COD Deadline definition

COD Deadline has the meaning set forth in Section 5.5(a) hereof.
Sample 1Sample 2
COD Deadline means that date which is the earlier of (i) ***, and (ii) ***.
Sample 1Sample 2
COD Deadline means the date that is 90 Days after the Scheduled Commercial Operation Date; «ԿՇԱ Վերջնաժամկետ» նշանակում է Նախատեսված Կոմերցիոն Շահագործման Ամսաթվից 90 Օր անց ընկած օրը.
Sample 1Sample 2

Examples of COD Deadline in a sentence

  • In the event that on the Project COD Deadline, the In-Service Date has occurred but the Contract Capacity is less than the Project Capacity, Seller shall pay Liquidated Damages in the amount of one hundred fifty thousand dollars ($150,000), multiplied by the number of MW by which the Contract Capacity is below the Project Capacity less any Daily Delay Liquidated Damages previously paid by Seller (“Contract Capacity Buy-Down Liquidated Damages”).

  • Notwithstanding anything to the contrary contained herein, if the Project COD Target Date (as defined in the BOOT Contract) has not occurred on or before the Project COD Deadline, at any time after such date Lessor may terminate this Lease.

  • If the In-Service Date has not occurred on or before the Day that is the Project COD Deadline, Buyer may terminate this Agreement by written notice to the Seller and shall be entitled to the amount of one hundred fifty thousand dollars ($150,000) multiplied by the Project Capacity (“COD Liquidated Damages”) as its sole remedy, less any Daily Delay Liquidated Damages already paid by Seller.

  • In the event that the Commercial Operation Date does not occur by the COD Deadline, Buyer shall be entitled to terminate this Agreement by giving Seller prior written notice of ten (10) Business Days.

  • Subject to limitations on Project Participants’ Import Capability, as set forth below, Seller shall use commercially reasonable efforts to deliver to Buyer, on or before the Final COD Deadline, Project Net Capacity equal to the Maximum Capacity.

  • Seller shall determine the location, design, configuration, and Facility Net Capacity of each Facility, subject to the Requirements and to any conditions which are imposed by any Governmental Authority as part of the environmental review of each Facility required under applicable Federal and Nevada or California Requirements of Law, as applicable; provided, each Facility shall be a Firm Clean Resource and shall have a Commercial Operation Date that occurs no later than the Final COD Deadline.

  • Payment of Construction Delay Damages shall be Buyer’s sole and exclusive remedy for any failure to achieve the Commercial Operation Date by the Scheduled Commercial Operation Date, and the right to terminate (as set forth in this Section 2.4) shall be Buyer’s sole and exclusive remedy for any failure to achieve the Commercial Operation Date by the COD Deadline.

  • If Project COD has not occurred on or before the day that is the Project COD Deadline, Buyer may terminate this Agreement by written notice to the Seller and shall be entitled to the amount of $150,000 multiplied by the Project Capacity (“COD Liquidated Damages”) as its sole remedy, less any Daily Delay Damages already paid by Seller.

  • In addition to the right to terminate upon a Buyer Event of Default as provided in Article 6, Seller shall have the right at any point up to the Project COD Deadline, unless waived by Seller in writing, to terminate this Agreement, without any further or financial obligation to Buyer as a result of such termination, by written notice to Buyer if either event described in Section 2.4.1 or 2.4.2 has not been waived or satisfied.

  • SRP will provide Customer with periodic updates on the construction status of the Facility, and will use commercially reasonable efforts to promptly notify Customer if SRP learns of any event or circumstance that will delay, or is reasonably likely to delay, the Facility COD beyond the COD Deadline.


More Definitions of COD Deadline

COD Deadline means July 31, 2007, except that the COD Deadline shall be extended day for day for any extension of the Scheduled Commercial Operation Date pursuant to the definition thereof.
Sample 1Sample 2
COD Deadline means 12 months after the date on which all the necessary permits and authorizations have been obtained to start the assembly of the Dedicated Installation.
Sample 1

Related to COD Deadline

  • Claim Deadline means the last date by which a Claim submitted to the Settlement Administrator by a Settlement Class Member must be postmarked or submitted electronically, which will be ninety (90) Days after the Notice Deadline. All Claims postmarked or submitted electronically at the Settlement Website on or before the Claim Deadline shall be timely, and all Claims postmarked or submitted electronically at the Settlement Website after the Claim Deadline shall be untimely and barred from entitlement to any Settlement Relief.

