Rights of Landlord (a) Consent by Landlord to one or more assignments of this Lease, or to one or more sublettings of the Premises or any portion thereof, or collection of rent by Landlord from any assignee or sublessee, shall not operate to exhaust Landlord’s rights under this Article 11, nor constitute consent to any subsequent assignment or subletting. No assignment of Tenant’s interest in this Lease and no sublease shall relieve Tenant of its obligations hereunder, notwithstanding any waiver or extension of time granted by Landlord to any assignee or sublessee, or the failure of Landlord to assert its rights against any assignee or sublessee, and regardless of whether Landlord’s consent thereto is given or required to be given hereunder. In the event of a default by any assignee, sublessee or other successor of Tenant in the performance of any of the terms or obligations of Tenant under this Lease, Landlord may proceed directly against Tenant without the necessity of exhausting remedies against any such assignee, sublessee or other successor. In addition, Tenant immediately and irrevocably assigns to Landlord, as security for Tenant’s obligations under this Lease, all rent from any subletting of all or a part of the Premises as permitted under this Lease, and Landlord, as Tenant’s assignee, or any receiver for Tenant appointed on Landlord’s application, may collect such rent and apply it toward Tenant’s obligations under this Lease; except that, until the occurrence and during the continuance of an event of default by Tenant, Tenant shall have the right to collect such rent and to retain all sublease profits (subject to the provisions of Section 11.2(c), below),
(b) Upon any assignment of Tenant’s interest in this Lease for which Landlord’s consent is required under Section 11.1 hereof, Tenant shall pay to Landlord, within ten (10) days after receipt thereof by Tenant from time to time, one-half ( 1/2) of all cash sums and other economic considerations received by Tenant in connection with or as a result of such assignment, after first deducting therefrom (i) any costs incurred by Tenant for leasehold improvements (including, but not limited to, third-party architectural and space planning costs) in the Premises in connection with such assignment, amortized over the remaining term of this Lease, (ii) any real estate commissions and/or reasonable attorneys’ fees actually incurred by Tenant in connection with such assignment, and (iii) the unamortized cost (assuming straight-line amortization over the entire period from the Rent Commencement Date through the remainder of the initial term of this Lease) of any alterations, additions and improvements made to the Premises at Tenant’s expense and remaining in the Premises at the time of such assignment.
(c) Upon any sublease of all or any portion of the Premises for which Landlord’s consent is required under Section 11.1 hereof, Tenant shall pay to Landlord, within ten (10) days after receipt thereof by Tenant from time to time, one-half ( 1/2) of all cash sums and other economic considerations received by Tenant in connection with or as a result of such sublease, after first deducting therefrom (i) the minimum rental due hereunder for the corresponding period, prorated (on the basis of the average per-square-foot cost paid by Tenant for the Premises for the applicable period under this Lease) to reflect the size of the subleased portion of the Premises, (ii) any costs incurred by Tenant for leasehold improvements in the subleased portion of the Premises (including, but not limited to, third-party architectural and space planning costs) for the specific benefit of the sublessee in connection with such sublease, amortized over the remaining term of this Lease, (iii) any real estate commissions and/or reasonable attorneys’ fees actually incurred by Tenant in connection with such sublease, amortized over the term of such sublease, and (iv) amortized over the term of such sublease, the portion allocable to the sublease term of the unamortized cost (assuming straight-line amortization over the entire period from the Rent Commencement Date through the remainder of the initial term of this Lease) of any alterations, additions and improvements made to the Premises at Tenant’s expense and reasonably allocable to the subleased portion of the Premises at the time of the sublease. Notwithstanding anything to the contrary contained in this paragraph (c), in no event shall the economic considerations required to be shared by Tenant with Landlord hereunder include the reasonable, good faith value of any goods or services provided by Tenant to any sublessee in connection with any subletting, including, but not limited to, any shipping, receiving, security, reception, facilities management, laboratory, repair, maintenance, utilities and other similar goods and services provided to the sublessee in excess of the goods and services provided by Landlord to Tenant under this Lease.
