Warranty Claim Validation Sample Clauses

Warranty Claim Validation. (i) Seller may require return of a reasonable quantity of Cells and/or inspect Cells which are subject to a warranty claim in order to validate the basis for such claim. Seller may decline warranty coverage for any Cells which are disassembled by Tesla or anyone acting on Tesla’s behalf if Seller has not consented to such disassembly. (ii) Tesla shall use Commercially Reasonable Efforts to support Seller’s validation of the basis for a warranty claim hereunder, and the Parties shall discuss the warranty claim in good faith. (iii) In the event of a disagreement or dispute as to the basis for a warranty claim with respect to Cells, the Parties will designate by mutual agreement a third party that will make the technical determination of the existence of a basis for the warranty claim and whether such claim is based on a breach of one or more warranties in Section 5.1 above. (iv) Cell(s) will be a “Non-Conforming Item(s)” if and to the extent that the Cell(s) fail to conform to one or more applicable warranties. Tesla and Seller will work together in good faith to evaluate, [***], whether the Cell(s) meet all applicable warranties. If the results if any such evaluation are inconclusive, the Parties shall [***]. Certain identified information has been omitted from this document because it is not material and would be competitively harmful if publicly disclosed, and has been marked with “[***]” to indicated where omissions have been made.
Sample 1
AutoNDA by SimpleDocs

Related to Warranty Claim Validation

  • Warranty Claims 8.1 The Supplier shall be obliged to inspect the quantity and the quality of the goods before delivery. 8.2 We shall have no duty to inspect the goods nor to notify any detected defects within a specific time period. In any event, a warranty claim will be timely made if raised prior to the expiration of the warranty period set forth in sub- clause 8.7 hereof. 8.3 We are entitled to demand, at our discretion, that the Supplier either replace defective goods or remedy the defect. The Supplier may only refuse the form of supplementary performance we have chosen on the grounds of dispropor- tionate cost where such costs would exceed the value of the goods in defect-free condition. 8.4 The Supplier warrants that the supplied goods are free of any fault or defect, whether of design, workmanship or materials. 8.5 Where supplementary performance fails, we are entitled to withdraw from the contract according to applicable law. Supplementary performance shall be deemed to have failed after one unsuccessful attempt, provided that the type of product or defect does not indicate that we are required to accept a further attempt at supplementary perfor- xxxxx. 8.6 We are entitled to remedy defects ourselves or to have them remedied at the expense of the Supplier, or to under- take shortfall purchases, where exigency or particular urgency applies and it is no longer possible to notify the Sup- plier with a deadline because of such particular urgency. 8.7 The Supplier shall be liable for any breach of the warranties if, within 18 months after the delivery date, we give no- xxxx in writing to the Supplier of any defect in the goods which shall arise from faulty design, materials or xxxxxxx- ship. This warranty period starts upon delivery of the goods and shall be suspended while the Supplier attempts supplementary performance. With respect to replaced or repaired goods, a new warranty period shall commence upon delivery of the replaced or repaired goods. 8.8 We expressly reserve the right to claim damages under applicable law. Warranty disclaimers and/or limitations of li- ability on the part of the Supplier do not apply. The foregoing warranties shall be without prejudice to any other rights and remedies available to us. 8.9 The Supplier indemnifies and holds us harmless against third party claims in connection with defective, delayed or in other manners faulty delivery, including court and attorney fees.

  • Third Party Claim Procedures In the case of any claim asserted by a third party (a “Third Party Claim”) against a party entitled to indemnification under this Agreement (an “Indemnified Party”), notice shall be given by the Indemnified Party to the party required to provide indemnification (the “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of such Third Party Claim, and the Indemnified Party shall permit the Indemnifying Party (at the expense of such Indemnifying Party and so long as the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party for Losses related to such Third Party Claim) to assume the defense of such Third Party Claim, provided that (a) counsel for the Indemnifying Party who shall conduct the defense of such Third Party Claim shall be reasonably satisfactory to the Indemnified Party, and the Indemnified Party may participate in such defense at such Indemnified Party’s expense, and (b) the failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligation under this Agreement except to the extent that such failure results in a lack of actual notice to the Indemnifying Party and such Indemnifying Party is materially prejudiced as a result of such failure to be given notice. If the Indemnifying Party does not promptly assume the defense of such Third Party Claim following notice thereof, the Indemnified Party shall be entitled to assume and control such defense and to settle or agree to pay in full such Third Party Claim without the consent of the Indemnifying Party without prejudice to the ability of the Indemnified Party to enforce its claim for indemnification against the Indemnifying Party hereunder. Except with the prior written consent of the Indemnified Party, no Indemnifying Party, in the defense of any such Third Party Claim, shall consent to entry of any judgment or enter into any settlement that provides for injunctive or other nonmonetary relief affecting the Indemnified Party or that does not include as an unconditional term thereof the giving by each claimant or plaintiff to such Indemnified Party of an irrevocable release from all liability and wrongdoing with respect to such Third Party Claim. Seller and Buyers shall cooperate in the defense of any Third Party Claim subject to this Article IX and the records of each shall be reasonably available to the other with respect to such defense.

