The need for a capacity commitment Sample Clauses

The need for a capacity commitment. Aurizon Network disagrees with the QCA’s view that ‘an up-front capacity commitment…is essential for the QCA to be able to commit to’ pre-approval28. A capacity guarantee would provide comfort that the scope and standard chosen is sufficient to deliver capacity (i.e. the scope is not inadequate). Pre-approval is testing the opposite concern, namely that the scope and standard is prudent and not greater than what is required (i.e. the scope is not excessive). The inclusion of a capacity guarantee would make pre-approval harder, not easier, to achieve as the pre-approval would need to ensure the scope included as a result of the capacity guarantee is prudent in the light of that guarantee. The inclusion of a capacity guarantee in a SUFA transaction, and substantial financial consequences for the capacity guarantor should the guaranteed capacity not be delivered, should be considered in determining whether the project scope is prudent. Aurizon Network expects that this determination would support the inclusion of more scope than would apply for the same project in the absence of a capacity guarantee.
Sample 1
AutoNDA by SimpleDocs

Related to The need for a capacity commitment

  • Maximum Capacity The Sick Leave Bank shall accumulate unused Bank days from year to year to a maximum capacity which shall not exceed double the number of eligible employees as defined in the above Section C, Eligibility for Membership.

  • Service Commitment Newly hired nurses and currently employed nurses who voluntarily choose to relocate and receive a relocation allowance may be required to serve for a minimum of two years at their base before they will be considered for transfer to another base. This commitment will not apply when the employer and nurse mutually agree to waive it and when relocation occurs as a result of layoff/rehire.

  • Acting Capacity ‌ When an employee is assigned temporarily to a job for which he/she is qualified in a higher pay grade for a period of five (5) days or his/her regular workweek, whichever is less, the employee shall be paid retroactively from the initial date of the temporary transfer for the duration of the temporary assignment. The employee shall be paid as if he/she had been promoted during such assignment. In no event may an employee acquire any status in a higher classification as a result of his/her temporary assignment. Acting capacity assignments shall not be made on an arbitrary or capricious basis. Employees shall not be rotated in acting capacity in an arbitrary or capricious manner in order to avoid payment of acting capacity pay. This Article shall not be used in lieu of the proper processing of any request for reclassification or reallocation of a position pursuant to Article 48, Reclassifications, or the filling of a vacancy pursuant to Article 56, Seniority.

  • Reserved Capacity The maximum amount of capacity and energy that the Transmission Provider agrees to transmit for the Transmission Customer over the Transmission Provider’s Transmission System between the Point(s) of Receipt and the Point(s) of Delivery under Part II of the Tariff. Reserved Capacity shall be expressed in terms of whole megawatts on a sixty (60) minute interval (commencing on the clock hour) basis.

  • DVBE Commitment This section is applicable if Contractor received a disabled veteran business enterprise (“DVBE”) incentive in connection with this Agreement. Contractor’s failure to meet the DVBE commitment set forth in its bid or proposal constitutes a breach of the Agreement. If Contractor used DVBE subcontractor(s) in connection with this Agreement: (i) Contractor must use the DVBE subcontractors identified in its bid or proposal, unless the JBE approves in writing replacement by another DVBE subcontractor in accordance with the terms of this Agreement; and (ii) Contractor must complete and return to the JBE a post-contract certification form promptly upon completion of the awarded contract, and by no later than the date of submission of Contractor’s final invoice to the JBE. (The post-contract certification form is located at: xxxxx://xxx.xxxxxx.xx.xxx/documents/JBCM-Post- Contract-Certification-Form.docx) If the Contractor fails to do so, the JBE will withhold $10,000 from the final payment, or withhold the full payment if it is less than $10,000, until the Contractor submits a complete and accurate post-contract certification form. The JBE shall allow the Contractor to cure the deficiency after written notice of the Contractor’s failure to complete and submit an accurate post- contract certification form. Notwithstanding the foregoing and any other law, if after at least 15 calendar days, but no more than 30 calendar days, from the date of the written notice the Contractor refuses to comply with these certification requirements, the JBE shall permanently deduct $10,000 from the final payment, or the full payment if less than $10,000. The post-contract certification form shall include: (1) the total amount of money Contractor received under the Agreement, (2) the total amount of money and the percentage of work that Contractor committed to provide to each DVBE subcontractor; (3) the name and address of each DVBE subcontractor to which Contractor subcontracted work in connection with the Agreement; (4) the amount of money each DVBE subcontractor actually received from Contractor in connection with the Agreement, and the corresponding percentage this payment comprises of the total amount of money Contractor received under the Agreement; and (5) that all payments under the Agreement have been made to the applicable DVBE subcontractors. Upon request by the JBE, Contractor shall provide proof of payment for the work. A person or entity that knowingly provides false information shall be subject to a civil penalty for each violation. Contractor will comply with all rules, regulations, ordinances and statutes that govern the DVBE program, including, without limitation, Military and Veterans Code section 999.5.

