U niversity’s Right to Substitute Performance. The University shall have the right, in its sole discretion, at any time and for any reason, to engage another contractor to perform any part of the Services under this Agreement.
U niversity’s Right to Substitute Performance Sample Clauses
Related to U niversity’s Right to Substitute Performance
No Right to Subcontracting Subcontractor may not subcontract, either part or in whole, the Services authorized under this Agreement.
Right to Compel Performance Notwithstanding the foregoing, upon the occurrence of an event of Default, a non-Defaulting Interconnection Party shall be entitled to (a) commence an action to require the Defaulting Interconnection Party to remedy such Default and specifically perform its duties and obligations hereunder in accordance with the terms and conditions hereof, (b) withhold payments, (c) suspend performance hereunder, and (d) exercise such other rights and remedies as it may have in equity or at law; provided, however, that the Transmission Provider shall not terminate the Interconnection Service Agreement due to the failure of Interconnection Customer to make a payment hereunder unless such failure could reasonably be expected to have a material adverse effect on the Interconnected Transmission Owner.
Right to Specific Performance THE COMPANY HEREBY ACKNOWLEDGES AND AGREES THAT THE DAMAGES TO BE INCURRED BY PARTICIPANT AS A RESULT OF THE COMPANY’S BREACH OF THIS AGREEMENT WILL BE DIFFICULT, IF NOT IMPOSSIBLE, TO ASCERTAIN, THAT DAMAGES WILL NOT BE AN ADEQUATE REMEDY AND THAT ANY BREACH OR THREATENED BREACH OF ANY OF THE PROVISIONS OF THIS AGREEMENT BY THE COMPANY MAY CAUSE IMMEDIATE IRREPARABLE HARM FOR WHICH THERE MAY BE NO ADEQUATE REMEDY AT LAW. ACCORDINGLY, THE PARTIES AGREE THAT, IN THE EVENT OF ANY SUCH BREACH OR THREATENED BREACH, PARTICIPANT SHALL BE ENTITLED TO IMMEDIATE AND PERMANENT EQUITABLE RELIEF (INCLUDING INJUNCTIVE RELIEF AND SPECIFIC PERFORMANCE OF THE PROVISIONS OF THIS AGREEMENT) FROM A COURT OF COMPETENT JURISDICTION (IN ADDITION TO ANY OTHER REMEDY TO WHICH IT MAY BE ENTITLED AT LAW OR IN EQUITY). THE PARTIES AGREE AND STIPULATE THAT PARTICIPANT SHALL BE ENTITLED TO SUCH EQUITABLE (INCLUDING INJUNCTIVE) RELIEF WITHOUT POSTING A BOND OR OTHER SECURITY AND THE COMPANY FURTHER WAIVES ANY DEFENSE IN ANY SUCH ACTION FOR SPECIFIC PERFORMANCE OR INJUNCTIVE RELIEF THAT A REMEDY AT LAW WOULD BE ADEQUATE AND ANY REQUIREMENT UNDER LAW TO POST SECURITY AS A PREREQUISITE TO OBTAINING EQUITABLE RELIEF. NOTHING CONTAINED IN THIS SECTION SHALL LIMIT THE PARTIES’ RIGHT TO ANY REMEDIES AT LAW, INCLUDING THE RECOVERY OF DAMAGES FOR BREACH OF THIS AGREEMENT.
Right to Subcontract The Carrier at its discretion may subcontract on any terms the whole or any part of the Carriage.
Contractor’s Performance Warranties Contractor represents and warrants to the State that: (i) Each and all of the services shall be performed in a timely, diligent, professional and skillful manner, in accordance with the highest professional or technical standards applicable to such services, by qualified persons with the technical skills, training and experience to perform such services in the planned environment. (ii) Any time software is delivered to the State, whether delivered via electronic media or the internet, no portion of such software or the media upon which it is stored or delivered will have any type of software routine or other element which is designed to facilitate unauthorized access to or intrusion upon; or unrequested disabling or erasure of; or unauthorized interference with the operation of any hardware, software, data or peripheral equipment of or utilized by the State. Without limiting the generality of the foregoing, if the State believes that harmful code may be present in any software delivered hereunder, Contractor will, upon State’s request, provide a new or clean install of the software. Notwithstanding the foregoing, Contractor assumes no responsibility for the State’s negligence or failure to protect data from viruses, or any unintended modification, destruction or disclosure. (iii) To the extent Contractor resells commercial hardware or software it purchased from a third party, Contractor will, to the extent it is legally able to do so, pass through any such third party warranties to the State and will reasonably cooperate in enforcing them. Such warranty pass-through will not relieve the Contractor from Contractor’s warranty obligations set forth herein.