  • Breach of Contract Claims [Option (Include if University prefers an abbreviated Breach of Contract Claims provision): To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.] 19.1 To the extent that Chapter 2260, Texas Government Code, as it may be amended from time to time (Chapter 2260), is applicable to this Agreement and is not preempted by other Applicable Laws, the dispute resolution process provided for in Chapter 2260 will be used, as further described herein, by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor: 12.19.1.1 Contractor’s claims for breach of this Agreement that the parties cannot resolve pursuant to other provisions of this Agreement or in the ordinary course of business will be submitted to the negotiation process provided in subchapter B of Chapter 2260. To initiate the process, Contractor will submit written notice, as required by subchapter B of Chapter 2260, to University in accordance with the notice provisions in this Agreement. Contractor's notice will specifically state that the provisions of subchapter B of Chapter 2260 are being invoked, the date and nature of the event giving rise to the claim, the specific contract provision that University allegedly breached, the amount of damages Contractor seeks, and the method used to calculate the damages. Compliance by Contractor with subchapter B of Chapter 2260 is a required prerequisite to Contractor's filing of a contested case proceeding under subchapter C of Chapter 2260. The chief business officer of University, or another officer of University as may be designated from time to time by University by written notice to Contractor in accordance with the notice provisions in this Agreement, will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. 12.19.1.2 If the parties are unable to resolve their disputes under Section 12.19.1.1, the contested case process provided in subchapter C of Chapter 2260 is Contractor’s sole and exclusive process for seeking a remedy for any and all of Contractor's claims for breach of this Agreement by University. 12.19.1.3 Compliance with the contested case process provided in subchapter C of Chapter 2260 is a required prerequisite to seeking consent to xxx from the Legislature under Chapter 107,

  • Notice of Loss; Third Party Claims (a) An Indemnified Party shall give the Indemnifying Party notice of any matter that an Indemnified Party has determined has given or could give rise to a right of indemnification under this Agreement, within thirty (30) days of such determination, stating the amount of the Loss, if known, and method of computation thereof, and containing a reference to the provisions of this Agreement in respect of which such right of indemnification is claimed or arises. (b) If an Indemnified Party shall receive notice of any Action, audit, demand or assessment (each, a “Third Party Claim”) against it or which may give rise to a claim for a Loss under this Article VIII, within thirty (30) days of the receipt of such notice, the Indemnified Party shall give the Indemnifying Party notice of such Third Party Claim; provided, however, that the failure to provide such notice shall not release the Indemnifying Party from any of its obligations under this Article VIII except to the extent that the Indemnifying Party is materially prejudiced by such failure and shall not relieve the Indemnifying Party from any other obligation or liability that it may have to any Indemnified Party otherwise than under this Article VIII. If the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party hereunder against any Losses that may result from such Third Party Claim, then the Indemnifying Party shall be entitled to assume and control the defense of such Third Party Claim at its expense and through counsel of its choice if it gives notice of its intention to do so to the Indemnified Party within five (5) days of the receipt of notice from the Indemnified Party of such Third Party Claim; provided, however, that if there exists or is reasonably likely to exist a conflict of interest that would make it inappropriate in the judgment of the Indemnified Party in its sole and absolute discretion for the same counsel to represent both the Indemnified Party and the Indemnifying Party, then the Indemnified Party shall be entitled to retain its own counsel in each jurisdiction for which the Indemnified Party determines counsel is required, at the expense of the Indemnifying Party. In the event that the Indemnifying Party exercises the right to undertake any such defense against any such Third Party Claim as provided above, the Indemnified Party shall cooperate with the Indemnifying Party in such defense and make available to the Indemnifying Party, at the Indemnifying Party’s expense, all witnesses, pertinent records, materials and information in the Indemnified Party’s possession or under the Indemnified Party’s control relating thereto as is reasonably required by the Indemnifying Party. Similarly, in the event the Indemnified Party is, directly or indirectly, conducting the defense against any such Third Party Claim, the Indemnifying Party shall cooperate with the Indemnified Party in such defense and make available to the Indemnified Party, at the Indemnifying Party’s expense, all such witnesses, records, materials and information in the Indemnifying Party’s possession or under the Indemnifying Party’s control relating thereto as is reasonably required by the Indemnified Party. No such Third Party Claim may be settled by the Indemnifying Party without the prior written consent of the Indemnified Party.

