Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following: i) acts of God; ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities; iii) acts of war (whether declared or undeclared), invasion or civil unrest; iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement); v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals; vi) earthquakes, explosions, accidents, landslides; fire; vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality; viii) chemical or radioactive contamination or ionizing radiation; or ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs; x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.
Reporting of Non-Force Majeure Events Each Party (the “Notifying Party”) shall notify the other Parties when the Notifying Party becomes aware of its inability to comply with the provisions of this Agreement for a reason other than a Force Majeure event. The Parties agree to cooperate with each other and provide necessary information regarding such inability to comply, including the date, duration, reason for the inability to comply, and corrective actions taken or planned to be taken with respect to such inability to comply. Notwithstanding the foregoing, notification, cooperation or information provided under this Article shall not entitle the Party receiving such notification to allege a cause for anticipatory breach of this Agreement.
SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence: a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
Infectious Diseases The Employer and the Union desire to arrest the spread of infectious diseases in the nursing home. To achieve this objective, the Joint Health and Safety Committee may review and offer input into infection control programs and protocols including surveillance, outbreak control, isolation, precautions, worker education and training, and personal protective equipment. The Employer will provide training and ongoing education in communicable disease recognition, use of personal protective equipment, decontamination of equipment, and disposal of hazardous waste.
Safeguarding and Protecting Children and Vulnerable Adults The Supplier will comply with all applicable legislation and codes of practice, including, where applicable, all legislation and statutory guidance relevant to the safeguarding and protection of children and vulnerable adults and with the British Council’s Child Protection Policy, as notified to the Supplier and amended from time to time, which the Supplier acknowledges may include submitting to a check by the UK Disclosure & Barring Service (DBS) or the equivalent local service; in addition, the Supplier will ensure that, where it engages any other party to supply any of the Services under this Agreement, that that party will also comply with the same requirements as if they were a party to this Agreement.
Events of Force Majeure Neither Party shall be held liable or responsible to the other Party nor be deemed to be in default under, or in breach of any provision of, this Agreement for failure or delay in fulfilling or performing any obligation of this Agreement when such failure or delay is due to force majeure, and without the fault or negligence of the Party so failing or delaying. For purposes of this Agreement, force majeure is defined as causes beyond the control of the Party, including, without limitation, acts of God; acts, regulations, or laws of any government; war; civil commotion; destruction of production facilities or materials by fire, flood, earthquake, explosion or storm; labor disturbances; epidemic; and failure of public utilities or common carriers. In such event Medistem or Licensee, as the case may be, shall immediately notify the other Party of such inability and of the period for which such inability is expected to continue. The Party giving such notice shall thereupon be excused from such of its obligations under this Agreement as it is thereby disabled from performing for so long as it is so disabled and the 30 days thereafter. To the extent possible, each Party shall use reasonable efforts to minimize the duration of any force majeure.
Effect of Force Majeure Event If either party to this contract cannot meet an obligation under this contract because of an event outside the control of that party (‘a force majeure event’): (a) the obligation, other than an obligation to pay money, is suspended to the extent it is affected by the force majeure event for as long as the force majeure event continues; and (b) the affected party must use its best endeavours to give the other party prompt notice of that fact including full particulars of the event, an estimate of its likely duration, the extent to which the affected party’s obligations are affected and the steps being taken to remove, overcome or minimise those effects.
Abuse and Neglect of Children and Vulnerable Adults: Abuse Registry Party agrees not to employ any individual, to use any volunteer or other service provider, or to otherwise provide reimbursement to any individual who in the performance of services connected with this agreement provides care, custody, treatment, transportation, or supervision to children or to vulnerable adults if there has been a substantiation of abuse or neglect or exploitation involving that individual. Party is responsible for confirming as to each individual having such contact with children or vulnerable adults the non-existence of a substantiated allegation of abuse, neglect or exploitation by verifying that fact though (a) as to vulnerable adults, the Adult Abuse Registry maintained by the Department of Disabilities, Aging and Independent Living and (b) as to children, the Central Child Protection Registry (unless the Party holds a valid child care license or registration from the Division of Child Development, Department for Children and Families). See 33 V.S.A. §4919(a)(3) and 33 V.S.A. §6911(c)(3).
Labor Disputes and Acts of God Neither the business nor the properties of the Borrower or any Subsidiary or any Guarantor are affected by any fire, explosion, accident, strike, lockout, or other labor dispute, drought, storm, hail, earthquake, embargo, act of God or of the public enemy, or other casualty (whether or not covered by insurance), materially and adversely affecting such business or properties or the operation of the Borrower or such Subsidiary or such Guarantor.
Technical and Organisational Measures (1) Before the commencement of processing, the Supplier shall document the execution of the necessary Technical and Organisational Measures, set out in advance of the awarding of the Order or Contract, specifically with regard to the detailed execution of the contract, and shall present these documented measures to the Client for inspection. Upon acceptance by the Client, the documented measures become the foundation of the contract. Insofar as the inspection/audit by the Client shows the need for amendments, such amendments shall be implemented by mutual agreement. (2) The Supplier shall establish the security in accordance with Article 28 Paragraph 3 Point c, and Article 32 GDPR in particular in conjunction with Article 5 Paragraph 1, and Paragraph 2 GDPR. The measures to be taken are measures of data security and measures that guarantee a protection level appropriate to the risk concerning confidentiality, integrity, availability and resilience of the systems. The state of the art, implementation costs, the nature, scope and purposes of processing as well as the probability of occurrence and the severity of the risk to the rights and freedoms of natural persons within the meaning of Article 32 Paragraph 1 GDPR must be taken into account. [Details in Appendix 1] (3) The Technical and Organisational Measures are subject to technical progress and further development. In this respect, it is permissible for the Supplier to implement alternative adequate measures. In so doing, the security level of the defined measures must not be reduced. Substantial changes must be documented.