Acceptance of REMIC I by Trustee (a) The Trustee, by the execution and delivery of this Agreement, acknowledges receipt by it or a Custodian on its behalf, subject to any exceptions noted on the Schedule of Exceptions to Mortgage File Delivery attached hereto as Schedule VI, to the provisions of Section 2.01 and to the further review provided for in this Section 2.02, of, with respect to each Mortgage Loan, an original Mortgage Note endorsed to the Trustee, an original or a copy of the Mortgage (with evidence of recording thereon), and an original assignment of such Mortgage executed in favor of the Trustee (in such capacity) and of all other assets included in REMIC I, in good faith and without notice of any adverse claim, and declares that it or a Custodian on its behalf holds and will hold the documents delivered or caused to be delivered by the Mortgage Loan Seller in respect of the Mortgage Loans, and that it holds and will hold such other assets included in REMIC I, in trust for the exclusive use and benefit of all present and future Certificateholders.
(b) Within ___ days of the Closing Date (or, in the case of any Mortgage Loan as to which a Servicing Transfer Event has occurred during such____-day period of which event the Trustee has notice, within the shorter of ___ days of the Closing Date and ____ Business Days of the Trustee's receiving such notice), the Trustee or a Custodian on its behalf shall review each of the documents delivered or caused to be delivered by the Mortgage Loan Seller with respect to each Mortgage Loan pursuant to Section 2.01(c); and, promptly following such review, the Trustee shall, subject to Section 2.02(d), certify in writing to each of the Depositor, the Master Servicer, the Special Servicer and the Mortgage Loan Seller that as to each Mortgage Loan listed in the Mortgage Loan Schedule (other than any Mortgage Loan paid in full), and except as specifically identified in any exception report annexed to such certification, (i) all documents specified in clauses [(i) through (iii), (ix)] and, if the Mortgage Loan Schedule specifies that the related Mortgagor has a leasehold interest in the related Mortgaged Property, (xiii) of the definition of "Mortgage File" are in its possession or the possession of a Custodian on its behalf, or the Mortgage Loan Seller has otherwise satisfied the delivery requirements in respect of such documents in accordance with Section 2.01(c), (ii) all documents received by it or any Custodian in respect of such Mortgage Loan have been reviewed by it or by a Custodian on its behalf and appear regular on their face and relate to such Mortgage Loan, and (iii) based on such examination and only as to the foregoing documents, the information set forth in the Mortgage Loan Schedule with respect to the items specified in clauses [(ii), (iii), (iv) and (vi)(B)] of the definition of "Mortgage Loan Schedule" is correct.
(c) The Trustee or a Custodian on its behalf shall review each of the documents relating to the Mortgage Loans received thereby subsequent to the Closing Date; and, on or about the first anniversary of the Closing Date, the Trustee shall, subject to Section 2.02(d), certify in writing to each of the Depositor, the Master Servicer, the Special Servicer and, the Mortgage Loan Seller that as to each Mortgage Loan listed on the Mortgage Loan Schedule (other than any Mortgage Loan paid in full or otherwise liquidated), and except as specifically identified in any exception report annexed to such certification, (i) all documents specified in clauses [(i), (ii), (ix)] and, if the Mortgage Loan Schedule specifies that the related Mortgagor has a leasehold interest in the related Mortgaged Property, (xiii) of the definition of "Mortgage File" are in its possession or the possession of a Custodian on its behalf, or the Mortgage Loan Seller has otherwise satisfied the delivery requirements in respect of such documents in accordance with Section 2.01(c), (ii) it or a Custodian on its behalf has received either the original or copy of each of the assignments specified in clauses [(iii) and (v)] of the definition of "Mortgage File" that were delivered by the Mortgage Loan Seller with evidence of recording thereon, (iii) all documents received by it or any Custodian in respect of such Mortgage Loan have been reviewed by it or by such Custodian on its behalf and appear regular on their face and relate to such Mortgage Loan, and (iv) based on the examinations referred to in subsection (b) above and this subsection (c) and only as to the foregoing documents, the information set forth in the Mortgage Loan Schedule with respect to the items specified in clauses [(ii), (iii), (iv) and (vi)(B)] of the definition of "Mortgage Loan Schedule", is correct.
(d) It is herein acknowledged that, notwithstanding any other provision hereof, neither the Trustee nor any Custodian is under any duty or obligation (i) to determine whether any of the documents specified in clauses [(iv) through (viii), (x) through (xii) and (xiv) through (xv)] of the definition of "Mortgage File" exist or are required to be delivered by the Mortgage Loan Seller in respect of any Mortgage Loan or (ii) to inspect, review or examine any of the documents, instruments, certificates or other papers relating to the Mortgage Loans delivered to it to determine that the same are genuine, enforceable, in recordable form or appropriate for the represented purpose, or that they are other than what they purport to be on their face.
