PAYMENT AND INVOICE PROVISIONS An itemized invoice addressed to the ordering entity shall reference purchase order number, contract number, quantity, description, list and net unit price. Installation/Labor and any other ancillary charges will be shown as a separate line item on all quotes and invoices. Payment will be made in accordance with applicable State of Arkansas accounting procedures upon acceptance by the Agency. The State may not be invoiced in advance of delivery and acceptance of any commodity. Payment will be made only after the contractor has successfully satisfied the state agency as to the goods purchased. Contractor should invoice agency by an itemized list of charges. Purchase Order Number and/or Contract Number should be referenced on each invoice.
Invoice Disputes If you believe any delivered software or service does not conform to the warranties in this Agreement, you will provide us with written notice within thirty (30) days of your receipt of the applicable invoice. The written notice must contain reasonable detail of the issues you contend are in dispute so that we can confirm the issue and respond to your notice with either a justification of the invoice, an adjustment to the invoice, or a proposal addressing the issues presented in your notice. We will work with you as may be necessary to develop an action plan that outlines reasonable steps to be taken by each of us to resolve any issues presented in your notice. You may withhold payment of the amount(s) actually in dispute, and only those amounts, until we complete the action items outlined in the plan. If we are unable to complete the action items outlined in the action plan because of your failure to complete the items agreed to be done by you, then you will remit full payment of the invoice. We reserve the right to suspend delivery of all SaaS Services, including maintenance and support services, if you fail to pay an invoice not disputed as described above within fifteen (15) days of notice of our intent to do so.
Outage Schedules The Connecting Transmission Owner shall post scheduled outages of its transmission facilities on the NYISO OASIS. Developer shall submit its planned maintenance schedules for the Large Generating Facility to Connecting Transmission Owner and NYISO for a minimum of a rolling thirty-six month period. Developer shall update its planned maintenance schedules as necessary. NYISO may direct, or the Connecting Transmission Owner may request, Developer to reschedule its maintenance as necessary to maintain the reliability of the New York State Transmission System. Compensation to Developer for any additional direct costs that the Developer incurs as a result of rescheduling maintenance, including any additional overtime, breaking of maintenance contracts or other costs above and beyond the cost the Developer would have incurred absent the request to reschedule maintenance, shall be in accordance with the ISO OATT. Developer will not be eligible to receive compensation, if during the twelve (12) months prior to the date of the scheduled maintenance, the Developer had modified its schedule of maintenance activities other than at the direction of the NYISO or request of the Connecting Transmission Owner.
Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Residence Life or the Director’s designee.
Unbundled Voice Loops (UVLs) 2.2.1 BellSouth shall make available the following UVLs:
DISTRIBUTION OF CONTRACTOR PRICE LIST AND CONTRACT APPENDICES Contractor shall provide Authorized Users with electronic copies of the Contract, including price lists and Appendices, upon request. Contract Updates will be handled as provided in Appendix C – Contract Modification Procedures.
Contract Schedule The information set forth in the Contract Schedule is true and correct.
Contract Modifications It is understood that changes are inherent in operations of the type covered by this contract. The number of changes, the scope of those changes, and the impact they have on the progress of the original operations cannot be defined at this time. The PURCHASER is notified that changes are anticipated and that there will be no compensation made to the PURCHASER directly related to the number of changes made. Each change will be evaluated for extension of contract time and increase or decrease in compensation based on its own merit. STATE reserves the right to make, at any time during the contract, such modifications as are necessary or desirable; provided such modifications shall not change the character of the operations to be done nor increase the cost, unless such operations or cost increase is approved in writing by PURCHASER. Any modifications so made shall not invalidate this contract nor release PURCHASER of obligations under the performance bond. PURCHASER agrees to do the modified operations as if it had been a part of the original contract. If any change under this section causes an increase or decrease in the PURCHASER's cost of, or the time required for the performance of any part of the operations, the PURCHASER must submit a written statement setting forth the nature and specific extent of the claim. Such claim shall include all time and cost impacts against the contract and be submitted as soon as possible, but no later than 30 days after receipt of any written notice of modification of the contract. If the PURCHASER discovers site conditions which differ materially from what was represented in the contract or from conditions that would normally be expected to exist and be inherent to the activities defined in the contract, the PURCHASER shall notify the STATE's Authorized Representative immediately and before the area has been disturbed. The STATE's Authorized Representative will investigate the area and make a determination as to whether or not the conditions differ materially from either the conditions stated in the contract or those which could reasonably be expected in execution of this particular contract. If it is determined that a differing site condition exists, any compensation or credit will be determined based on an analysis by STATE's Authorized Representative. If the PURCHASER does not concur with the decision of the STATE's Authorized Representative and/or believes that it is entitled to additional compensation, the PURCHASER may proceed to file a claim. All claims shall be submitted in writing and shall include a detailed, factual statement of the basis of the claim, pertinent dates, contract provisions which support or allow the claim, reference to or copies of any documents which support the claim, the exact dollar value of the claim, and specific time extension requested for the claim. If the claim involves operations to be completed by subcontractors, the PURCHASER will analyze and evaluate the merits of the subcontractor's claim. PURCHASER shall forward the subcontractor's claim and PURCHASER's evaluation of such claim to STATE's Authorized Representative. The STATE's Authorized Representative will not consider direct claims from subcontractors, suppliers, manufacturers, or others not a party to this contract. The decision of the STATE shall be final and binding unless the PURCHASER requests mediation.
Additional Submissions – Information Access The claimant shall then have the opportunity to submit written comments, documents, records and other information relating to the claim. The Plan Administrator shall also provide the claimant, upon request and free of charge, reasonable access to, and copies of, all documents, records and other information relevant (as defined in applicable ERISA regulations) to the claimant’s claim for benefits.
END USER AGREEMENTS (“EUA GAC acknowledges that the END USER may choose to enter into an End User Agreement (“EUA) with the Contractor through this Agreement, and that the term of the EUA may exceed the term of the current H-GAC Agreement. H-GAC’s acknowledgement is not an endorsement or approval of the End User Agreement’s terms and conditions. Contractor agrees not to offer, agree to or accept from the END USER, any terms or conditions that conflict with those in Contractor’s Agreement with H-GAC. Contractor affirms that termination of its Agreement with H-GAC for any reason shall not result in the termination of any underlying EUA, which shall in each instance, continue pursuant to the EUA’s stated terms and duration. Pursuant to the terms of this Agreement, termination of this Agreement will disallow the Contractor from entering into any new EUA with END USERS. Applicable H-GAC order processing charges will be due and payable to H-GAC
