General Responsibility The Consultant shall, at all times during the Agreement, remain responsible. The Consultant agrees, if requested by the Commissioner of NYSDOT or his or her designee, to present evidence of its continuing legal authority to do business in New York State, integrity, experience, ability, prior performance, and organizational and financial capacity.
Emergency Response Partners must develop, maintain, and carry out a response plan for public water system emergencies, including disease outbreaks, spills, operational failures, and water system contamination. Partners must notify DWS in a timely manner of emergencies that may affect drinking water supplies.
Company’s Response Upon receipt by the Company of a copy of a Conversion Notice, the Company shall as soon as practicable, but in no event later than one (1) Business Day after receipt of such Conversion Notice, send, via email, facsimile or overnight courier, a confirmation of receipt of such Conversion Notice to such Holder indicating that the Company will process such Conversion Notice in accordance with the terms herein. Within two (2) Business Days after the date of the Conversion Confirmation, the Company shall have issued and electronically transferred the shares to the Broker indicated in the Conversion Notice; should the Company be unable to transfer the shares electronically, it shall, within two (2) Business Days after the date of the Conversion Confirmation, have surrendered to FedEx for delivery the next day to the address as specified in the Conversion Notice, a certificate, registered in the name of the Holder, for the number of shares of Common Stock to which the Holder shall be entitled.
Personal Responsibility The Participant and his/her parent(s) or legal guardian(s) certify that Participant has no physical or mental condition that precludes him/her from participating in the Activities and that he/she is not participating against medical advice.
Conditions Term of Agreement 93 3.1 Conditions Precedent to the Initial Extension of Credit ............................................. 93 3.2 Conditions Precedent to all Extensions of Credit ........................................................ 93 3.3 Maturity ........................................................................................................................... 93 3.4
ONLY No response If proposing on Part 2, the vendor must download the Vendor Agreement from the attachment tab, fill in the requested information and upload the completed agreement. DO NOT UPLOAD encrypted or password protected files.
Incident Response Operator shall have a written incident response plan that reflects best practices and is consistent with industry standards and federal and state law for responding to a data breach, breach of security, privacy incident or unauthorized acquisition or use of any portion of Data, including PII, and agrees to provide LEA, upon request, an executive summary of the written incident response plan.
General Responsibilities Issuer hereby engages Distributor to act as exclusive distributor of the shares of each class of the Funds. The Funds subject to this Agreement as of the date hereof are identified on SCHEDULE A, which may be amended from time to time in accordance with Section 11 below. Sales of a Fund's shares shall be made only to investors residing in those states in which such Fund is registered. After effectiveness of each Fund’s registration statement, Distributor will hold itself available to receive, as agent for the Fund, and will receive by mail, telex, telephone, or such other method as may be agreed upon between Distributor and Issuer, orders for the purchase of Fund shares, and will accept or reject such orders on behalf of the Fund in accordance with the provisions of the applicable Fund’s prospectus. Distributor will be available to transmit orders, as promptly as possible after it accepts such orders, to the Fund’s transfer agent for processing at the shares’ net asset value next determined in accordance with the prospectuses.
Additional Responsibilities This paragraph applies to all phases of Architect's work. (a) Architect shall be responsible for the professional quality, technical accuracy, timely completion and coordination of all of Architect's work, including that performed by Architect's consultants, and including designs, Drawings, Specifications, reports and other services, irrespective of Owner's approval or acquiescence in same. Architect shall, without additional compensation, correct or revise any errors, omissions or other deficiencies in his work. (b) Architect shall be responsible, in accordance with applicable law, to Owner for all loss or damage to Owner caused by Architect's negligent act or omission; except that Architect hereby irrevocably waives and excuses Owner and its attorneys from compliance with any requirement to obtain a certificate of review as a condition precedent to commencement of an action, including any such requirements set forth in Section 00-00-000, C.R.S. or similar statute. (c) Architect's professional responsibility shall comply with the standard of care applicable to the type of engineering and architectural services provided, commensurate with the size, scope and nature of the Project. (d) Architect shall be completely responsible for the safety of Architect's employees in the execution of work under this Agreement, shall provide all necessary safety equipment for said employees, and shall hold harmless and indemnify and defend Owner from any and all claims, suits, loss or injury to Architect's employees. (e) Architect acknowledges that, due to the nature of architectural and related professional services and the impact of same on the Project, the Owner has a substantial interest in the personnel and consultants to whom Architect assigns principal responsibility for services performed under this Agreement. Consequently, Architect represents that Architect has selected and intends to employ or assign the key personnel and consultants identified in Appendix C - "Identification of Personnel, Subcontractors and Task Responsibility", attached hereto for the Project assignments and areas of responsibility stated therein. Within 10 days of execution of this Agreement, Owner shall have the right to object in writing to employment on the Project of any such key person, consultant or assignment of principal responsibility, in which case Architect will employ alternate personnel for such function or reassign such responsibility to another to whom Owner has no reasonable objection. Thereafter, Architect shall not assign or reassign Project work to any person to whom Owner has reasonable objection. Within 5 days of execution of this Agreement, Architect shall designate in writing a Project representative who shall have complete authority to bind Architect, and to whom Owner should address communications. (f) Promptly after execution of this Agreement and upon receipt of authorization from Owner to proceed, Architect shall submit to Owner for approval a schedule showing the order in which Architect proposes to accomplish his work, with dates on which he will commence and complete each major work item. The schedule shall provide for performance of the work in a timely manner so as to not delay Owner's time table for achievement of interim tasks and final completion of Project work, provided however, the Architect will not be responsible for delays beyond his control. (g) Before undertaking any work which Architect considers beyond or in addition to the scope of work and services which Architect has contractually agreed to perform under the terms of this Agreement, Architect shall advise Owner in writing (i) that Architect considers the work beyond the scope of this Agreement, (ii) the reasons the Architect believes the out of scope or additional work should be performed, and (iii) a reasonable estimate of the cost of such work. Architect shall not proceed with such out of scope or additional work until authorized in writing by Owner. The compensation for such authorized work shall be negotiated, but in the event the parties fail to negotiate or are unable to agree as to compensation, then Architect shall be compensated for his direct costs and professional time at the rates set forth in Appendix B - "Fee Schedule".
Agency Response a. OGS will consider all information relevant to the Formal Dispute, and may, in its discretion, suspend, modify, or cancel the disputed procurement/Contract action prior to issuance of a Formal Dispute decision. b. OGS reserves the right to require the filer to meet or participate in a conference call with OGS to discuss the Formal Dispute when, in its sole judgment, circumstances so warrant. c. OGS reserves the right to waive or extend the time requirements for decisions and final determinations on appeals herein prescribed when, in its sole judgment, circumstances so warrant. d. OGS reserves the right to consider or reject the merits of any Formal Dispute.