(e) If, in the process of reviewing the documents delivered or caused to be delivered by the Mortgage Loan Seller pursuant to Section 2.01(c), the Trustee or any Custodian discovers that any document required to have been delivered pursuant to Section 2.01(c) has not been so delivered, or discovers that any of the documents that were delivered has not been properly executed, contains information that does not conform in any material respect with the corresponding information set forth in the Mortgage Loan Schedule, or is defective on its face (each, including, without limitation, that a document is missing, a "Document Defect"), or if, at any other time, the Trustee or any other party hereto discovers a Document Defect in respect of any Mortgage Loan, the party discovering such Document Defect shall promptly so notify each of the other parties hereto. If and when such party is notified of or discovers any error in the Mortgage Loan Schedule, the Mortgage Loan Seller shall promptly correct such error and distribute a new, corrected Mortgage Loan Schedule to each of the other parties hereto. Such new, corrected Mortgage Loan Schedule shall be deemed to amend and replace the existing Mortgage Loan Schedule.
Acceptance of REMIC I by the Trustee Subject to the provisions of Section 2.01 and subject to any exceptions noted on the exception report described in the next paragraph below, the Trustee or the Custodian acknowledges receipt of the documents referred to in Section 2.01 (other than such documents described in Section 2.01(a)(iv)) above and all other assets included under clauses (i), (iii), (iv) and (v) of the definition of “REMIC I” (to the extent of amounts deposited into the Distribution Account) and declares that the Trustee or the Custodian, as applicable, holds and will hold such documents and the other documents delivered to it constituting the Mortgage File on behalf of the Trust, and that it holds or will hold all such assets and such other assets included in the definition of “REMIC I” in trust for the exclusive use and benefit of all present and future Certificateholders. The Trustee also acknowledges receipt of the amounts on deposit in the Net WAC Reserve Fund in trust for the exclusive use and benefit of all present and future Certificateholders. The Trustee agrees on or before the Closing Date, for the benefit of the Certificateholders, to review, or cause the Custodian to review, each Mortgage File and to certify and deliver, or cause the Custodian to certify and deliver an initial certification, to the Depositor, the Seller, the Servicer and the Trustee in substantially the form attached hereto as Exhibit C-1 (the “Initial Certification”). It is herein acknowledged that, in conducting such review, neither the Trustee nor the Custodian was under any duty or obligation (i) to inspect, review or examine any such documents, instruments, certificates or other papers to determine whether they are genuine, enforceable, or appropriate for the represented purpose (including with respect to Section 2.01(a)(vi), whether such title insurance policy insures the priority of the Mortgage as a first lien) or whether they have actually been recorded or that they are other than what they purport to be on their face or (ii) to determine whether any Mortgage File should include any of the documents specified in Section 2.01(a)(iv). Prior to the first anniversary date of this Agreement, the Trustee shall cause the Custodian to deliver to the Depositor, the Trustee, the Seller and the Servicer a final certification in substantially the form annexed hereto as Exhibit C-2 (the “Final Certification”) evidencing the completeness of the Mortgage Files, with any applicable exceptions noted thereon. If in the process of reviewing the Mortgage Files and making or preparing, as the case may be, the certifications referred to above, the Trustee or the Custodian finds any document or documents constituting a part of a Mortgage File to be missing or defective in any material respect, at the conclusion of its review the Trustee shall so notify the Depositor, the Seller and the Servicer. In addition, upon the discovery by the Depositor, the Servicer, the Custodian or the Trustee of a breach of any of the representations and warranties made by the Originator or the Seller in the Mortgage Loan Purchase Agreement or this Agreement, respectively, in respect of any Mortgage Loan which materially adversely affects such Mortgage Loan or the interests of the related Certificateholders in such Mortgage Loan, the party discovering such breach shall give prompt written notice to the other parties. Enforcement of the Mortgage Loan Purchase Agreement or this Agreement against the Originator or the Seller, respectively, shall be effected by the Trustee. The Trustee shall pay the costs of such enforcement at its own expense, and shall be reimbursed therefor only (i) from a general recovery resulting from such enforcement, to the extent, if any, that such recovery exceeds all amounts due in respect of the Mortgage Loans or (ii) from a specific recovery of costs, expenses or attorneys’ fees against the Person against which such enforcement is directed; provided, however, if the sources of reimbursement described in clauses (i) and (ii) are insufficient, the Trustee may seek reimbursement for any remaining unreimbursed costs of such enforcement from the Trust Fund as an Extraordinary Trust Fund Expense.
