Failure to comply with directions If the Train Operator fails to comply with any directions given under paragraph 4.1, Network Rail shall be entitled to remove from the Network or Stable any Specified Equipment left on the Network or to instruct a third party to do so and any reasonable costs incurred by Network Rail in taking such steps shall be paid promptly by the Train Operator.
Work Does Not Comply with Contract If the Engineer submits work that does not comply with the terms of this contract, the State shall instruct the Engineer to make such revision as is necessary to bring the work into compliance with the contract. No additional compensation shall be paid for this work.
Amendment to Comply with Law The Parties acknowledge that state and federal laws and regulations relating to data security and privacy are rapidly evolving and that amendment of this Agreement may be required to provide procedures to ensure compliance with such developments.
Failure to Comply with Arbitrator’s Decision 10.6.1 The award of such Arbitrator shall be final and binding upon the parties.
Notice of Criminal Activity and Disciplinary Actions a. Xxxxxxx shall immediately report in writing to their contract manager when Xxxxxxx has knowledge or any reason to believe that they or any person with ownership or controlling interest in the organization/business, or their agent, employee, contractor or volunteer that is providing services under this Contract has:
Joint Funded Project with the Ohio Department of Transportation In the event that the Recipient does not have contracting authority over project engineering, construction, or right-of- way, the Recipient and the OPWC hereby assign certain responsibilities to the Ohio Department of Transportation, an authorized representative of the State of Ohio. Notwithstanding Sections IV, VI.A., VI.B., VI.C., and VII of the Project Agreement, Recipient hereby acknowledges that upon notification by the Ohio Department of Transportation, all payments for eligible project costs will be disbursed by the Grantor directly to the Ohio Department of Transportation. A Memorandum of Funds issued by the Ohio Department of Transportation shall be used to certify the estimated project costs. Upon receipt of a Memorandum of Funds from the Ohio Department of Transportation, the OPWC shall transfer funds directly to the Ohio Department of Transportation via an Intra-State Transfer Voucher. The amount or amounts transferred shall be determined by applying the Participation Percentages defined in Appendix D to those eligible project costs within the Memorandum of Funds. In the event that the Project Scope is for right-of-way only, notwithstanding Appendix D, the OPWC shall pay for 100% of the right-of-way costs not to exceed the total financial assistance provided in Appendix C. APPENDIX D LOCAL SUBDIVISION CONTRIBUTION, PROJECT FINANCING AND EXPENSES SCHEME AND DISBURSEMENT RATIO
Consistency with Federal Laws and Regulations This Agreement shall incorporate by reference Section 22.9 of the CAISO Tariff as if the references to the CAISO Tariff were referring to this Agreement.
Comply with Laws It will comply in all material respects with all applicable laws and orders to which it may be subject if failure so to comply would materially impair its ability to perform its obligations under this Agreement or any Credit Support Document to which it is a party.
CHILD AND DEPENDENT ADULT/ELDER ABUSE REPORTING CONTRACTOR shall establish a procedure acceptable to ADMINISTRATOR to ensure that all employees, agents, subcontractors, and all other individuals performing services under this Agreement report child abuse or neglect to one of the agencies specified in Penal Code Section 11165.9 and dependent adult or elder abuse as defined in Section 15610.07 of the WIC to one of the agencies specified in WIC Section 15630. CONTRACTOR shall require such employees, agents, subcontractors, and all other individuals performing services under this Agreement to sign a statement acknowledging the child abuse reporting requirements set forth in Sections 11166 and 11166.05 of the Penal Code and the dependent adult and elder abuse reporting requirements, as set forth in Section 15630 of the WIC, and shall comply with the provisions of these code sections, as they now exist or as they may hereafter be amended.
Early Warning 32.1 The Contractor is to warn the Engineer at the earliest opportunity of specific likely future events or circumstances that may adversely affect the quality of the work, increase the Contract Price or delay the execution of works. The Engineer may require the Contractor to provide an estimate of the expected effect of the future event or circumstance on the Contract Price and Completion Date. The estimate is to be provided by the Contractor as soon as reasonably possible.
