Failure to Deliver Damages has the meaning set forth in Section 7.8(a)(vi).
Cover Damages means, with respect to any Delivery Failure, an amount equal to (a) the positive net amount, if, any, by which the Replacement Price exceeds the applicable Price that would have been paid pursuant to Section 5.1 hereof, multiplied by the quantity of that Delivery Failure, plus (b) any applicable penalties and other costs assessed by ISO-NE or any other Person against Buyer as a result of Seller’s failure to deliver such Products in accordance with the terms of this Agreement. Buyer shall provide a statement for the applicable period explaining in reasonable detail the calculation of any Cover Damages.
Actual Damages has the meaning set forth in Section 12.4(C).
Seller Damages shall have the meaning given to such term in Section 14.3.
Loss or Damage means any loss or damage to the Vehicle, including that caused by theft of the Vehicle or by adverse weather events, that requires repair or replacement including the loss of use of the Vehicle (demurrage), legal expenses, assessment fees, towing and recovery costs, storage, service charges and any appraisal fees of the Vehicle;
Special Damages has the meaning specified in Section 11.21.
Direct Damage has the meaning given to it in clause 26.2;
Delay Damages means the damages assessed pursuant to Section 3.2(a) hereof.
Punitive Damages are those damages awarded as a penalty, the amount of which is neither governed nor fixed by statute.
Consequential Damages means Losses claimed to have resulted from any indirect, incidental, reliance, special, consequential, punitive, exemplary, multiple or any other Loss, including damages claimed to have resulted from harm to business, loss of anticipated revenues, savings, or profits, or other economic Loss claimed to have been suffered not measured by the prevailing Party’s actual damages, and any other damages typically considered consequential damages under Applicable Law, regardless of whether the Parties knew or had been advised of the possibility that such damages could result in connection with or arising from anything said, omitted, or done hereunder or related hereto, including willful acts or omissions.
Major Damage means damage that in the estimation of the surveyor exceeds USD
Daily Delay Damages means with respect to a Guaranteed Project Milestone, an amount equal to (a) the Project Development Security Amount posted as of the first date that Daily Delay Damages are payable under this Agreement with respect to such Guaranteed Project Milestone, divided by (b) 120.
Environmental Damages means all liabilities (including strict liability), losses, damages (excluding consequential, special, exemplary or punitive damages except to the extent such damages were imposed upon an Indemnitee as a result of any claims made against such Indemnitee by a governmental entity or any other third party), judgments, penalties, fines, costs and expenses (including fees, costs and expenses of attorneys, consultants, contractors, experts and laboratories), of any and every kind or character, at law or in equity, contingent or otherwise, matured or unmatured, foreseeable or unforeseeable, made, incurred, suffered, brought, or imposed at any time and from time to time, whether before or after the Release Date and arising in whole or in part from:
Rejection Damages Claim means any Claim on account of the rejection of an Executory Contract or Unexpired Lease pursuant to section 365 of the Bankruptcy Code or the repudiation of such contract.
Economic damages means objectively verifiable monetary losses, including medical expenses, loss of earnings, burial costs, loss of use of property, cost of replacement or repair, cost of obtaining substitute domestic services, loss of employment, and loss of business or employment opportunities.
Catastrophic Damage as used hereunder is major change or damage to In- cluded Timber on Sale Area, to Sale Area, to access to Sale Area, or a combination thereof:
Indemnified Damages shall have the meaning assigned to such term in Section 6(a).
Consequential Loss means indirect or consequential loss or damage such as, but not limited to, loss of contract, bargain, expectation, opportunity, profit, production, revenue, anticipated cost reduction or interest payable howsoever caused, arising out of or in connection with this Contract.
Breach of Contract means the failure of a Party to perform any of its obligations in accordance with this Contract, in whole or in part or in a timely or satisfactory manner. The institution of proceedings under any bankruptcy, insolvency, reorganization or similar law, by or against Contractor, or the appointment of a receiver or similar officer for Contractor or any of its property, which is not vacated or fully stayed within 30 days after the institution of such proceeding, shall also constitute a breach. If Contractor is debarred or suspended under §24-109-105, C.R.S. at any time during the term of this Contract, then such debarment or suspension shall constitute a breach.
Structural damage means a covered building, regardless of the date of its construction, has experienced the following.
Work loss means loss of income from work the injured victim would have performed if the injured victim had not been injured and expenses reasonably incurred by the injured victim in obtaining services in lieu of those the injured victim would have performed for income,
Indemnifiable Damages shall have the meaning set forth in Section 9.1 herein.
Physical Damage means tangible damage to a Property that materially adversely affects the use, marketability, or value of the Property, whether caused by accident or otherwise, including, but not limited to damage caused by reason of fire, destruction of tangible property, defects in construction, land subsidence, earth movement or slippage, flood, earthquake, war, civil insurrection, or riot; and further, Physical Damage includes Environmental Impairment and the destruction or removal of chattel items that are considered part of the Property (see Section I., KK., [Property]) For purposes of this definition "material" shall mean an amount equal to or greater than $1,500.00 such that the estimated cost to repair a Property is $1,500.00 or more before the exclusion set forth in Section III., G., (Physical Damage Exclusion) would apply to exclude coverage for a Loan. The presence of radon gas, lead paint or asbestos in the dwelling on the Property shall not be deemed to be Physical Damage.
Resale Damages means, with respect to any Rejected Purchase, an amount equal to (a) the positive net amount, if any, by which the applicable Price that would have been paid pursuant to Section 5.1 hereof for such Rejected Purchase, had it been accepted, exceeds the Resale Price multiplied by the quantity of that Rejected Purchase, plus (b) any applicable penalties assessed by ISO-NE or any other Person against Seller as a result of Buyer’s failure to accept such Products. Seller shall provide a written statement explaining in reasonable detail the calculation of any Resale Damages.
Breach of Agreement provisions of Section 5(a)(ii) will apply to Party A and will not apply to Party B.
Defects Liability Expiry Certificate means the certificate to be issued by the Client to the Contractor, in accordance with the Contract.
Limitation of Liability PrimePay has negotiated preferred terms and conditions with FD as a service to PrimePay Clients. Client understands that FD, and not PrimePay, will be performing those services and that Client will enter its own service agreement(s) with FD for such services under terms and conditions specified by FD and agreed to by Client. Accordingly, Client acknowledges that FD shall be the provider of Payment Processing Services hereunder and that PrimePay shall have no liability whatsoever for or related to the performance of those services, including any and all damages, costs and related expenses (including attorney fees).