Premises and Term a. Landlord, in consideration of the Rent hereinafter reserved to be paid and of the covenants, conditions and agreements to be kept and performed by Tenant, hereby leases, lets and demises to Tenant, and Tenant hereby leases and hires from Landlord, the Project. Upon the Commencement Date for Phase 1, Tenant shall be entitled to the exclusive use and occupancy of Phase 1 and that portion of the Parking Area allocated for Phase 1 plus such spaces in addition to the spaces allocated for Phase 1, if any, that may be constructed by Landlord at the time, so long as Tenant’s use of such spaces in addition to the spaces allocated for Phase 1 does not interfere with the construction of the remainder of the Project by Landlord. Upon the Commencement Date for Phase 2, Tenant shall be entitled to the exclusive use and occupancy of Phase 2 and the entire Parking Area, and at which time Tenant will have the exclusive use and occupancy of the entire Project.
b. Promptly after the actual Commencement Date for each Phase, the parties shall execute an instrument in which the Commencement Date and expiration date for such Phase will be specified, as well as any adjustments to the Rentable Area of the Premises as described above and any corresponding adjustments to the Base Rent.
c. Notwithstanding anything to the contrary contained in this Lease, although Landlord has estimated a completion date for Phase 1 of October 1, 1999, the parties agree that if Landlord has not achieved Substantial Completion of Phase 1 on or before November 1, 1999 (the “Phase 1 Completion Date”) (subject to any Tenant Delays and Force Majeure events, as hereinafter defined), then, commencing on November 1, 1999, Tenant shall receive a credit against the Base Rent to become due under this Lease in connection with Phase 1, such credit to be equal to one (1) day’s Base Rent for Phase 1 for each day of Landlord’s delay beyond the Phase 1 Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below.
d. If Landlord has not achieved Substantial Completion of Phase 1 on or before November 15, 1999 (the “Phase 1 Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on November 16, 1999, the Base Rent credit available to Tenant for Phase 1 shall be increased to two (2) days’ Base Rent for each day of Landlord’s delay beyond the Phase 1 Extended Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below.
e. If Landlord has not achieved Substantial Completion of Phase 1 on or before December 17, 1999 (the “Phase 1 Second Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on December 18, 1999, (x) the Base Rent credit available to Tenant for Phase 1 shall be decreased back to one (1) day’s Base Rent for each day of Landlord’s delay beyond the Phase 1 Second Extended Completion Date that Landlord has not achieved Substantial Completion, plus (y) Tenant shall be entitled to receive, as liquidated damages and not as a penalty, the sum of Ten Thousand and No/100 ($10,000.00) Dollars per day, subject to the limitations thereon pursuant to subsection (m), below.
f. If Landlord has not achieved Substantial Completion of Phase 1 on or before January 17, 2000 (the “Phase 1 Outside Completion Date”) (subject to any Tenant Delays and Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 1 Outside Completion Date, whereupon (i) Landlord shall return to Tenant the Prepaid Rent and Security Deposit, and (ii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 1 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 1 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder; provided, however, that if Landlord achieves Substantial Completion of Phase 1 within fifteen (15) days after receipt of Tenant’s termination notice, then the termination notice will be deemed to be void and rescinded, and the Lease shall continue in full force and effect.
g. If Tenant does not elect to terminate the Lease as provided above, and Landlord has not achieved Substantial Completion of Phase 1 on or before May 17, 2000 (the “Phase 1 Extended Outside Completion Date”) (subject to any Tenant Delays but regardless of Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 1 Extended Outside Completion Date, whereupon (i) Landlord shall return to Tenant the Prepaid Rent and Security Deposit, and (ii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 1 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 1 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder. If Tenant intends to exercise its termination right under this paragraph, then Tenant will use its best efforts to notify Landlord in writing between April 1, 2000 and May 1, 2000 of such intent, but Tenant’s failure to so notify Landlord shall not constitute a waiver of Tenant’s termination right.
