Changes in the Law definition

Changes in the Law shall have that meaning set forth in Section 6.07 of this Agreement.
Sample 1Sample 2Sample 3
Changes in the Law shall have the meaning set forth in Section 2.7.
Sample 1Sample 2Sample 3
Changes in the Law is defined in Section 4.8.
Sample 1Sample 2

Examples of Changes in the Law in a sentence

  • In the event the Changes in the Law prevent or preclude compliance with one or more of the provisions of this Agreement, such provisions of the Agreement shall be modified or suspended, or performance thereof delayed, as may be necessary, to comply with the Changes in the Law.

  • In the event the Changes in the Law prevent or preclude compliance with one or more provisions of this Agreement, such provisions of the Agreement shall be modified or suspended as may be necessary to comply with the Changes in the Law, and City and Developer shall take such action as may be required pursuant to this Agreement.

  • The City shall not apply to the Project any such law or regulation that is inconsistent with this Agreement until the Community Development Director makes a finding that such law or regulation is necessary to comply with such Changes in the Law.

  • Developer or City shall have the right to institute litigation relating to the Changes in the Law, and raise any issues regarding the validity of the Changes in the Law.

  • Provided, however, that if any action that City would take in furtherance of this Agreement would be rendered invalid, facially or otherwise, by the Changes in the Law, City shall not be required to undertake such action until the litigation is resolved, or the Changes in the Law are otherwise determined invalid, inapplicable, or are repealed.

  • In the event that such judgment determines that the validity of this Agreement is, directly or indirectly affected by the Changes in the Law, then the provisions of this Section shall apply.

  • In the event Changes in the Law prevent or preclude compliance with one or more provisions of this Agreement by either party hereto, such provisions of this Agreement shall be modified or suspended or performance delayed, as may be necessary to comply with Changes in the Law, and City and Developer shall meet and confer in good faith to determine whether the Changes in the Law apply to the Property and whether an amendment to this Agreement is necessary in light of the Changes in the Law.

  • In the event that such judgment invalidates the Changes in the Law or determines that it does not affect the validity of this Agreement, this Agreement shall remain in full force and effect, and its Term shall be extended by the amount of time between the effective date of the Changes in the Law, and the effective date of the judgment.

  • In the event the Changes in the Law prevent or preclude compliance with one or more provisions of this Agreement, such provisions of the Agreement shall be modified or suspended, or performance thereof delayed, as may be necessary, to comply with the Changes in the Law.

  • Nothing in this Agreement shall preclude City or Developer from contesting by any available means (including administrative or judicial proceedings) the applicability to the Project any such Changes in the Law.


More Definitions of Changes in the Law

Changes in the Law is defined in Section 3.7.
Sample 1
Changes in the Law shall have the meaning set forth in Section 4.11(d) of this Agreement.
Sample 1
Changes in the Law is defined in Section 5.7.
Sample 1
Changes in the Law means changes in laws, regulations, plans or policies that are specifically mandated and required by changes in state or federal law or regulations, as further defined in Section 2.3.4 of this Agreement.
Sample 1
Changes in the Law shall have that meaning set forth in Section 4.03(c) of this Agreement. “City” shall mean the City of Manteca, and shall include its City Council, Planning Commission, agencies, departments, employees, consultants, officers, officials, agents, consultants and volunteers.
Sample 1

Related to Changes in the Law

  • (1) In this Act employee” means an individual who has entered into or works under (or, where the employment has ceased, worked under) a contract of employment.

  • Reasonable in the circumstances means using no more force than is needed.

  • 6.-(1) In this Act an earlier trade mark” means -

  • the Law means any applicable law, proclamation, ordinance, act of parliament or enactment having force of law;

  • Data Protection Laws and Regulations means all laws and regulations, including laws and regulations of the European Union, the European Economic Area and their member states, Switzerland and the United Kingdom, applicable to the Processing of Personal Data under the Agreement.

  • bye-law means a bye-law framed by the corporation under this Act;

  • Access Laws means the Americans With Disabilities Act of 1990; the Fair Housing Amendments Act of 1988; all other federal, state and local laws or ordinances related to disabled access; and all statutes, rules, regulations, ordinances, orders of governmental bodies and regulatory agencies and orders and decrees of any court adopted, enacted or issued with respect thereto; all as now existing or hereafter amended or adopted.

  • Change in the Control means any change in any person(s) who directly exercise effective control over the Grantee.

  • Change in 1940 Act Law shall have the meaning set forth in the definition of "Investment Company Event."

  • Data Protection Law means the applicable legislation protecting the fundamental rights and freedoms of persons and their right to privacy with regard to the processing of Personal Data under the Agreement (and includes, as far as it concerns the relationship between the parties regarding the processing of Personal Data by SAP on behalf of Customer, the GDPR as a minimum standard, irrespective of whether the Personal Data is subject to GDPR or not).

  • Qualifying Provinces means each of the provinces of Canada;

  • EU Data Protection Law means (i) prior to 25 May 2018, Directive 95/46/EC of the European Parliament and of the Council on the protection of individuals with regard to the processing of Personal Data and on the free movement of such data ("Directive") and on and after 25 May 2018, Regulation 2016/679 of the European Parliament and of the Council on the protection of natural persons with regard to the processing of Personal Data and on the free movement of such data (General Data Protection Regulation) ("GDPR"); and (ii) Directive 2002/58/EC concerning the processing of Personal Data and the protection of privacy in the electronic communications sector and applicable national implementations of it (as may be amended, superseded or replaced).

  • Doing business in this state means issuing or performing wholly or in part any term of an interment rights agreement executed within the state of Iowa.

  • Anticorruption Laws means the US Foreign Corrupt Practices Act of 1977, as amended and any other anticorruption or anti-bribery Applicable Law applicable to the Company or any of its Subsidiaries.

  • Section 162(m) Exemption means the exemption from the limitation on deductibility imposed by Section 162(m) of the Code that is set forth in Section 162(m)(4)(C) of the Code.

  • the data protection principles means the principles set out in Part I of Schedule 1 to that Act, as read subject to Part II of that Schedule and to section 27(1) of that Act;

  • Data Protection Laws means all laws and regulations that govern the access, use, disclosure, or protection of Personal Data to which a party is subject with respect to the Service or the Software.

  • Change in Use means altering the purpose of an existing room, within the facility, that requires structural changes.

  • Applicable Data Protection Law means all data privacy or data protection laws or regulations globally that apply to the Processing of Personal Information under this Data Processing Agreement, which may include Applicable European Data Protection Law.

  • EU Data Protection Laws means EU Directive 95/46/EC, as transposed into domestic legislation of each Member State and as amended, replaced or superseded from time to time, including by the GDPR and laws implementing or supplementing the GDPR;

  • Resident means a student whose parents, legal guardians, persons having lawful control of the student, or persons standing in loco parentis reside in the school district.

  • UK Data Protection Laws means the Data Protection Xxx 0000 (incorporating the UK GDPR) and the Privacy and Electronic Communications (EC Directive) Regulations 2003, and the laws implementing or supplementing them;

  • Competition Law means any Law that prohibits, restricts or regulates actions having the purpose or effect of monopolization or restraint of trade or lessening of competition through merger or acquisition.

  • TUPE Regulations means the Transfer of Undertakings (Protection of Employment) Regulations 2006, as amended.

  • EEA Regulations means the Immigration (European Economic Area) Regulations 2006.

  • Change in Tax Law means the enactment, promulgation, execution or ratification of, or any change in or amendment to, any law (or in the application or official interpretation of any law) that occurs on or after the date on which the relevant Transaction is entered into.