Collateral, for the ratable benefit of the Agent and the Lenders. Each Lender agrees that any action taken by the Agent, Majority Lenders or Required Lenders, as applicable, in accordance with the terms of this Agreement or the other Loan Documents relating to the Collateral, and the exercise by the Agent, the Majority Lenders, or the Required Lenders, as applicable, of their respective powers set forth therein or herein, together with such other powers that are reasonably incidental thereto, shall be binding upon all of the Lenders.
Actions of Custodian Based on Proper Instructions and Special Instructions So long as and to the extent that the Custodian acts in accordance with (a) Proper Instructions or Special Instructions, as the case may be, and (b) the terms of this Agreement, the Custodian shall not be responsible for the title, validity or genuineness of any property, or evidence of title thereof, received by it or delivered by it pursuant to this Agreement.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Complete Agreement; Construction This Agreement, including the Schedules hereto, shall constitute the entire agreement between the Parties with respect to the subject matter hereof and shall supersede all previous negotiations, commitments and writings with respect to such subject matter. In the event of any inconsistency between this Agreement and any Schedule, the Schedule shall prevail. The rights and remedies of the Parties herein provided shall be cumulative and in addition to any other or further remedies provided by law or equity.
Amendments of Sale and Servicing Agreement and Trust Agreement The Issuer shall not agree to any amendment to Section 9.01 of the Sale and Servicing Agreement or Section 11.01 of the Trust Agreement to eliminate the requirements thereunder that the Indenture Trustee or the Noteholders consent to amendments thereto as provided therein.
Delivery of the Funding Agreement and the Guarantee The Trust hereby authorizes the Custodian, on behalf of the Indenture Trustee, to receive the Funding Agreement from Principal Life and the Guarantee from PFG pursuant to the assignment of the Funding Agreement and Guarantee (the “Assignment”), to be entered into on the Original Issue Date, included in the closing instrument dated as of the Original Issue Date (the “Closing Instrument”).