INDEMNIFICATION RELATING TO THIRD PARTY RIGHTS The Contractor will also indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs that may be finally assessed against the Authorized Users in any action for infringement of a United States Letter Patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims arise from the Authorized Users gross negligence or willful misconduct, provided that the State shall give Contractor: (i) prompt written notice of any action, claim or threat of infringement suit, or other suit, (ii) the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and (iii) assistance in the defense of any such action at the expense of Contractor. If usage shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue Usage (ii) to modify the service or Product so that Usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace said service or Product or part(s) thereof, as applicable, with non-infringing service or Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided the Authorized User is given a refund for any amounts paid for the period during which Usage was not feasible. The foregoing provisions as to protection from third party rights shall not apply to any infringement occasioned by modification by the Authorized User of any Product without Contractor’s approval. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the service or Product under the Contract infringes any patent, copyright or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract. Contractor shall in such event protect the interests of the Authorized User and secure a continuance to permit the Authorized User to appear and defend its interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
Claims relating to Intellectual Property Rights 29.1. The Contractor must not infringe any Intellectual Property Rights of any third party in providing the Services or otherwise performing its obligations under the Framework Agreement and must ensure that the provision of the Services and the use or possession of the Deliverables does not infringe such Intellectual Property Rights.
29.2. The Contractor must promptly notify the Authority if any claim or demand is made or action brought against the Contractor for infringement or alleged infringement of any Intellectual Property Right which may affect the use or possession of the Deliverables or which may affect the provision of the Services.
29.3. Where a claim to which this clause applies is made, the Contractor must, at its expense, use its best endeavours to:
29.3.1. modify the Services or Deliverables or substitute alternative Services or Deliverables (in any case without reducing performance or functionality) so as to avoid the infringement or alleged infringement of the Intellectual Property Rights; or
29.3.2. procure the grant of a licence or licences from the pursuer, claimant or complainer, on terms acceptable to the Authority, so as to avoid the infringement or alleged infringement of the Intellectual Property Rights of the pursuer, claimant or complainer.
29.4. The Contractor must not without the consent of the Authority make any admissions which may be prejudicial to the defence or settlement of any claim to which this clause applies.
INDEMNIFICATION RELATING TO INFRINGEMENT The Contractor will also defend, indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs in any action for infringement of a patent, copyright, trademark, trade secret or other proprietary right provided: a) such claim arises solely out of the Products as supplied by the Contractor, and not out of any modification to the Products made by Authorized User or by someone other than Contractor at the direction of the Authorized User without Contractor’s approval, or by reason of an off-the-shelf component; and b) Authorized User gives Contractor prompt written notice of any such action, claim suit or threat of suit alleging infringement. The Authorized User shall give Contractor the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and to provide assistance in the defense of any such action, claim or suit at the expense of Contractor. Such indemnity shall only be applicable in the event of claims, judgments, liabilities and/or costs that may be finally assessed against Authorized User in any action for infringement of a patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims, judgments, liabilities and/or costs arise solely from the Authorized Users negligent act, failure to act, gross negligence or willful misconduct. If usage of a Product shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue usage (ii) to modify the service or Product so that usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace such Product or parts thereof, as applicable, with non-infringing Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided that the Authorized User is given a refund for any amounts paid for the period during which usage was not feasible. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the Product under the Contract infringes any patent, copyright, trademark, trade secret or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract and to what extent it is not so obligated to defend and indemnify. Contractor shall in such event protect the interests of the Authorized User and seek to secure a continuance to permit the Authorized User to appear and defend their interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
Covenants Relating to Rule 144 For so long as the Company is subject to the reporting requirements of Section 13 or 15 of the Securities Act, the Company covenants that it will file the reports required to be filed by it under the Securities Act and Section 13(a) or 15(d) of the Exchange Act and the rules and regulations adopted by the Commission thereunder. If the Company ceases to be so required to file such reports, the Company covenants that it will upon the request of any Holder of Registrable Securities (a) make publicly available such information as is necessary to permit sales pursuant to Rule 144 under the Securities Act, (b) deliver such information to a prospective purchaser as is necessary to permit sales pursuant to Rule 144A under the Securities Act and it will take such further action as any Holder of Registrable Securities may reasonably request, and (c) take such further action that is reasonable in the circumstances, in each case, to the extent required, from time to time, to enable such Holder to sell its Registrable Securities without registration under the Securities Act within the limitation of the exemptions provided by (i) Rule 144 under the Securities Act, as such Rule may be amended from time to time, (ii) Rule 144A under the Securities Act, as such rule may be amended from time to time, or (iii) any similar rules or regulations hereafter adopted by the Commission. Upon the request of any Holder of Registrable Securities, the Company will deliver to such Holder a written statement as to whether it has complied with such requirements and of the Securities Act and the Exchange Act (at any time after it has become subject to the reporting requirements of the Exchange Act), a copy of the most recent annual and quarterly report(s) of the Company, and such other reports, documents or stockholder communications of the Company, and take such further actions consistent with this Section 8(a), as a Holder may reasonably request in availing itself of any rule or regulation of the Commission allowing a Holder to sell any such Registrable Securities without registration.