  • Indemnification Procedure for Third Party Claims (a) In the event that any party (the “Indemnified Person”) desires to make a claim against any other party (the “Indemnifying Person”) in connection with any Losses for which the Indemnified Person may seek indemnification hereunder in respect of a claim or demand made by any Person not a party to this Agreement against the Indemnified Person (a “Third-Party Claim”), such Indemnified Person must notify the Indemnifying Person in writing, of the Third-Party Claim (a “Third-Party Claim Notice”) as promptly as reasonably possible after receipt, but in no event later than fifteen (15) calendar days after receipt, by such Indemnified Person of notice of the Third-Party Claim; provided, that failure to give a Third-Party Claim Notice on a timely basis shall not affect the indemnification provided hereunder except to the extent the Indemnifying Person shall have been actually and materially prejudiced as a result of such failure. Upon receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall be entitled, at the Indemnifying Person’s election, to assume or participate in the defense of any Third-Party Claim at the cost of Indemnifying Person. In any case in which the Indemnifying Person assumes the defense of the Third-Party Claim, the Indemnifying Person shall give the Indemnified Person ten (10) calendar days’ notice prior to executing any settlement agreement and the Indemnified Person shall have the right to approve or reject the settlement and related expenses; provided, however, that upon rejection of any settlement and related expenses, the Indemnified Person shall assume control of the defense of such Third-Party Claim and the liability of the Indemnifying Person with respect to such Third-Party Claim shall be limited to the amount or the monetary equivalent of the rejected settlement and related expenses. (b) The Indemnified Person shall retain the right to employ its own counsel and to discuss matters with the Indemnifying Person related to the defense of any Third-Party Claim, the defense of which has been assumed by the Indemnifying Person pursuant to Section 10.3(a) of this Agreement, but the Indemnified Person shall bear and shall be solely responsible for its own costs and expenses in connection with such participation; provided, however, that, subject to Section 10.3(a) above, all decisions of the Indemnifying Person shall be final and the Indemnified Person shall cooperate with the Indemnifying Person in all respects in the defense of the Third-Party Claim, including refraining from taking any position adverse to the Indemnifying Person. (c) If the Indemnifying Person fails to give notice of the assumption of the defense of any Third-Party Claim within a reasonable time period not to exceed forty-five (45) days after receipt of the Third-Party Claim Notice from the Indemnified Person, the Indemnifying Person shall no longer be entitled to assume (but shall continue to be entitled to participate in) such defense. The Indemnified Person may, at its option, continue to defend such Third-Party Claim and, in such event, the Indemnifying Person shall indemnify the Indemnified Person for all reasonable fees and expenses in connection therewith (provided it is a Third-Party Claim for which the Indemnifying Person is otherwise obligated to provide indemnification hereunder). The Indemnifying Person shall be entitled to participate at its own expense and with its own counsel in the defense of any Third-Party Claim the defense of which it does not assume. Prior to effectuating any settlement of such Third-Party Claim, the Indemnified Person shall furnish the Indemnifying Person with written notice of any proposed settlement in sufficient time to allow the Indemnifying Person to act thereon. Within fifteen (15) days after the giving of such notice, the Indemnified Person shall be permitted to effect such settlement unless the Indemnifying Person (a) reimburses the Indemnified Person in accordance with the terms of this Article 10 for all reasonable fees and expenses incurred by the Indemnified Person in connection with such Claim; (b) assumes the defense of such Third-Party Claim; and (c) takes such other actions as the Indemnified Person may reasonably request as assurance of the Indemnifying Person’s ability to fulfill its obligations under this Article 10 in connection with such Third-Party Claim.