  • Bid Deadline means the last date and time for submission of Bid in response to this RFP as specified in Bid Information Sheet;

  • Claims Deadline means the date by which all Claim Forms must be received to be considered timely and shall be set as the date ninety (90) days after the Notice Date. The Claims Deadline shall be clearly set forth in the Long Form Notice, the Summary Notice, the Claim Form, and the Court’s order granting Preliminary Approval.

  • Response Deadline means 60 days after the Administrator mails Notice to Class Members and Aggrieved Employees, and shall be the last date on which Class Members may: (a) fax, email, or mail Requests for Exclusion from the Settlement, or (b) fax, email, or mail his or her Objection to the Settlement. Class Members to whom Notice Packets are resent after having been returned undeliverable to the Administrator shall have an additional 14 calendar days beyond the Response Deadline has expired.

  • Opt-Out Deadline means the deadline set by the Court for the timely submission of requests by Settlement Class Members to be excluded from the Settlement Class.

  • Submission Deadline means 1:00 P.M., New York City time, on any Auction Date or such other time on any Auction Date as may be specified by the Auction Agent from time to time as the time by which each Broker-Dealer must submit to the Auction Agent in writing all Orders obtained by it for the Auction to be conducted on such Auction Date.

  • Objection Deadline means the date identified in the Preliminary Approval Order and Class Notice by which a Settlement Class Member must serve written objections, if any, to the Settlement to be able to object to the Settlement. The Objection Deadline shall be no later than 30 days before the Final Approval Hearing.

  • Qualification Deadline has the meaning set forth in Section 2(a)(ii).

  • Application Deadline means 5:00 p.m., Eastern Time, on the final day of the Application Period.

  • Election Deadline shall have the meaning set forth in Section 3.2.3.

  • Completion Deadline means the date by which the Arrangement is to be completed, which date shall be April 30, 2014 or such later date as may be agreed to in writing by the Parties;

  • Offer Deadline means the exact date and time when no Offer submitted thereafter may be considered or accepted by District.

  • Notice Deadline means 2.30 p.m. (Dublin time), provided that the Notice Deadline in respect of any Series of ETP Securities may be adjusted by agreement between the Issuer and the Margin Loan Provider with effect from the fifth calendar day following the date on which notice of such adjustment is given to the holders in accordance with Condition 17.

  • Plan Objection Deadline means the date the Bankruptcy Court establishes as the deadline to File an objection to Confirmation of the Plan.

  • Filing Deadline Date has the meaning set forth in Section 2(a) hereof.

  • Extension Deadline means, with respect to a letter of credit, the Cutoff Time on the Business Day preceding the day on which the letter of credit expires.

  • CHECK-IN DEADLINE means the time limit specified by us by which you must have completed check-in formalities and received your boarding pass.

  • Cure Deadline shall have the meaning provided in Section 11.11(a).

  • Claim Objection Deadline means the first Business Day that is 180 days after the Effective Date, as may be extended by order of the Bankruptcy Court.

  • Claims Objection Deadline means the deadline for objecting to a Claim against a Debtor, which shall be on the date that is the later of (a) 180 days after the Effective Date and (b) such other period of limitation as may be fixed by the Debtors or the Reorganized Debtors, as applicable, or by an order of the Court for objecting to such Claims.

  • Closing Deadline means the date and time specified on the RFP Cover Page or any Addenda issued by TO LIVE, as the date and time by which Proponents must submit their Proposal;

  • Filing Deadline As defined in Sections 3(a) and 4(a) hereof.

  • Voting Deadline means the deadline for submitting Ballots to accept or reject the Plan in accordance with section 1126 of the Bankruptcy Code that is specified in the Disclosure Statement, the Ballots or related solicitation documents approved by the Bankruptcy Court.

  • Deadline Date has the meaning set forth in Section 4.1(f).

  • Dealing Deadline means in relation to a Fund, such time on any Dealing Day as shall be specified in the relevant Supplement for the Fund.

  • LIBOR Deadline has the meaning set forth in Section 2.13(b)(i).