Submission of Claims 39 If Provider submits claims for Services rendered under this Contract, the following 40 requirements shall apply:
Assertion of Claims (a) In the event that a Person (the "Indemnified Party") desires to assert its right to indemnification from a Person (an "Indemnifying Party") required to indemnify such Indemnified Party under this Article XII, the Indemnified Party will give the Indemnifying Party prompt notice of the claim giving rise thereto (a "Claim"), and the Indemnifying Party shall undertake the defense thereof (unless the Claim is asserted against or related to or results from any action or failure to take action by such Indemnifying Party). The failure to promptly notify the Indemnifying Party hereunder shall not relieve the Indemnifying Party of its obligations hereunder, except to the extent that the Indemnifying Party is actually prejudiced by the failure to so notify promptly.
(b) The Indemnified Party shall not settle or compromise any Claim without the written consent of the Indemnifying Party unless the Indemnified Party agrees in writing to forego any and all claims for indemnification from the Indemnifying Party with respect to such Claim. However, if the Indemnifying Party, within a reasonable time after notice of any such Claim, fails to defend such Claim, the Indemnified Party shall have the right to undertake the defense, compromise or settlement of such Claim on behalf of and for the account and risk of the Indemnifying Party, subject to the right of the Indemnifying Party to assume the defense of such Claim at any time prior to settlement, compromise or final determination thereof.
(c) If the Indemnifying Party has undertaken the defense of a Claim and (i) if there is a reasonable expectation that (x) a Claim may materially and adversely affect the Indemnified Party other than as a result of money damages or other money payments or (y) the Indemnified Party or Parties may have legal defenses available to it or them that are different from or additional to the defenses available to the Indemnifying Party, or (ii) if the Indemnifying Party shall not have employed counsel reasonably satisfactory to the Indemnified Party, the Indemnified Party shall nevertheless have the right, at the Indemnifying Party's cost and expense, to defend such Claim.
Resolution of Claims The Company acknowledges that a settlement or other disposition short of final judgment may be successful on the merits or otherwise for purposes of Section 8(a)(i) if it permits a party to avoid expense, delay, distraction, disruption and uncertainty. In the event that any Claim relating to an Indemnifiable Event to which Indemnitee is a party is resolved in any manner other than by adverse judgment against Indemnitee (including, without limitation, settlement of such action, claim or proceeding with our without payment of money or other consideration) it shall be presumed that Indemnitee has been successful on the merits or otherwise for purposes of Section 8(a)(i). The Company shall have the burden of proof to overcome this presumption.
Nonadmission of Wrongdoing The Parties agree that neither this Agreement nor the furnishing of the consideration for this Agreement shall be deemed or construed at any time for any purpose as an admission by Releasees of wrongdoing or evidence of any liability or unlawful conduct of any kind.
Non-Admission of Wrongdoing The Parties agree neither this Agreement nor the furnishing of the consideration for same shall be deemed or construed at any time for any purpose as an admission by any Party of any liability or unlawful conduct of any kind.
Information Submission by Connecting Transmission Owner The initial information submission by Connecting Transmission Owner shall occur no later than one hundred eighty (180) Calendar Days prior to Trial Operation and shall include New York State Transmission System information necessary to allow the Developer to select equipment and meet any system protection and stability requirements, unless otherwise mutually agreed to by the Developer and Connecting Transmission Owner. On a monthly basis Connecting Transmission Owner shall provide Developer and NYISO a status report on the construction and installation of Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades, including, but not limited to, the following information: (1) progress to date; (2) a description of the activities since the last report; (3) a description of the action items for the next period; and (4) the delivery status of equipment ordered.
Submission of Grievances A. Any employee or group of employees shall have the right to present a grievance. No employee or group of employees shall be hindered from or disciplined for exercising this right.
B. If any two (2) or more employees have essentially the same grievance they may, and if requested by the County must, collectively present and pursue their grievance if they report to the same immediate supervisor.
C. If the grievant is a group of more than three (3) employees, the group shall, at the request of the County, appoint one (1) or two (2) employees to speak for the collective group. To be considered a grievant in a group grievance, each employee must be individually identified as a grievant when the grievance is submitted at Step 2.
Judicial or Administrative Proceedings Business Associate shall notify County if it is named as a defendant in a criminal proceeding for a violation of HIPAA. County may terminate this Agreement if Business Associate is found guilty of a criminal violation of HIPAA. County may terminate this Agreement if a finding or stipulation that the Business Associate has violated any standard or requirement of HIPAA, or other security or privacy laws is made in any administrative or civil proceeding in which the Business Associate is a party or has been joined.
Arbitration of Claims The parties shall submit all Claims (as defined in Exhibit E) arising under this Agreement or any other Transaction Document or any other agreement between the parties and their affiliates or any Claim relating to the relationship of the parties to binding arbitration pursuant to the arbitration provisions set forth in Exhibit E attached hereto (the “Arbitration Provisions”). For the avoidance of doubt, the parties agree that the injunction described in Section 9.3 below may be pursued in an arbitration that is separate and apart from any other arbitration regarding all other Claims arising under the Transaction Documents. The parties hereby acknowledge and agree that the Arbitration Provisions are unconditionally binding on the parties hereto and are severable from all other provisions of this Agreement. By executing this Agreement, Company represents, warrants and covenants that Company has reviewed the Arbitration Provisions carefully, consulted with legal counsel about such provisions (or waived its right to do so), understands that the Arbitration Provisions are intended to allow for the expeditious and efficient resolution of any dispute hereunder, agrees to the terms and limitations set forth in the Arbitration Provisions, and that Company will not take a position contrary to the foregoing representations. Company acknowledges and agrees that Investor may rely upon the foregoing representations and covenants of Company regarding the Arbitration Provisions.
Exclusion of Claim You acknowledge and agree that you shall have no entitlement to compensation or damages insofar as such entitlement arises or may arise from you ceasing to have rights under or to be entitled to vest in your Restricted Shares as a result of such termination (whether the termination is in breach of contract or otherwise), or from the loss or diminution in value of your Restricted Shares. Upon the grant of your Restricted Shares, you shall be deemed to have waived irrevocably any such entitlement.