Certain Rules Relating to the Payment of Additional Amounts (a) If any Affected Person requests compensation under Section 5.01, or if the Borrower is required to pay any additional amount to any Affected Person or to any Governmental Authority for the account of any Affected Person pursuant to Section 5.03, then such Affected Person shall (at the request of the Borrower) use commercially reasonable efforts to designate a different lending office for funding or booking the related Loans hereunder or to assign and delegate (or cause to be assigned and delegated) such Affected Person’s rights and obligations hereunder to another office, branch or Affiliate of such Affected Person if, in the judgment of such Affected Person, such designation or assignment (i) would eliminate or reduce amounts payable pursuant to Section 5.01 or 5.03, as the case may be, in the future and (ii) would not subject such Affected Person to any unreimbursed cost or expense and would not otherwise be disadvantageous to such Affected Person. The Borrower hereby agrees to pay all reasonable out of pocket costs and expenses incurred by any Affected Person in connection with any such designation or assignment and delegation.
(b) If (i) any Affected Person requests compensation under Section 5.01, (ii) the Borrower is required to pay any additional amount to any Affected Person or any Governmental Authority for the account of any Affected Person pursuant to Section 5.03, (iii) any Affected Person has become a Defaulting Lender or (iv) any Affected Person has failed to consent to a proposed amendment, waiver, discharge or termination that requires the consent of all Lenders and with respect to which the other Lenders shall have or would have granted their consent, then the Borrower may, at its sole expense and effort, upon notice to the Administrative Agent, require the Administrative Agent to cause the related Affected Person to assign and delegate, without recourse (in accordance with and subject to all applicable transfer restrictions), all its interests, rights and obligations under this Agreement and the other Transaction Documents to another appropriate Person (which, in the case of a Lender, shall be an Eligible Assignee) that shall acquire such interest or assume such commitment; provided that (a) the Borrower shall have received the prior written consent of the Administrative Agent and the other Lenders, which consent shall not unreasonably be withheld, (b) such Affected Person, if a Lender, shall have received payment of an amount equal to its outstanding Capital and, if applicable, accrued Interest and Fees thereon and all other amounts then owing to it hereunder from the assignee or the Borrower, (c) in the case of any such assignment and delegation resulting from a claim for compensation under Section 5.01 or payments required to be made pursuant to Section 5.03, such assignment is expected to result in a reduction in such compensation or payments for future periods and (d) in the case of any such assignment and delegation resulting from the failure of an Affected Person to provide a consent, the assignee shall have given such consent and, as a result of such assignment and delegation and any contemporaneous assignments and delegations and consents, the applicable amendment, waiver, discharge or termination can be effected. An Affected Person shall not be required to make any such assignment and delegation if, prior thereto, as a result of a waiver or consent by such Affected Person or otherwise, the circumstances entitling the Borrower to require such assignment and delegation have ceased to apply.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Covenants Relating to Conduct of Business (a) Except for matters set forth in Schedule 4.01 or otherwise expressly permitted by the terms of this Agreement, from the date hereof to the Closing, each Parent Party shall cause its respective Existing Business to be conducted in the usual, regular and ordinary course in substantially the same manner as previously conducted (including with respect to advertising, promotions, capital expenditures and inventory levels) and use all reasonable efforts to keep intact the respective businesses of such Parent Party's Existing Business, keep available the services of their current employees and preserve their relationships with customers, suppliers, licensors, licensees, distributors and others with whom they deal to the end that their respective businesses shall be unimpaired at the Closing. Each Parent Party shall not, and shall not permit any of its Affiliates to, take any action that would, or that could reasonably be expected to, result in any of the conditions set forth in Article V not being satisfied. In addition (and without limiting the generality of the foregoing), except as set forth in Schedule 4.01 or otherwise expressly permitted or required by the terms of this Agreement, each Parent Party shall not, and shall not permit any of its Affiliates to, do any of the following in connection with its Existing Business without the prior written consent of the other Parent Party:
(i) with respect to any of its Contributed Subsidiaries, amend its Organizational Documents, except as is necessary to consummate the Transactions;
(ii) other than sweeping cash in the ordinary course of business consistent with past practice, make any declaration or payment of any dividend or any other distribution in respect of its equity interest in any Contributed Subsidiary;
(iii) with respect to any of its Contributed Subsidiaries, redeem or otherwise acquire any shares of its capital stock or issue any capital stock (except upon the exercise of outstanding options) or any option, warrant or right relating thereto or any securities convertible into or exchangeable for any shares of such capital stock;
(iv) incur or assume any indebtedness for borrowed money or guarantee any such indebtedness in connection with its Existing Business;
(v) permit, allow or suffer any Contributed Assets to become subjected to any Lien of any nature whatsoever, except Permitted Liens;
(vi) cancel any material indebtedness (individually or in the aggregate) or waive any claims or rights of substantial value relating to its Existing Business;
(vii) except for intercompany loans among Contributed Subsidiaries in the ordinary course of business or transactions in the ordinary course, consistent with past practice and not material in amount, pay, loan or advance any amount to, or sell, transfer or lease any of its assets to, or enter into any agreement or arrangement with any of its Affiliates;
(viii) make any change in any method of financial accounting or financial accounting practice or policy of its Existing Business other than those required by generally accepted accounting principles;
(ix) make any change in the methods or timing of collecting receivables or paying payables with respect to its Existing Business;
(x) other than in the ordinary course of business, make or incur any capital expenditure in connection with its Existing Business that is not currently approved in writing or budgeted;
(xi) sell, lease, license or otherwise dispose of any of the assets of its Existing Business, except inventory, programming or other goods or services sold in the ordinary course of business consistent with past practice; or
(xii) authorize any of, or commit or agree to take, whether in writing or otherwise, to do any of, the foregoing actions.
