Occupancy After Foreclosure Any sale of the Mortgaged Property or any part thereof will divest all right, title and interest of Mortgagor in and to the property sold. Subject to applicable law, any purchaser at a foreclosure sale will receive immediate possession of the property purchased. If Mortgagor retains possession of such property or any part thereof subsequent to such sale, Mortgagor will be considered a tenant at sufferance of the purchaser, and will, if Mortgagor remains in possession after demand to remove, be subject to eviction and removal, forcible or otherwise, with or without process of law.
Upon Substantial Completion of the Work or designated portion thereof and upon application by the Contractor and certification by the Architect, the State shall make payment, reflecting adjustment in retainage, if any, for such Work or portion thereof, as provided in the Contract Documents.
Substantial Completion Date Substantial Completion of the Work as defined in Article 6.1.2 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by July 31, 2022.
Completion of Concrete Pours and Emergency Work (a) Except as provided in this sub-clause an Employee shall nor work or be required to work in the rain. (b) Employees shall not be required to start a concrete pour in Inclement Weather. (c) Where a concrete pour has been commenced prior to the commencement of a period of Inclement Weather Employees may be required to complete such concrete pour to a practical stage and for such work shall be paid at the rate of double time calculated to the next hour, and in the case of wet weather shall be provided with adequate wet weather gear. (d) If an Employee’s clothes become wet as a result of working in the rain during a concrete pour the Employee shall, unless the Employee has a change of dry working clothes available, be allowed to go home without loss of pay. (e) The provisions of clauses 32.7(c) and 32.7(d) hereof shall also apply in the case of emergency work where the Employees concerned and their delegates agree that the work is of an emergency nature and can start and/or proceed.
DATE OF COMMENCEMENT AND SUBSTANTIAL COMPLETION § 3.1 The date of commencement of the Work shall be: § 3.2 The Contract Time shall be measured from the date of commencement of the Work.
Substantial Completion 9.8.1 When the Contractor considers that the Work, or a designated portion thereof which has been accepted in writing to by the State, is substantially complete as defined in Subparagraph
Happen After We Receive Your Letter When we receive your letter, we must do two things:
Payment after Vesting Any Performance Shares that vest in accordance with paragraphs 3 through 4 will be paid to the Employee (or in the event of the Employee’s death, to his or her estate) in Shares as soon as practicable following the date of vesting, subject to paragraph 9, but in no event later than the applicable two and one-half (2 1/2) month period of the “short-term deferral” rule set forth in the Section 1.409A-1(b)(4) of the Treasury Regulations issued under Section 409A. Notwithstanding the foregoing, if the Performance Shares are “deferred compensation” within the meaning of Section 409A, the vested Performance Shares will be released to the Employee (or in the event of the Employee’s death, to his or her estate) in Shares as soon as practicable following the date of vesting, subject to paragraph 9, but in no event later than the end of the calendar year that includes the date of vesting or, if later, the fifteen (15th) day of the third (3rd) calendar month following the date of vesting (provided that the Employee will not be permitted, directly or indirectly, to designate the taxable year of the payment). Further, if some or all of the Performance Shares that are “deferred compensation” within the meaning of Section 409A vest on account of the Employee’s Termination of Service (other than due to death) in accordance with paragraphs 3 through 4, the Performance Shares that vest on account of the Employee’s Termination of Service will not be considered due or payable until the Employee has a “separation from service” within the meaning of Section 409A. In addition, if the Employee is a “specified employee” within the meaning of Section 409A at the time of the Employee’s separation from service (other than due to death), then any accelerated Performance Shares will be paid to the Employee no earlier than six (6) months and one (1) day following the date of the Employee’s separation from service unless the Employee dies following his or her separation from service, in which case, the Performance Shares will be paid to the Employee’s estate as soon as practicable following his or her death, subject to paragraph 9. Any Performance Shares that vest in accordance with paragraph 5 will be paid to the Employee (or in the event of the Employee’s death, to his or her estate) in Shares in accordance with the provisions of such paragraph, subject to paragraph 9. For each Performance Share that vests, the Employee will receive one Share.
Tax Periods Beginning Before and Ending After the Closing Date The Company or the Purchaser shall prepare or cause to be prepared and file or cause to be filed any Returns of the Company for Tax periods that begin before the Closing Date and end after the Closing Date. To the extent such Taxes are not fully reserved for in the Company’s financial statements, the Sellers shall pay to the Company an amount equal to the unreserved portion of such Taxes that relates to the portion of the Tax period ending on the Closing Date. Such payment, if any, shall be paid by the Sellers within fifteen (15) days after receipt of written notice from the Company or the Purchaser that such Taxes were paid by the Company or the Purchaser for a period beginning prior to the Closing Date. For purposes of this Section, in the case of any Taxes that are imposed on a periodic basis and are payable for a Taxable period that includes (but does not end on) the Closing Date, the portion of such Tax that relates to the portion of such Tax period ending on the Closing Date shall (i) in the case of any Taxes other than Taxes based upon or related to income or receipts, be deemed to be the amount of such Tax for the entire Tax period multiplied by a fraction the numerator of which is the number of days in the Tax period ending on the Closing Date and the denominator of which is the number of days in the entire Tax period (the “Pro Rata Amount”), and (ii) in the case of any Tax based upon or related to income or receipts, be deemed equal to the amount that would be payable if the relevant Tax period ended on the Closing Date. The Sellers shall pay to the Company with the payment of any taxes due hereunder, the Sellers’ Pro Rata Amount of the costs and expenses incurred by the Purchaser or the Company in the preparation and filing of the Tax Returns. Any net operating losses or credits relating to a Tax period that begins before and ends after the Closing Date shall be taken into account as though the relevant Tax period ended on the Closing Date. All determinations necessary to give effect to the foregoing allocations shall be made in a reasonable manner as agreed to by the parties.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
