Uncontrollable Forces and Delivery Events
Uncontrollable Forces and Delivery Events Sample Clauses
Related to Uncontrollable Forces and Delivery Events
Uncontrollable Forces 12.1 Section 14.1 of the CAISO Tariff shall be incorporated by reference into this Agreement except that all references in Section 14.1 of the CAISO Tariff to Market Participants shall be read as a reference to the Scheduling Coordinator and references to the CAISO Tariff shall be read as references to this Agreement.
Uncontrollable Forces Tariff Provisions Section 14.1 of the CAISO Tariff shall be incorporated by reference into this Agreement except that all references in Section 14.1 of the CAISO Tariff to Market Participants shall be read as a reference to the Participating Generator and references to the CAISO Tariff shall be read as references to this Agreement.
Uncontrollable Events BISYS assumes no responsibility hereunder, and shall not be liable for any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control.
Extraordinary Events No fault if failure due to an Extraordinary Event 15.1 Neither Party will be liable to the other for any failure to perform its obligations under this Contract where the failure is due to an Extraordinary Event. Obligations of the affected Party 15.2 A Party who wishes to claim suspension of its obligations due to an Extraordinary Event must notify the other Party as soon as reasonably possible. The Notice must state: a. the nature of the circumstances giving rise to the Extraordinary Event b. the extent of that Party's inability to perform under this Contract c. the likely duration of that non-performance, and d. what steps are being taken to minimise the impact of the Extraordinary Event on the delivery of Services. Alternative arrangements requiring immediate termination 15.3 If the Buyer, acting reasonably, requires the Services to be supplied during the period affected by an Extraordinary Event, then despite clause 15.4, the Buyer may terminate this Contract immediately by giving Notice.
Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
Extraordinary Events Regarding Common Stock In the event that the Company shall (a) issue additional shares of the Common Stock as a dividend or other distribution on outstanding Common Stock, (b) subdivide its outstanding shares of Common Stock, or (c) combine its outstanding shares of the Common Stock into a smaller number of shares of the Common Stock, then, in each such event, the Purchase Price shall, simultaneously with the happening of such event, be adjusted by multiplying the then Purchase Price by a fraction, the numerator of which shall be the number of shares of Common Stock outstanding immediately prior to such event and the denominator of which shall be the number of shares of Common Stock outstanding immediately after such event, and the product so obtained shall thereafter be the Purchase Price then in effect. The Purchase Price, as so adjusted, shall be readjusted in the same manner upon the happening of any successive event or events described herein in this Section 4. The number of shares of Common Stock that the Holder of this Warrant shall thereafter, on the exercise hereof as provided in Section 1, be entitled to receive shall be adjusted to a number determined by multiplying the number of shares of Common Stock that would otherwise (but for the provisions of this Section 4) be issuable on such exercise by a fraction of which (a) the numerator is the Purchase Price that would otherwise (but for the provisions of this Section 4) be in effect, and (b) the denominator is the Purchase Price in effect on the date of such exercise.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Extraordinary Event Registry Operator will use commercially reasonable efforts to restore the critical functions of the registry within twenty-‐four (24) hours after the termination of an extraordinary event beyond the control of the Registry Operator and restore full system functionality within a maximum of forty-‐eight (48) hours following such event, depending on the type of critical function involved. Outages due to such an event will not be considered a lack of service availability.
Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.