h. Although Landlord has estimated a completion date for Phase 2 of October 1, 2001, the parties agree that if Landlord has not achieved Substantial Completion of Phase 2 on or before November 1, 2001 (the “Phase 2 Completion Date”) (subject to any Tenant Delays and Force Majeure events, as hereinafter defined), then, commencing on November 1, 2001, Tenant shall receive a credit against the Base Rent to become due under this Lease in connection with Phase 2, such credit to be equal to one (1) day’s Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below.
i. If Landlord has not achieved Substantial Completion of Phase 2 on or before November 15, 2001 (the “Phase 2 Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on November 16, 2001, the Base Rent credit available to Tenant for Phase 2 shall be increased to two (2) days’ Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Extended Completion Date that Landlord has not achieved Substantial Completion, subject to the limitations thereon pursuant to subsection (m), below.
j. If Landlord has not achieved Substantial Completion of Phase 2 on or before December 17, 2001 (the “Phase 2 Second Extended Completion Date”) (subject to any Tenant Delays and Force Majeure events), then, commencing on December 18, 2001, (x) the Base Rent credit available to Tenant shall be decreased back to one (1) day’s Base Rent for Phase 2 for each day of Landlord’s delay beyond the Phase 2 Second Extended Completion Date that Landlord has not achieved Substantial Completion, plus (y) Tenant shall be entitled to receive, as liquidated damages and not as a penalty, the sum of Ten Thousand and No/100 ($10,000.00) Dollars per day, subject to the limitations thereon pursuant to subsection (m), below.
k. If Landlord has not achieved Substantial Completion of Phase 2 on or before January 17, 2002 (the “Phase 2 Outside Completion Date”) (subject to any Tenant Delays and Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 2 Outside Completion Date, whereupon (i) Tenant shall vacate and surrender the Premises to Landlord in the manner required by this Lease, (ii) Landlord shall return to Tenant the Security Deposit, (iii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 2 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 2 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease between the Commencement Date for Phase 1 and the date of Tenant’s termination notice, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder; provided, however, that if Landlord achieves Substantial Completion of Phase 2 within fifteen (15) days after receipt of Tenant’s termination notice, then the termination notice will be deemed to be void and rescinded, and the Lease shall continue in full force and effect. Within ninety (90) days after Tenant’s termination notice, Tenant shall notify Landlord of the exact date that Tenant will vacate and surrender Phase 1, which date shall be (a) no earlier than ninety (90) days after the date of Tenant’s notification of such exact date, and (b) no later than one (1) year after the date of Tenant’s termination notice. Rent for Phase 1 shall be prorated through the date that Tenant so vacates and surrenders Phase 1 to Landlord.
l. If Tenant does not elect to terminate the Lease as provided above, and Landlord has not achieved Substantial Completion of Phase 2 on or before May 17, 2002 (the “Phase 2 Extended Outside Completion Date”) (subject to any Tenant Delays but regardless of Force Majeure events), then Tenant shall have the right to terminate this Lease by written notice to Landlord delivered within ten (10) days after the Phase 2 Extended Outside Completion Date, whereupon (i) Tenant shall vacate and surrender the Premises to Landlord in the manner required by this Lease, (ii) Landlord shall return to Tenant the Security Deposit, (iii) Landlord shall pay to Tenant liquidated damages equal to (x) the total of the Base Rent abatements for Phase 2 accrued to the date of Tenant’s termination notice, plus (y) the total of the $10,000.00 per day damages for Phase 2 accrued to the date of Tenant’s termination notice, plus (z) the actual, reasonable out-of-pocket costs incurred by Tenant directly in connection with this Lease between the Commencement Date for Phase 1 and the date of Tenant’s termination notice, subject to the limitations thereon pursuant to subsection (m), below, and thereupon both parties shall be relieved of all further obligations hereunder. Within ninety (90) days after Tenant’s termination notice, Tenant shall notify Landlord of the exact date that Tenant will vacate and surrender Phase 1, which date shall be (a) no earlier than ninety (90) days after the date of Tenant’s notification of such exact date, and (b) no later than one (1) year after the date of Tenant’s termination notice. Rent for Phase 1 shall be prorated through the date that Tenant so vacates and surrenders Phase 1 to Landlord. If Tenant intends to exercise its termination right under this paragraph, then Tenant will use its best efforts to notify Landlord in writing between April 1, 2002 and May 1, 2002 of such intent, but Tenant’s failure to so notify Landlord shall not constitute a waiver of Tenant’s termination right.