Waiver of Breach; Specific Performance The waiver of a breach of any provision of this Agreement shall not operate or be construed as a waiver of any other breach. Each of the parties to this Agreement will be entitled to enforce this Agreement, specifically, to recover damages by reason of any breach of this Agreement, and to exercise all other rights existing in that party’s favor. The parties hereto agree and acknowledge that money damages may not be an adequate remedy for any breach of the provisions of this Agreement and that any party may apply to any court of law or equity of competent jurisdiction for specific performance or injunctive relief to enforce or prevent any violations of the provisions of this Agreement.
Right to Seek Assurance The Transfer Agent may refuse to transfer, exchange or redeem shares of the Fund or take any action requested by a shareholder until it is satisfied that the requested transaction or action is legally authorized or until it is satisfied there is no basis for any claims adverse to the transaction or action. It may rely on the provisions of the Uniform Act for the Simplification of Fiduciary Security Transfers or the Uniform Commercial Code. The Company shall indemnify the Transfer Agent for any act done or omitted to be done in reliance on such laws or for refusing to transfer, exchange or redeem shares or taking any requested action if it acts on a good faith belief that the transaction or action is illegal or unauthorized.
Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
LANDLORD'S RIGHT TO PERFORM TENANT'S OBLIGATIONS (a) Without limiting the rights and remedies of Landlord contained in Sections 20.2 and 20.3 above, if Tenant shall be in default in the performance of any of the terms, provisions, covenants or conditions to be performed or complied with by Tenant pursuant to this Lease, then Landlord may at Landlord’s option, without any obligation to do so, and without notice to Tenant perform any such term, provision, covenant, or condition, or make any such payment and Landlord by reason of so doing shall not be liable or responsible for any loss or damage thereby sustained by Tenant or anyone holding under or through Tenant or any of Tenant’s Agents. (b) Without limiting the rights of Landlord under Sections 20.2 and 20.3 above, Landlord shall have the right at Landlord’s option, without any obligation to do so, to perform any of Tenant’s covenants or obligations under this Lease without notice to Tenant in the case of an emergency, as determined by Landlord in its sole and absolute judgment, or if Landlord determines, in its sole and absolute judgment, that such action is necessary or desirable to avoid imminent harm to the Premises or any persons. (c) If Landlord performs any of Tenant’s obligations hereunder in accordance with this Section 20.4, the full amount of the cost and expense incurred or the payment so made or the amount of the loss so sustained shall immediately be owing by Tenant to Landlord, and Tenant shall promptly pay to Landlord upon demand, as Additional Charges, the full amount thereof with interest thereon from the date of payment by Landlord at the lower of (i) ten percent (10%) per annum, or (ii) the highest rate permitted by applicable law.
Landlord’s Right to Perform Tenant’s Covenants Tenant covenants and agrees that, if it shall at any time fail to make any payment or perform any other act on its part to be made or performed as in this Lease provided, then Landlord, in its sole discretion may after due notice to, or demand upon, Tenant and subject to the limitations set forth below, make any payment or perform any other act on the part of Tenant to be made and performed as in this Lease provided, in such manner and to such extent as Landlord may reasonably deem desirable, and in exercising any such rights, Landlord may pay necessary and incidental costs and expenses, employ counsel, and incur and pay reasonable attorneys’ fees. The making of any such payment or the performing of any other act by Landlord pursuant to this Article shall not waive, or release Tenant from, any obligations of Tenant in this Lease contained. All sums so paid by Landlord and all reasonably necessary and incidental costs and expenses in connection with the performance of any such act by Landlord shall, except as otherwise in this Lease expressly provided, be payable to Landlord on demand, and Tenant covenants to pay any such sum or sums promptly, and Landlord shall have (in addition to any other right or remedy of Landlord) the same rights and remedies in the event of the non-payment thereof by Tenant as in the case of default by Tenant in the payment of the Base Rent. Whenever practicable, Landlord, before proceeding as provided in this Section 12.4, shall give Tenant notice in writing of the failure of Tenant which Landlord proposes to remedy, and shall allow Tenant such length of time as may be reasonable in the circumstances, consistent with any grace periods contained herein, but not exceeding 30 days from the giving of notice, to remedy the failure itself and, if Tenant shall not remedy the failure in the time so allowed, Landlord shall be deemed to have given “due notice” and may proceed as provided in this Section 12.4; provided that nothing in this Section shall prevent Landlord from acting without notice to Tenant in case of any emergency wherein there is danger to property or person or where there may exist any violation of legal requirements including but not limited to the presence of Hazardous Materials, in which event no notice shall be required.
