Governing Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the laws of the State of New York. The section headings in this Agreement have been inserted as a matter of convenience of reference and are not a part of this Agreement.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Certain Matters of Construction The terms “herein,” “hereof,” “hereunder” and other words of similar import refer to this Agreement as a whole and not to any particular section, paragraph or subdivision. Any pronoun used shall be deemed to cover all genders. In the computation of periods of time from a specified date to a later specified date, “from” means “from and including,” and “to” and “until” each mean “to but excluding.” The terms “including” and “include” shall mean “including, without limitation” and, for purposes of each Loan Document, the parties agree that the rule of ejusdem generis shall not be applicable to limit any provision. Section titles appear as a matter of convenience only and shall not affect the interpretation of any Loan Document. All references to (a) laws or statutes include all related rules, regulations, interpretations, amendments and successor provisions; (b) any document, instrument or agreement include any amendments, waivers and other modifications, extensions or renewals (to the extent permitted by the Loan Documents); (c) any section mean, unless the context otherwise requires, a section of this Agreement; (d) any exhibits or schedules mean, unless the context otherwise requires, exhibits and schedules attached hereto, which are hereby incorporated by reference; (e) any Person include successors and assigns; (f) time of day mean time of day at Lenders’ notice addresses under Section 13.3.1; or (g) discretion of any Lender mean the sole and absolute discretion of such Person. All calculations of fundings of the Loans, and payments of Obligations shall be in Dollars and, unless the context otherwise requires, all determinations made from time to time under the Loan Documents shall be made in light of the circumstances existing at such time. Borrowers shall have the burden of establishing any alleged negligence, misconduct or lack of good faith by any Lender under any Loan Documents. No provision of any Loan Documents shall be construed against any party by reason of such party having, or being deemed to have, drafted the provision.
Covenants and Conditions; Construction of Agreement All provisions of this Lease to be observed or performed by Lessee are both covenants and conditions. In construing this Lease, all headings and titles are for the convenience of the Parties only and shall not be considered a part of this Lease. Whenever required by the context, the singular shall include the plural and vice versa. This Lease shall not be construed as if prepared by one of the Parties, but rather according to its fair meaning as a whole, as if both Parties had prepared it.
Law; Construction This Agreement and any claim, counterclaim or dispute of any kind or nature whatsoever arising out of or in any way relating to this Agreement (“Claim”), directly or indirectly, shall be governed by, and construed in accordance with, the internal laws of the State of New York.
Certain Constructions (a) For purposes of this Agreement, references to the most or next most subordinate Class of Pooled Regular Certificates outstanding at any time shall mean the most or next most subordinate Class of Pooled Regular Certificates then outstanding as among the Class A-1, Class A-2, Class A-3, Class A-4, Class A-AB, Class X-A, Class X-B, Class X-D, Class X-F, Class X-G, Class X-H, Class A-S, Class B, Class C, Class D, Class E, Class F, Class G, Class H, Class J-RR and Class K-RR Certificates; provided, however, that for purposes of determining the most subordinate Class of Pooled Regular Certificates, in the event that the Class A-1, Class A-2, Class A-3, Class A-4 and Class A-AB Certificates are the only Classes of Pooled Principal Balance Certificates outstanding, the Class A-1, Class A-2, Class A-3, Class A-4, Class A-AB and Class X-A Certificates together will be treated as the most subordinate Class of Pooled Regular Certificates. For purposes of this Agreement, each Class of Certificates (other than the Class S and Class R Certificates) shall be deemed to be outstanding only to the extent its respective Certificate Balance or Notional Amount has not been reduced to zero. For purposes of this Agreement, the Class R Certificates shall be deemed to be outstanding so long as the Trust REMICs have not been terminated pursuant to Section 9.01 of this Agreement.
(b) For purposes of this Agreement, except as otherwise expressly provided or unless the context otherwise requires:
(i) the terms defined in this Agreement include the plural as well as the singular, and the use of any gender herein shall be deemed to include the other gender;
(ii) references herein to “Articles”, “Sections”, “Subsections”, “Paragraphs” and other subdivisions without reference to a document are to designated Articles, Sections, Subsections, Paragraphs and other subdivisions of this Agreement;
Governing Law; Severability; Rules of Construction This Security Instrument is governed by federal law and the law of the State of Ohio. All rights and obligations contained in this Security Instrument are subject to any requirements and limitations of Applicable Law. If any provision of this Security Instrument or the Note conflicts with Applicable Law (i) such conflict will not affect other provisions of this Security Instrument or the Note that can be given effect without the conflicting provision, and (ii) such conflicting provision, to the extent possible, will be considered modified to comply with Applicable Law. Applicable Law might explicitly or implicitly allow the parties to agree by contract or it might be silent, but such silence should not be construed as a prohibition against agreement by contract. Any action required under this Security Instrument to be made in accordance with Applicable Law is to be made in accordance with the Applicable Law in effect at the time the action is undertaken. As used in this Security Instrument: (a) words in the singular will mean and include the plural and vice versa; (b) the word “may” gives sole discretion without any obligation to take any action; (c) any reference to “Section” in this document refers to Sections contained in this Security Instrument unless otherwise noted; and (d) the headings and captions are inserted for convenience of reference and do not define, limit, or describe the scope or intent of this Security Instrument or any particular Section, paragraph, or provision.
Conflict; Construction of Documents; Reliance In the event of any conflict between the provisions of this Agreement and any of the other Loan Documents, the provisions of this Agreement shall control. The parties hereto acknowledge that they were represented by competent counsel in connection with the negotiation, drafting and execution of the Loan Documents and that such Loan Documents shall not be subject to the principle of construing their meaning against the party which drafted same. Borrower acknowledges that, with respect to the Loan, Borrower shall rely solely on its own judgment and advisors in entering into the Loan without relying in any manner on any statements, representations or recommendations of Lender or any parent, subsidiary or Affiliate of Lender. Lender shall not be subject to any limitation whatsoever in the exercise of any rights or remedies available to it under any of the Loan Documents or any other agreements or instruments which govern the Loan by virtue of the ownership by it or any parent, subsidiary or Affiliate of Lender of any equity interest any of them may acquire in Borrower, and Borrower hereby irrevocably waives the right to raise any defense or take any action on the basis of the foregoing with respect to Lender’s exercise of any such rights or remedies. Borrower acknowledges that Lender engages in the business of real estate financings and other real estate transactions and investments which may be viewed as adverse to or competitive with the business of Borrower or its Affiliates.
Severability and Construction Nothing in this Agreement is intended to require or shall be construed as requiring the Company to do or fail to do any act in violation of applicable law. The Company’s inability, pursuant to a court order, to perform its obligations under this Agreement shall not constitute a breach of this Agreement. In addition, if any portion of this Agreement shall be held by a court of competent jurisdiction to be invalid, void, or otherwise unenforceable, the remaining provisions shall remain enforceable to the fullest extent permitted by applicable law. The parties hereto acknowledge that they each have opportunities to have their respective counsels review this Agreement. Accordingly, this Agreement shall be deemed to be the product of both of the parties hereto, and no ambiguity shall be construed in favor of or against either of the parties hereto.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