m. The abatements, liquidated damages and termination rights in favor of Tenant as described above shall be Tenant’s sole and exclusive remedies in the event of any late delivery of the Buildings by Landlord, and notwithstanding anything to the contrary contained in this Lease, in no event shall the entire liability of Landlord in connection with the total aggregate amounts of the Base Rent credits, plus the $10,000.00 per day damages, plus the out-of-pocket costs incurred by Tenant exceed a total amount of Seven Hundred Fifty Thousand and No/100 ($750,000.00) Dollars in the aggregate, regardless of the length of time such rent credits, and/or liquidated damages and/or out-of-pocket costs actually accrue and regardless of whether Tenant terminates this Lease.
n. Although the completion date for Phase 2 is intended to be October 1, 2001, Tenant may notify Landlord in writing of Tenant’s election to have the Commencement Date for Phase 2 be on October 1, 2000. Tenant must provide such notice no later than April 1, 1999. If Tenant timely provides such notice, then the anticipated Commencement Date for Phase 2 will be deemed to be October 1, 2000, and subparagraphs 2.h through 2.I above will be deemed to be modified as follows: All references to the year “2001” in such subparagraphs will be deemed to be “2000,” and all references to the year “2002” in such subparagraphs will be deemed to be “2001.”
Remedies of Landlord Upon the occurrence of any such event of default, Landlord shall have the option to pursue any one or more of the following remedies (as well as any other remedies provided by law or equity) without any notice or demand whatsoever:
10.2.1 Enter upon and take possession of the Premises without terminating this Lease and without relieving Tenant of its obligation to make the payments of Rent herein reserved, and expel or remove Tenant and any other person who may be occupying the Premises or any part thereof and any personal property or trade fixtures located therein, and change or alter the locks and other security devices, without notice to Tenant and relet the Premises on behalf of Tenant, at any rental readily obtainable, and receive the rent therefor. Landlord shall have no obligation to furnish a new key to Tenant unless and until tenant cures all existing defaults and delivers to Landlord additional security satisfactory to Landlord to secure Tenant's performance of its obligations under this Lease. In such event, Tenant shall pay to Landlord on demand the expenses of such reletting (as described in Paragraph 10.2.2 hereof), and any deficiency which may arise by reason of such reletting for the remainder of the Term. Tenant shall not be entitled to any excess obtained by Landlord in reletting over the Rent. Landlord can bring separate actions from time to time against Tenant to collect rent due and owing.
10.2.2 Terminate this Lease forthwith. In the event of such termination, Tenant shall immediately surrender the Premises to Landlord and if Tenant fails to do so, Landlord may enter upon and take possession of the Premises and expel or remove Tenant and any other person who may be occupying the Premises or any part thereof, and any personal property or trade fixtures located therein. In the event of the termination of this Lease as provided herein, Tenant shall pay to Landlord, on demand, the expenses of such reletting (including all repairs, tenant finish, improvements, brokers' and attorneys' fees and all loss or damage which Landlord may sustain by reason of such re-entry and reletting) plus an amount equal to the difference between the Rent provided for herein and the amount of Rent received by Landlord from the subsequent reletting of the Premises, for the period which would otherwise constitute the balance of the Term, which amount shall be considered accelerated and immediately due and payable, (discounted at the prime rate then in effect) per year) in full by Tenant to Landlord.
10.2.3 Cure any default of Tenant hereunder and Tenant shall immediately reimburse Landlord for the cost thereof plus interest thereon at the Default Rate from the date of expenditure by Landlord until the date of reimbursement by Tenant.
Right to Extend Term Tenant shall have the right to extend the Term of the Lease upon the following terms and conditions:
Reliance by Trustee Except as otherwise provided in Section 7.1:
(a) The Trustee may rely and shall be protected in acting upon any resolution, certificate, statement, instrument, opinion, report, notice, request, consent, order, or other paper or document believed by it to be genuine and to have been signed or presented by the proper party or parties.
(b) The Trustee may consult with legal counsel, auditors or other experts to be selected by it, including firms with which the Trustee may be an affiliate, and the advice or opinion of such counsel, accountants, auditors or other experts shall be full and complete protection to the Trustee, the employees and the agents of the Trustee in respect of any action taken or omitted or suffered by them in good faith and in reliance on, or in accordance with, such advice or opinion.
