Use of Project Development Security Buyer shall be entitled to draw upon the Project Development Security posted by Seller for Daily Delay Damages until such time as the Project Development Security is exhausted. Buyer shall also be entitled to draw upon the Project Development Security for any damages arising upon Buyer’s declaration of an Early Termination Date.
PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Assignment Liability Indemnity Force Majeure Consequential Damages and Default Notwithstanding any other provision of this Agreement, the liability, indemnification and insurance provisions of the Transmission Operating Agreement (“TOA”) or other applicable operating agreements shall apply to the relationship between the System Operator and the Interconnection Transmission Owner and the liability, indemnification and insurance provisions of the Tariff apply to the relationship between the System Operator and the Interconnection Customer and between the Interconnecting Transmission Owner and the Interconnection Customer.
Withdrawal of Property from Market or Termination of Discussions Potential Investor acknowledges that the Property has been offered for sale subject to withdrawal of the Property from the market at any time or rejection of any offer because of the terms thereof, or for any other reason whatsoever, without notice, as well as the termination of discussions with any party at any time without notice for any reason whatsoever.
WARRANTY OF CONTRACTOR’S ABILITY TO PERFORM The Contractor warrants that, to the best of its knowledge, there is no pending or threatened action, proceeding, or investigation, or any other legal or financial condition, that would in any way prohibit, restrain, or diminish the Contractor’s ability to satisfy its Contract obligations. The Contractor warrants that neither it nor any affiliate is currently on the Suspended Vendor List, Convicted Vendor List, or the Discriminatory Vendor List, or on any similar list maintained by any other state or the federal government. The Contractor shall immediately notify the Department in writing if its ability to perform is compromised in any manner during the term of the Contract. Information Technology Staff Augmentation Services Contract No. 80101507-21-STC-ITSA Contract Exhibit F Resume Self-Certification Form Contractor’s candidates shall complete this Resume Self-Certification Form. Completed Resume Self-Certification Forms shall be submitted within the Contractor’s response to Customer’s requests for quote. “I the undersigned do hereby certify, under the penalty of perjury, that information in my resume submitted for consideration of the State of Florida contract position is true, correct, complete, and made in good faith to the best of my knowledge and belief. If an omission, falsification, misstatement, or misrepresentation has been made regarding my education, work ability, experience, employment history, and/or fitness for employment as a contractor, I may be disqualified as a contractor, and the matter will be reported to appropriate agency or law enforcement personnel. I understand that there may be civil and/or criminal penalties for misrepresenting pertinent information in connection with contract positions, including, but not limited to, penalties available under sections 287.133 or 817.566, Florida Statutes. I further understand that if I am not a United States citizen, violation cases may be reported to the US Department of Homeland Security for potential deportation.” “In addition, I the undersigned do hereby consent to the release of my information by employers, educational institutions, law enforcement agencies, and other individuals and organizations to investigators and other authorized agents of Florida for verification and investigation purposes. I understand that any documents submitted to procure a contract(s) with the State of Florida, including resumes, are public records.” Print Full Legal Name of Candidate Candidate’s Signature Date Candidate’s Form of Identification Presented Identification number Contractor’s Witness Signature One Date Contractor’s Witness Signature Two Date Print Name Contractor’s Witness One Print Name Contractor’s Witness Two Information Technology Staff Augmentation Services Contract No. 80101507-21-STC-ITSA Contract Exhibit G Contractor Selection Justification Form Customers shall complete this Contractor Selection Justification Form for each candidate selected and attach all completed forms to the purchase order. Date: Contractor’s Name: _ Contractor’s Contact Information: Candidate’s Name: Address: _ Phone: _ Email: _ Date Candidate will be available: _ Hourly rate of candidate: $ Position candidate recommended for: _ Justification for selection of candidate: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Agency: Division/Section/Unit: _ Printed Name: _ Title: _ Signature _ Date: Information Technology Staff Augmentation Services Contract No. 80101507-21-STC-ITSA Contract Exhibit H Contractor Performance Survey Note: This is an example of the questions contained in the Contractor Performance Survey. The actual survey will be provided in electronic form. Customers shall complete this Contractor Performance Survey for each Contractor on a quarterly basis. Customers will electronically submit the completed Contractor Performance Survey(s) to the Department Contract Manager no later than the due date indicated the Scope of Work. Contractor's Name: Quarter: Purchase Order (PO) Number: PO Total $ Amount: PO Starting Date Ending Date Please review the attached Rating Definitions and provide your opinion by rating the following: Quality of Service
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
Copayments and annual out-of-pocket maximums For the first and second year of the contract: Tier 1 copayment: Fourteen dollar ($14) copayment per prescription or refill for a Tier 1 drug dispensed in a thirty (30) day supply. Tier 2 copayment: Twenty-five dollar ($25) copayment per prescription or refill for a Tier 2 drug dispensed in a thirty (30) day supply. Tier 3 copayment: Fifty dollar ($50) copayment per prescription or refill for a Tier 3 drug dispensed in a thirty (30) day supply. Out of pocket maximum: There is an annual maximum eligible out-of-pocket expense limit for prescription drugs of eight hundred dollars ($800) per person or one thousand six hundred dollars ($1,600) per family.
Transition from Existing Evaluation System A) The parties may agree that 50% of more of Educators in the district will be evaluated under the new procedures at the outset of this Agreement, and 50% or fewer will be evaluated under the former evaluation procedures for the first year of implementation of the new procedures in this Agreement.
Excuse for Nonperformance or Delayed Performance Except with respect to defaults of subcontractors, Contractor/Vendor shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure by Contractor/Vendor to make progress in the prosecution of the work hereunder which endangers such performance) if Contractor/Vendor has notified the Commission or designee within 15 days after the cause of the delay and the failure arises out of causes such as: acts of God; acts of the public enemy; acts of the State and any other governmental entity in its sovereign or contractual capacity; fires; floods; epidemics; quarantine restrictions; strikes or other labor disputes; freight embargoes; or unusually severe weather. If the failure to perform is caused by the failure of a subcontractor to perform or to make progress, and if such failure arises out of causes similar to those set forth above, Contractor/Vendor shall not be deemed to be in default, unless the services to be furnished by the subcontractor were reasonably obtainable from other sources in sufficient time to permit Contractor to meet the contract requirements. Upon request of Contractor, the Commission or designee shall ascertain the facts and extent of such failure, and, if such officer determines that any failure to perform was occasioned by any one or more of the excusable causes, and that, but for the excusable cause, Contractor’s progress and performance would have met the terms of the contract, the delivery schedule shall be revised accordingly, subject to the rights of the State under the clause entitled (in fixed-price contracts, “Termination for Convenience,” in cost-reimbursement contracts, “Termination”). (As used in this Paragraph of this clause, the term “subcontractor” means subcontractor at any tier).