(b) Except as set forth in Schedule 4.01 or otherwise expressly permitted by the terms of this Agreement or any ancillary agreements that may be entered into in connection with the Transactions, USAi shall not, and shall not permit any of its Affiliates to:
(i) adopt or amend any USAi Benefit Arrangement (or any plan or arrangement that would be an USAi Benefit Arrangement if adopted) relating primarily to its Existing Business or enter into, adopt, extend (beyond the Closing Date), renew or amend any collective bargaining agreement or other Contract relating to its Existing Business with any labor organization, union or association, except in each case, in the ordinary course of business and consistent with past practice or as required by Applicable Law; or
(ii) (A) grant to any USAi Business Employee any increase in compensation or benefits, except grants in the ordinary course of business and consistent with past practice or as may be required under agreements in existence on the date of this Agreement or (B) grant new options or restricted stock to any USAi Business Employee except as may be required under agreements in existence on the date of this Agreement.
(c) Each Parent Party shall promptly advise the other Parent Party in writing of the occurrence of any matter or event that is material to the business, assets, financial condition, or results of operations of its Existing Business, taken as a whole.
(d) Notwithstanding any other provision of this Agreement, following the date hereof, each Parent Party shall manage its cash (including any sweeps thereof), payables and receivables relating to its Existing Business in each case in the ordinary course of business and consistent with past practice.
Other Matters Relating to the Servicer The Servicer is hereby authorized and empowered to:
(a) advise the Trustee in connection with the amount of withdrawals from Accounts in accordance with the provisions of this Indenture;
(b) execute and deliver, on behalf of the Issuer, any and all instruments of satisfaction or cancellation, or of partial or full release or discharge, and all other comparable instruments, with respect to the Pledged Loans and, after the delinquency of any Pledged Loan and to the extent permitted under and in compliance with applicable law and regulations, to commence enforcement proceedings with respect to such Pledged Loan including without limitation the exercise of rights under any power-of-attorney granted in any Pledged Loan; and
(c) make any filings, reports, notices, applications, registrations with, and to seek any consents or authorizations from the Securities and Exchange Commission and any state securities authority on behalf of the Issuer as may be necessary or advisable to comply with any federal or state securities or reporting requirements laws. Prior to the occurrence of an Event of Default hereunder, the Trustee agrees that it shall promptly follow the instructions of the Servicer duly given to withdraw funds from the Accounts.
Returning to Work (a) Returning to work early
(i) During the period of parental leave an Employee may return to work at any time as agreed between the Employer and the Employee, provided that time does not exceed four weeks from the recommencement date desired by the Employee.
(ii) In the case of adoption, where the placement of an eligible child with an Employee does not proceed or continue, the Employee will notify the Employer immediately and the Employer will nominate a time not exceeding four weeks from receipt of notification for the Employee’s return to work.
(b) Returning to work at conclusion of leave
(i) At least four weeks prior to the expiration of parental leave, the Employee will notify the Employer of their return to work after a period of parental leave.
(ii) Subject to 51.23(b)(iii), an Employee will be entitled to the position which they held immediately before proceeding on parental leave. In the case of an Employee transferred to a safe job pursuant to clause 51.12 above, the Employee will be entitled to return to the position they held immediately before such transfer.
(iii) Where such position no longer exists but there are other positions available which the Employee is qualified for and is capable of performing, the Employee will be entitled to a position as nearly comparable in status and pay to that of their former position.
(c) Returning to work at a reduced time fraction
(i) To assist an Employee in reconciling work and parental responsibilities, an Employee may request to return to work at a reduced time-fraction until their Child reaches school age, after which the Employee will resume their substantive time-fraction.
(ii) Where an Employee wishes to make a request under 51.23(c)(i) such a request must be made as soon as possible but no less than seven weeks prior to the date upon which the Employee is due to return to work from parental leave.