(c) Persons dealing with the Trustee shall look only to the Trust Assets to satisfy any liability relating to the Trust Assets incurred by the Trustee to such Person in carrying out the terms of this Trust, and the Trustee shall have no obligation to satisfy any such liability.
(d) As far as practicable and except as expressly permitted above, the Trustee shall cause any written instrument creating an obligation of the Trust to include a reference to this Agreement and to provide that neither the Beneficiaries, the Trustee nor their agents shall be liable thereunder and that the other parties to such instrument shall look solely to the Trust Assets for the payment of any claim thereunder or the performance thereof; provided, however, that the omission of such provision from any such instrument shall not render the Beneficiaries, the Trustee, or their agents liable, nor shall the Trustee be liable to anyone for such omission.
Subordination of All Guarantor Claims As used herein, the term “Guarantor Claims” shall mean all debts and liabilities of Borrower to Guarantor, whether such debts and liabilities now exist or are hereafter incurred or arise, or whether the obligations of Borrower thereon be direct, contingent, primary, secondary, several, joint and several, or otherwise, and irrespective of whether such debts or liabilities be evidenced by note, contract, open account, or otherwise, and irrespective of the person or persons in whose favor such debts or liabilities may, at their inception, have been, or may hereafter be created, or the manner in which they have been or may hereafter be acquired by Guarantor. The Guarantor Claims shall include without limitation all rights and claims of Guarantor against Borrower (arising as a result of subrogation or otherwise) as a result of Guarantor’s payment of all or a portion of the Guaranteed Obligations. Upon the occurrence of an Event of Default or the occurrence of an event which would, with the giving of notice or the passage of time, or both, constitute an Event of Default, Guarantor shall not receive or collect, directly or indirectly, from Borrower or any other party any amount upon the Guarantor Claims.
Maintenance by Tenant Subject to the provisions of Paragraph 13.2, 21 and 22 below, throughout the Term, Tenant shall, at its sole expense, (1) keep and maintain in good order and condition the Building and the Premises and repair the Building and the Premises and every part thereof, including interior and exterior glass, windows, window frames and casements, interior and exterior doors and door frames and door closers; interior and exterior lighting (including, without limitation, light bulbs and ballasts), the roof covering; the Systems serving the Premises and the Building; interior and exterior signage, interior demising walls and partitions, equipment, interior painting and interior walls and floors, and the roll-up doors, ramps and dock equipment, including, without limitation, dock bumpers, dock plates, dock seals, dock levelers and dock lights located in or on the Premises (excepting only those portions of the Building or the Project to be maintained by Landlord, as provided in Paragraph 13.2 below), (2) furnish all expendables, including light bulbs, paper goods and soaps, used in the Premises, and (3) keep and maintain in good order and condition and repair and replace all of Tenant’s security systems in or about or serving the Premises. Tenant shall not do nor shall Tenant allow Tenant’s Agents to do anything to cause any damage, deterioration or unsightliness to the Premises, the Building or the Project. Tenant shall perform its obligations under this Paragraph 13.1 in accordance with maintenance and repair standards adopted by Landlord from time to time for the Project. Tenant shall cause to be furnished to Landlord on not less than a quarterly basis maintenance reports on all Systems and the roof of the Building prepared by a qualified vendor or consultant, and Tenant shall promptly perform any maintenance tasks recommended by such reports or otherwise required by Landlord to cause the Premises and the Systems to comply with Landlord’s maintenance and repair standards.