  • Claim of Infringement In the event that use of any facilities or equipment (including software), becomes, or in the reasonable judgment of the Party who owns the affected network is likely to become, the subject of a claim, action, suit, or proceeding based on intellectual property infringement, then said Party shall promptly and at its sole expense and sole option, but subject to the limitations of liability set forth below: 9.4.1 modify or replace the applicable facilities or equipment (including software) while maintaining form and function, or 9.4.2 obtain a license sufficient to allow such use to continue. 9.4.3 In the event 9.4.1 or 9.4.2 are commercially unreasonable, then said Party may, terminate, upon reasonable notice, this contract with respect to use of, or services provided through use of, the affected facilities or equipment (including software), but solely to the extent required to avoid the infringement claim.

  • Product Claims The parties acknowledge that NCR Voyix, not Apple, is responsible for addressing any claims you or any third party relating to the Software or your possession and/or use of the Software, including, but not limited to: (a) product liability claims; (b) any claim that the Software fails to conform to any applicable legal or regulatory requirement; and (c) claims arising under consumer protection or similar legislation.

  • Defense of Infringement Claims In the event Licensee or Licensor becomes aware that Licensee’s or any of its Affiliates’ or any Sublicensees’ practice of the Licensed Patents is the subject of a claim for patent infringement by a Third Party, that Party shall promptly notify the other, and the Parties shall consider the claim and the most appropriate action to take. Licensee shall cause each of its Affiliates and each Sublicensee to notify Licensee promptly in the event such entity becomes aware that its practice of the Licensed Patents is the subject of a claim of patent infringement by another. To the extent Licensor takes any action, Licensor (or the ReGenX Licensors) shall have the right to require Licensee’s reasonable cooperation in any such suit, upon written notice to Licensee; and Licensee shall have the obligation to participate upon Licensor’s request, in which event, Licensor shall bear the cost of Licensee’s participation. Without Licensor’s prior written permission, Licensee must not settle or compromise any such suit in a manner that imposes any material obligations or restrictions on Licensor or the ReGenX Licensors or grants any rights to the Licensed Patents other than rights that Licensee has the right to grant under this Agreement.

  • Product Liability Claims As soon as it becomes aware, each party will give the other prompt written notice of any defect or alleged defect in a Product, any injury alleged to have occurred as a result of the use or application of a Product, and any circumstances that may give rise to litigation or recall of a Product or regulatory action that may affect the sale or manufacture of a Product, specifying, to the extent the party has such information, the time, place and circumstances thereof and the names and addresses of the persons involved. Each party will also furnish promptly to the other copies of all papers received in respect of any claim, action or suit arising out of such alleged defect, injury or regulatory action.

  • Claim Procedure Any Person entitled to indemnification hereunder shall (i) give prompt written notice to the indemnifying party of any claim with respect to which it seeks indemnification (provided that the failure to give prompt notice shall impair any Person’s right to indemnification hereunder only to the extent such failure has prejudiced the indemnifying party) and (ii) unless in such indemnified party’s reasonable judgment a conflict of interest between such indemnified and indemnifying parties may exist with respect to such claim, permit such indemnifying party to assume the defense of such claim with counsel reasonably satisfactory to the indemnified party. If such defense is assumed, the indemnifying party shall not be subject to any liability for any settlement made by the indemnified party without its consent (but such consent shall not be unreasonably withheld, conditioned or delayed). An indemnifying party who is not entitled to, or elects not to, assume the defense of a claim shall not be obligated to pay the fees and expenses of more than one counsel for all parties indemnified by such indemnifying party with respect to such claim, unless in the reasonable judgment of any indemnified party a conflict of interest may exist between such indemnified party and any other of such indemnified parties with respect to such claim. In such instance, the conflicted indemnified parties shall have a right to retain one separate counsel, chosen by the Holders representing a majority of the Registrable Securities included in the registration if such Holders are indemnified parties, at the expense of the indemnifying party.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!