Defects Liability definition

Defects Liability means the term detailed in Clause 29.
Sample 1
Defects Liability means a period shall be 12 months after Completion and handing over of the project and any period extended as a result of rectification of the Work/change orders, between the Virtual Completion and the Final Completion of the Work, and during which period the Contractor shall be bound to replace and/or rectify and make good all defective materials, equipment and/or workmanship which arise in the Works or come to notice subsequent to the Virtual Completion of the Works and prior to the Final Completion of the Works without requiring the PMFPPL to bear any additional charges whatsoever.
Sample 1
Defects Liability means liability to pay for the cost of rectifying any defect in Your plumbing work carried out in Victoria.
Sample 1

Examples of Defects Liability in a sentence

  • Loss or damage to the Works or Materials to be incorporated in the Works between the Start Date and the end of the Defects Liability Periods shall be remedied by the Contractor at the Contractor’s cost if the loss or damage arises from the Contractor’s acts or omissions.

  • The Defects Liability Period shall be extended for as long as Defects remain to be corrected.

  • The expression "the Works" shall, in respect of the Defects Liability Period, be construed accordingly.

  • Upon issuance of the Certificate of Substantial Completion of the Works, the Contractor shall be deemed to have undertaken to complete with due expedition any outstanding work during the Defects Liability Period.

  • When the whole of the Works have been substantially completed and have satisfactorily passed any test on completion prescribed by the Contract, the Contractor may give a notice to that effect to the Engineer accompanied by an undertaking to finish any outstanding work during the Defects Liability Period.

  • If by reason of any accident or failure or other event occurring to, in or in connection with the Works or any part thereof either during the execution of the Works or during the Defects Liability Period any remedial or other work or repair shall in the opinion of the Engineer be urgently necessary for security and the Contractor is unable or unwilling at once to do such work or repair, the Employer may by his own or other workmen do such work or repair as the Engineer may consider necessary.

  • The expression "Defects Liability Period" shall mean the period of twelve (12) months, calculated from the date of completion of the Works stated in the Certificate of Substantial Completion issued by the Engineer or, in respect of any Section or part of the Works for which a separate Certificate of Substantial Completion has been issued, from the date of completion of that Section or part as stated in the relevant Certificate.

  • No claim shall be made against the Balance Contract Deposit after the issue of Defects Liability Certificate.

  • Upon satisfactory completion of the work outstanding on the Works, the Engineer shall within twenty eight (28) days of the expiration of the Defects Liability period issue a Certificate of Final Completion to the Contractor.

  • The Defects Liability Certificate is the certificate issued by Procuring Entity’s Representative upon correction of defects by the Contractor.

Related to Defects Liability

  • Products Liability means:Your legal liability in respect of Personal Injury and/or Property Damage caused by or arising out of any Products or the reliance upon a representation or warranty made at any time with respect to such products; but only where such Personal Injury and/or Property Damage occurs away from premises owned or leased by or rented to You and after physical possession of such products has been relinquished to others.

  • Defects Liability Period means the warranty period following the taking over, during which the Contractor is responsible for making good, defects and damage in Goods and Services provided, under the Contract.

  • Product Liability means any liability, claim or expense, including but not limited to attorneys’ fees and medical expenses, arising in whole or in part out of a breach of any express or implied product warranty by the Company, strict liability in tort, negligent manufacture of product, negligent provision of services, product recall, or any other allegation of liability arising from the design, testing, manufacture, packaging, labeling (including instructions for use), or sale of products.

  • Defects Liability Expiry Certificate means the certificate to be issued by the Client to the Contractor, in accordance with the Contract.

  • Defects Liability Period (Warranty Period) means the period stated in the Schedule A Special Stipulations, following the taking over, during which the Contractor is responsible for making good defects and damage in accordance with Clause 15.

  • Defects Liability Certificate means the certificate issued by Architect upon correction of defects by the Contractor.

  • Maximum Liability has the meaning assigned to such term in Section 10.10.

  • Defect Liability Period in relation to a work means the specified period from the date of COMPLETION CERTIFICATE upto the date of issue of FINAL CERTIFICATE during which the CONTRACTOR stands responsible for rectifying all defects that may appear in the works executed by the CONTRACTOR in pursuance of the CONTRACT and includes warranties against Manufacturing/Fabrication/ Erection/Construction defects covering all materials plants, equipment, components, and the like supplied by the CONTRACTOR, works executed against workmanship defects.