Option to Extend Term Tenant shall have the option (“Option”) to extend the Term by five (5) years as to the entire Premises (and no less than the entire Premises) upon the following terms and conditions. Any extension of the Term pursuant to the Option shall be on all the same terms and conditions as this Lease, except as follows:
42.1. Base Rent during the Option term (including annual escalations, if applicable) shall equal the then-current fair market value for comparable office and laboratory space in the Xxxxxx Xxxxx submarket of comparable age, quality, level of finish and proximity to amenities and public transit (“FMV”). Tenant may, no more than twelve (12) months prior to the date the Term is then scheduled to expire, request Landlord’s estimate of the FMV for the Option term. Landlord shall, within fifteen (15) days after receipt of such request, give Tenant a written proposal of such FMV. If Tenant gives written notice to exercise the Option, such notice shall specify whether Tenant accepts Landlord’s proposed estimate of FMV. If Tenant does not accept the FMV, then the parties shall endeavor to agree upon the FMV, taking into account all relevant factors, including (a) the size of the Premises, (b) the length of the Option term, (c) rent in comparable buildings in the relevant submarket, including concessions offered to new tenants, such as free rent, tenant improvement allowances and moving allowances, (d) Tenant’s creditworthiness and (e) the quality and location of the Building and the Project. In the event that the parties are unable to agree upon the FMV within thirty (30) days after Tenant notifies Landlord that Tenant is exercising the Option, then either party may request that the same be determined as follows: a senior officer of a nationally recognized leasing brokerage firm with local knowledge of the Xxxxxx Xxxxx laboratory/research and development leasing submarket (the “Baseball Arbitrator”) shall be selected and paid for jointly by Landlord and Tenant. If Landlord and Tenant are unable to agree upon the Baseball Arbitrator, then the same shall be designated by the local chapter of the American Arbitration Association or any successor organization thereto (the “AAA”). The Baseball Arbitrator selected by the parties or designated by the AAA shall (y) have at least ten (10) years’ experience in the leasing of laboratory/research and development space in the Xxxxxx Xxxxx submarket and (z) not have been employed or retained by either Landlord or Tenant or any affiliate of either for a period of at least ten (10) years prior to appointment pursuant hereto. Each of Landlord and Tenant shall submit to the Baseball Arbitrator and to the other party its determination of the FMV. The Baseball Arbitrator shall grant to Landlord and Tenant a hearing and the right to submit evidence. The Baseball Arbitrator shall determine which of the two (2) FMV determinations more closely represents the actual FMV. The arbitrator may not select any other FMV for the Premises other than one submitted by Landlord or Tenant. The FMV selected by the Baseball Arbitrator shall be binding upon Landlord and Tenant and shall serve as the basis for determination of Base Rent payable for the Option term. If, as of the commencement date of the Option term, the amount of Base Rent payable during the Option term shall not have been determined, then, pending such determination, Tenant shall pay Base Rent equal to the Base Rent payable with respect to the last year of the then-current Term. After the final determination of Base Rent payable for the Option term, the parties shall promptly execute a written amendment to this Lease specifying the amount of Base Rent to be paid during the Option term. Any failure of the parties to execute such amendment shall not affect the validity of the FMV determined pursuant to this Section.
42.2. The Option is not assignable separate and apart from this Lease.
42.3. The Option is conditional upon Tenant giving Landlord written notice of its election to exercise the Option on or before the date that is nine (9) months prior to the expiration of the then-current Term (such date, the “Option Date”). Time shall be of the essence as to Tenant’s exercise of the Option. Tenant assumes full responsibility for maintaining a record of the deadlines to exercise the Option. Tenant acknowledges that it would be inequitable to require Landlord to accept any exercise of the Option after the date provided for in this Section.
42.4. Notwithstanding anything contained in this Article to the contrary, Tenant shall not have the right to exercise the Option:
(a) During the time commencing from the date Landlord delivers to Tenant a written notice that Tenant is in default under any provisions of this Lease and continuing until Tenant has cured the specified default to Landlord’s reasonable satisfaction; or
(b) At any time after any Default as described in Article 31 of the Lease and continuing until Tenant cures any such Default, if such Default is susceptible to being cured; or
(c) In the event that Tenant has defaulted in the performance of its obligations under this Lease two (2) or more times and a service or late charge has become payable under Section 31.1 for each of such defaults during the twelve (12)-month period immediately prior to the date that Tenant intends to exercise the Option, whether or not Tenant has cured such defaults.
42.5. The period of time within which Tenant may exercise the Option shall not be extended or enlarged by reason of Tenant’s inability to exercise such Option because of the provisions of Section 42.4.
42.6. All of Tenant’s rights under the provisions of the Option shall terminate and be of no further force or effect even after Tenant’s due and timely exercise of the Option if, after such exercise, but prior to the commencement date of the new term, (a) Tenant fails to pay to Landlord a monetary obligation of Tenant for a period of twenty (20) days after written notice from Landlord to Tenant, (b) Tenant fails to commence to cure a default (other than a monetary default) within thirty (30) days after the date Landlord gives notice to Tenant of such default or (c) Tenant has defaulted under this Lease two (2) or more times and a service or late charge under Section 31.1 has become payable for any such default, whether or not Tenant has cured such defaults.