  • STAFF COMMITMENT 23. If this Settlement Agreement is accepted by the Hearing Panel, Staff will not initiate any proceeding under the By-laws of the MFDA against the Respondent in respect of the facts set out in Part IV and the contraventions described in Part V of this Settlement Agreement, subject to the provisions of Part IX below. Nothing in this Settlement Agreement precludes Staff from investigating or initiating proceedings in respect of any facts and contraventions that are not set out in Parts IV and V of this Settlement Agreement or in respect of conduct that occurred outside the specified date ranges of the facts and contraventions set out in Parts IV and V, whether known or unknown at the time of settlement. Furthermore, nothing in this Settlement Agreement shall relieve the Respondent from fulfilling any continuing regulatory obligations.

  • SLEEPING CAPACITY/DISTURBANCES Tenant and all other occupants of the premises will be required to vacate the premises and forfeit the rental fee and security deposit for any of the following: Occupancy exceeding the sleeping capacity of the property, using the premises for any illegal activity, causing damage to the premises rented or to any of the neighboring properties and any other acts that interfere with neighbors' right to quiet enjoyment of their premises. HOLD HARMLESS None of iTrip Vacations, Sea Oats Vacation Property Management, Inc. or the owner of the premises assume risk, responsibility or any liability for, and the Tenant hereby releases, waives, relinquishes and discharges iTrip Vacations, Sea Oats Vacation Property Management, Inc., the owner of the premises and all directors, officers, employees, agents or other representatives of such parties from, any (i) loss, damage, illness, injury or exposure to COVID-19, other viruses or the flu to persons or their personal property that occurs during their stay on the premises; (ii) any inconveniences, damage, loss or injury arising from any temporary defects or stoppage in supply of water, gas, cable service, internet service, electricity or plumbing or (iii) any inconveniences, damage, loss or injury arising from or due to weather conditions, insects, natural disasters, acts of God, or other reasons beyond their control. POOL & PATIO If the premises include a private or community pool (including hot tubs), then the Tenant hereby acknowledges that the premises they have reserved include a community pool and the undersigned agrees and acknowledges that the community pool and patio/deck can be dangerous areas, that the deck/patio can be slippery when wet, and that injury may occur to anyone who is not careful. With full knowledge of the above facts and warnings, the undersigned Tenant accepts and assumes all risks involved to Tenant and all of Tenant's guests in or related to the use of the private or community pool (including hot tubs) and patio areas.

  • Time Commitment The Advisor shall, and shall cause its Affiliates and their respective employees, officers and agents to, devote to the Company such time as shall be reasonably necessary to conduct the business and affairs of the Company in an appropriate manner consistent with the terms of this Agreement. The Company acknowledges that the Advisor and its Affiliates and their respective employees, officers and agents may also engage in activities unrelated to the Company and may provide services to Persons other than the Company or any of its Affiliates.

  • Right to Contracted Capacity & Energy 4.4.1 The SPD will declare the CUF of the project and will be allowed to revise the same once within first year after COD of the project. Thereafter, the CUF for the Project shall remain unchanged for the entire term of the PPA. The declared annual CUF shall in no case be less than 17%. It shall be the responsibility of the SPD, entirely at its cost and expense to install such number of Solar panels and associated infrastructure(like project equipment)as may be necessary to achieve the required CUF, and for this purpose SPD shall make its own study and investigation of the GHI and other factors prevalent in the area which have implication on the quantum of generation. Further, arrangement of extra land for such installation shall be intimated to MSPDCL in advance and MSPDCL shall have to reply for the same in 7 days in the best interest of the project generation. However,non- availability of land shall not absolve SPD from his obligations under the PPA. SPD shall maintain generation so as to achieve annual CUF within + 10% and -15% of the declared value till the end of 10 years from COD, subject to the annual CUF remaining minimum of 15%, and within +10% and -20% of the declared value of the annual CUF thereafter till the end of the PPA duration of 25 years. The lower limit will, however, be relaxable by MSPDCL to the extent of non-availability of grid for evacuation which is beyond the control of the SPD. The annual CUF will be calculated every Contract Year. The compensation due to shortfall in generation shall be applied to the amount of shortfall in generation during the Contract Year. The amount of compensation shall be equal to the compensation payable (including equivalent amount of Electricity purchased from the grid for meeting load demand due to short fall in solar power) by the buying Entity, which shall ensure that the buying Entity is offset for all potential costs associated with low generation and supply of power under the PPA, subject to a minimum of 50% (fifty per cent) of the cost of this shortfall in energy terms, calculated at PPA tariff. The amount, being equal to the compensation payable, by the buying Entity for not meeting load requirements is only a measure of damage. It shall not be construed that the compensation is payable by SPD only if the buying Entity are required to pay compensation for such not meeting of load requirements or that the buying Entity or the SPD shall be required to prove or establish such payment of compensation for not meeting the load. SPD shall agree that the methodology specified herein above for calculation of liquidated damages payable by the SPD for shortfall in generation is a genuine and accurate pre-estimation of the actual loss that will be suffered by buying Entity. SPD shall further acknowledge that a breach of any of the obligations contained herein result in injuries and that the amount of the liquidated damages or the method of calculating the liquidated damages specified in this document is a genuine and reasonable pre-estimate of the damages that may be suffered by buying Entity in each case specified under this Agreement. However, this compensation shall not be applicable in events of Force Majeure identified under the PPA with MSPDCL, affecting supply of power by the SPD to the Buying Entity.

  • INDEPENDENT CAPACITY The employees or agents of each party who are engaged in the performance of this Agreement shall continue to be employees or agents of that party and shall not be considered for any purpose to be employees or agents of the other party.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!