  • Environmental Damages means all liabilities (including strict liability), losses, damages (excluding consequential, special, exemplary or punitive damages except to the extent such damages were imposed upon an Indemnitee as a result of any claims made against such Indemnitee by a governmental entity or any other third party), judgments, penalties, fines, costs and expenses (including fees, costs and expenses of attorneys, consultants, contractors, experts and laboratories), of any and every kind or character, at law or in equity, contingent or otherwise, matured or unmatured, foreseeable or unforeseeable, made, incurred, suffered, brought, or imposed at any time and from time to time, whether before or after the Release Date and arising in whole or in part from:

  • Product Liability Claim means a Claim of a Third Party (other than a Claim arising out of use of the Product in a clinical trial) that (i) arises as a result of the use of the Product during the Term that results in personal injury or death or (ii) is in anticipation of or intended to prevent or forestall personal injury or death as a result of the use of the Product during the Term.

  • BRRD Liability means a liability in respect of which the relevant Write Down and Conversion Powers in the applicable Bail-in Legislation may be exercised.

  • Product Liabilities means all claims, Liabilities and Proceedings related to or arising from actual or alleged harm, injury, damage or death to persons, animals, property or business, irrespective of the legal theory asserted, and resulting from or alleged to result from the use, sale or manufacture of the Products.

  • Breach of Contract means the failure of a Party to perform any of its obligations in accordance with this Contract, in whole or in part or in a timely or satisfactory manner. The institution of proceedings under any bankruptcy, insolvency, reorganization or similar law, by or against Contractor, or the appointment of a receiver or similar officer for Contractor or any of its property, which is not vacated or fully stayed within 30 days after the institution of such proceeding, shall also constitute a breach. If Contractor is debarred or suspended under §24-109-105, C.R.S. at any time during the term of this Contract, then such debarment or suspension shall constitute a breach.

  • Legal Liability means responsibility which courts recognize and enforce between persons who sue one another.

  • Indemnity Obligations means all obligations of the Company to Indemnitee under this Agreement, including the Company’s obligations to provide indemnification to Indemnitee and advance Expenses to Indemnitee under this Agreement.

  • Seller Damages shall have the meaning given to such term in Section 14.3.

  • Excluded Liability means any liability that is excluded under the Bail-In Legislation from the scope of any Bail-In Action including, without limitation, any liability excluded pursuant to Article 44 of the Bank Recovery and Resolution Directive.

  • Environmental Damage means any material injury or damage to persons, living organisms or property or any material pollution or impairment of the environment resulting from the discharge, emission, escape or migration of any substance, energy, noise or vibration;

  • Loss or Damage means any loss or damage to the Vehicle, including that caused by theft of the Vehicle or by adverse weather events, that requires repair or replacement including the loss of use of the Vehicle (demurrage), legal expenses, assessment fees, towing and recovery costs, storage, service charges and any appraisal fees of the Vehicle;

  • AND LIABILITY LIMITS State Street shall assume no responsibility for lost interest with respect to the refundable amount of any unauthorized payment order, unless State Street is notified of the unauthorized payment order within thirty (30) days of notification by State Street of the acceptance of such payment order. In no event shall State Street be liable for special, indirect or consequential damages, even if advised of the possibility of such damages and even for failure to execute a payment order.

  • Indemnification Obligations means each of the Debtors’ indemnification obligations in place as of the Effective Date, whether in the bylaws, certificates of incorporation or formation, limited liability company agreements, other organizational or formation documents, board resolutions, management or indemnification agreements, or employment or other contracts, for their current and former directors, officers, managers, members, employees, attorneys, accountants, investment bankers, and other professionals and agents of the Debtors.

  • Damage to Property means physical injury to or destruction of tangible property, including the loss of its use. Tangible property includes the cost of recreating or replacing stocks, bonds, deeds, mortgages, bank deposits and similar instruments, but does not include the value represented by such instruments.

  • Personal liability means personal liability for a debt, liability, or other obligation of an organization which is imposed on a person that co-owns, has an interest in, or is a member of the organization:

  • Express warranty means an express warranty as set forth in sections 4-2-313 and 4-2.5-210, C.R.S. An express warranty shall cover every part of a new facilitative device.

  • Cover Damages means, with respect to any Delivery Failure, an amount equal to (a) the positive net amount, if, any, by which the Replacement Price exceeds the applicable Price that would have been paid pursuant to Section 5.1 hereof, multiplied by the quantity of that Delivery Failure, plus (b) any applicable penalties and other costs assessed by ISO-NE or any other Person against Buyer as a result of Seller’s failure to deliver such Products in accordance with the terms of this Agreement. Buyer shall provide a statement for the applicable period explaining in reasonable detail the calculation of any Cover Damages.

  • Limitation of Liability PrimePay has negotiated preferred terms and conditions with FD as a service to PrimePay Clients. Client understands that FD, and not PrimePay, will be performing those services and that Client will enter its own service agreement(s) with FD for such services under terms and conditions specified by FD and agreed to by Client. Accordingly, Client acknowledges that FD shall be the provider of Payment Processing Services hereunder and that PrimePay shall have no liability whatsoever for or related to the performance of those services, including any and all damages, costs and related expenses (including attorney fees).