Approval Process Tenant shall notify Landlord whether it approves of the submitted working drawings within three business days after Landlord’s submission thereof. If Tenant disapproves of such working drawings, then Tenant shall notify Landlord thereof specifying in reasonable detail the reasons for such disapproval, in which case Landlord shall, within five business days after such notice, revise such working drawings in accordance with Tenant’s objections and submit the revised working drawings to Tenant for its review and approval. Tenant shall notify Landlord in writing whether it approves of the resubmitted working drawings within one business day after its receipt thereof. This process shall be repeated until the working drawings have been finally approved by Landlord and Tenant. If Tenant fails to notify Landlord that it disapproves of the initial working drawings within three business days (or, in the case of resubmitted working drawings, within one business day) after the submission thereof, then Tenant shall be deemed to have approved the working drawings in question. Any delay caused by Tenant’s unreasonable withholding of its consent or delay in giving its written approval as to such working drawings shall constitute a Tenant Delay Day (defined below). If the working drawings are not fully approved (or deemed approved) by both Landlord and Tenant by the 15th business day after the delivery of the initial draft thereof to Tenant, then each day after such time period that such working drawings are not fully approved (or deemed approved) by both Landlord and Tenant shall constitute a Tenant Delay Day.
ROAD WORK PHASE APPROVAL Purchaser shall obtain written approval from the Contract Administrator upon completion of each of the following phases of road work: Drainage installation Subgrade compaction Rock compaction SUBSECTION RESTRICTIONS
Feasibility Study Buyer will, at Buyer's expense and within ____ days from Effective Date ("Feasibility Study Period"), determine whether the Property is suitable, in Buyer's sole and absolute discretion, for ___________________ use. During the Feasibility Study Period, Buyer may conduct a Phase I environmental assessment and any other tests, analyses, surveys and investigations ("Inspections") that Buyer deems necessary to determine to Buyer's satisfaction the Property's engineering, architectural and environmental properties; zoning and zoning restrictions; subdivision statutes; soil and grade; availability of access public roads, water, and other utilities; consistency with local, state and regional growth management plans, availability of permits, government approvals, and licenses; and other inspections that Buyer deems appropriate to determine the Property's suitability for the Buyer's intended use. If the Property must be rezoned, Buyer will obtain the rezoning from the appropriatx xxxernment agencies. Seller will sign all documents Buyer is required to file in connection with development or rezoning approvals. Seller gives Buyer, its agents, contractors and assigns, the right to enter the Property at any time during the Feasibility Study Period for the purpose of conducting inspections; provided, however, that Buyer, its agents, contractors and assigns enter the Property and conduct inspections at their own risk. Buyer will indemnify and hold Seller harmless from xxxxes, damages, costs, claims and expenses of any nature, including attorney's fees, expenses and liability incurred in application for rezoning or related proceedings, and from liability to any person, arising from the conduct of any and all inspections of any work authorized by Buyer. Buyer will not engage in any activity that xxxxx result in a construction lien being filed against the Property without Seller's prior written consent. If this transaction does not close, Buyer will, at Buyer's expense, (1) repair all damages to the Property resulting from the Inspections and return the Property to the condition it was in prior to conduct of the Inspections, and (2) release to Seller all reports and other work generated as a result of the Inspections. Buyer will deliver written notice to Seller prior to the expiration of the Feasibility Study Period of Buyer's determination of whether or not the Properxx xx acceptable. Buyer's failure to comply with this notice requirement will constitute acceptance of the Property as suitable for Buyer's intended use in its "as is" condition. If the Property is unacceptable to Buyer and written notice of this fact is timely delivered to Seller, this Contract will be deemed terminated as of the day after the Feasibility Study period ends and Buyer's deposit(s) will be returned after Escrow Axxxx receives proper authorization form all interested parties.
Approval Procedure 1. To request approval to receive shared leave hours, an employee or their representative must submit the following documentation to Human Resource Services:
Plan Approval 5.5.1.1 The A/E shall secure the required structural, plumbing, HVAC, and electrical plan approvals.
Project Approval The County may issue a Job Order Authorization for the Work, to include the firm-fixed-price of the Job Order and the project duration. Contractor agrees that all clauses of this Contract are applicable to any Job Order issued hereunder. The County reserves the right to reject a Contractor’s Quote based on unjustifiable quantities and/or methods, performance periods, inadequate documentation, or other inconsistencies or deficiencies on the Contractor’s part in the sole opinion of the County. The County reserves the right to issue a unilateral Job Order authorization for the Work if a Quote price cannot be mutually agreed upon. This is based upon unjustifiable quantities in the sole opinion of the County. The County also reserves the right to not issue a Job Order Authorization if the County’s requirement is no longer valid or the project is not funded. In these instances, the Contractor has no right of claim to recover Quote expenses. The County may pursue continuing valid requirements by other means where Contract was not reached with the Contractor.
New Project Approval Consultant and District recognize that Consultant’s Services may include working on various projects for District. Consultant shall obtain the approval of District prior to the commencement of a new project.
Final Approval Hearing “Final Approval Hearing” shall mean the hearing at which the Court will consider and finally decide whether to enter the Final Judgment.
Development Plan document specifying the work program, schedule, and relevant investments required for the Development and the Production of a Discovery or set of Discoveries of Oil and Gas in the Contract Area, including its abandonment.
Remediation Plan If deficiencies or weaknesses are cited on the evaluation form, the evaluator, working with the evaluatee, shall develop a written remediation plan for the purpose of assisting the evaluatee to improve. The remedial action plan shall be attached to the evaluation document and shall contain:
