Request for Review Within sixty (60) days after receiving notice from the Plan Administrator that a claim has been denied (in part or all of the claim), then claimant (or their duly authorized representative) may file with the Plan Administrator, a written request for a review of the denial of the claim. The claimant (or his duly authorized representative) shall then have the opportunity to submit written comments, documents, records and other information relating to the claim. The Plan Administrator shall also provide the claimant, upon request and free of charge, reasonable access to, and copies of, all documents, records and other information relevant (as defined in applicable ERISA regulations) to the claimant’s claim for benefits.
Review Report Within 5 Business Days after the end of the applicable Asset Representations Review period under Section 3.03(b), the Asset Representations Reviewer will deliver to the Issuer, the Administrator, the Servicer, the Depositor and the Indenture Trustee a report indicating for each Review Receivable whether there was a Test Pass, Test Fail or Test Complete for each related Test (a “Review Report”). For each Test Fail or Test Complete, the Review Report will indicate the related reason, including (for example) whether the Review Receivable was a Test Fail as a result of missing or incomplete Review Materials. The Review Report will contain a summary of the Asset Representations Review results to be included in the Issuer’s Form 10-D report for the Collection Period in which the Review Report is received. The Asset Representations Reviewer will ensure that the Review Report does not contain any PII. On reasonable request of the Servicer, the Asset Representations Reviewer will provide additional details on the Test results.
Contract Review Agent shall have reviewed all material contracts of Borrowers including, without limitation, leases, union contracts, labor contracts, vendor supply contracts, license agreements and distributorship agreements and such contracts and agreements shall be satisfactory in all respects to Agent;
Independent Review Contractor shall provide the Secretary of ADS/CIO an independent expert review of any Agency recommendation for any information technology activity when its total cost is $1,000,000.00 or greater or when CIO requires one. The State has identified two sub-categories for Independent Reviews, Standard and Complex. The State will identify in the SOW RFP the sub-category they are seeking. State shall not consider bids greater than the maximum value indicated below for this category. Standard Independent Review $25,000 Maximum Complex Independent Review $50,000 Maximum Per Vermont statute 3 V.S.A. 2222, The Secretary of Administration shall obtain independent expert review of any recommendation for any information technology initiated after July 1, 1996, as information technology activity is defined by subdivision (a) (10), when its total cost is $1,000,000 or greater or when required by the State Chief Information Officer. Documentation of this independent review shall be included when plans are submitted for review pursuant to subdivisions (a)(9) and (10) of this section. The independent review shall include: • An acquisition cost assessment • A technology architecture review • An implementation plan assessment • A cost analysis and model for benefit analysis • A procurement negotiation advisory services contract • An impact analysis on net operating costs for the agency carrying out the activity In addition, from time to time special reviews of the advisability and feasibility of certain types of IT strategies may be required. Following are Requirements and Capabilities for this Service: • Identify acquisition and lifecycle costs; • Assess wide area network (WAN) and/or local area network (LAN) impact; • Assess risks and/or review technical risk assessments of an IT project including security, data classification(s), subsystem designs, architectures, and computer systems in terms of their impact on costs, benefits, schedule and technical performance; • Assess, evaluate and critically review implementation plans, e.g.: • Adequacy of support for conversion and implementation activities • Adequacy of department and partner staff to provide Project Management • Adequacy of planned testing procedures • Acceptance/readiness of staff • Schedule soundness • Adequacy of training pre and post project • Assess proposed technical architecture to validate conformance to the State’s “strategic direction.” • Insure system use toolsets and strategies are consistent with State Chief Information Officer (CIO) policies, including security and digital records management; • Assess the architecture of the proposed hardware and software with regard to security and systems integration with other applications within the Department, and within the Agency, and existing or planned Enterprise Applications; • Perform cost and schedule risk assessments to support various alternatives to meet mission need, recommend alternative courses of action when one or more interdependent segment(s) or phase(s) experience a delay, and recommend opportunities for new technology insertions; • Assess the architecture of the proposed hardware and software with regard to the state of the art in this technology. • Assess a project’s backup/recovery strategy and the project’s disaster recovery plans for adequacy and conformance to State policy. • Evaluate the ability of a proposed solution to meet the needs for which the solution has been proposed, define the ability of the operational and user staff to integrate this solution into their work.
Asset Representations Review Representative The Asset Representations Reviewer will designate one or more representatives who will be available to the Issuer and the Servicer during the performance of an Asset Representations Review.
Completion of Review for Certain Review Receivables Following the delivery of the list of the Review Receivables and before the delivery of the Review Report by the Asset Representations Reviewer, the Servicer may notify the Asset Representations Reviewer if a Review Receivable is paid in full by the Obligor or purchased from the Issuer in accordance with the terms of the Basic Documents. On receipt of such notice, the Asset Representations Reviewer will immediately terminate all Tests of the related Review Receivable, and the Review of such Review Receivables will be considered complete (a “Test Complete”). In this case, the related Review Report will indicate a Test Complete for such Review Receivable and the related reason.
Document Review The Company and the Executive hereby acknowledge and agree that each (i) has read this Agreement in its entirety prior to executing it, (ii) understands the provisions and effects of this Agreement, (iii) has consulted with such attorneys, accountants and financial and other advisors as it or he has deemed appropriate in connection with their respective execution of this Agreement, and (iv) has executed this Agreement voluntarily and knowingly.
Asset Review Reports Within five (5) days of the end of the Asset Review period under Section 3.4(b), the Asset Representations Reviewer will deliver to the Issuer, the Servicer and the Trustee an Asset Review Report indicating for each Asset Review Receivable whether there was a Test Pass or a Test Fail for each Test, or whether the Asset Review Receivable was a Test Complete and the related reason. The Asset Review Report will contain a summary of the Asset Review results to be included in the Issuer’s Form 10-D report for the Collection Period in which the Asset Review Report is received. The Asset Representations Reviewer will ensure that the Asset Review Report does not contain any Non-Public Personal Information.
