General Construction Agreement definition

General Construction Agreement means that certain agreement between the Borrower and the General Contractor dated as of December 21, 2011, together with all riders, addenda and other instruments referred to therein, as amended, modified or supplemented from time to time.
Sample 1Sample 2Sample 3
General Construction Agreement means that certain agreement between the Borrower and the General Contractor dated as of September 25, 2014, together with all riders, addenda and other instruments referred to therein, as amended, modified or supplemented from time to time in accordance with the terms hereof (except Change Orders that are, in each instance, for an amount less than $10,000,000 and, in the aggregate (taken together with all such other Change Orders) less than $150,000,000).
Sample 1Sample 2Sample 3
General Construction Agreement means that certain agreement between the Borrower and the General Contractor dated as of February 5, 2013, together with all riders, addenda and other instruments referred to therein, as amended, modified or supplemented from time to time.
Sample 1Sample 2

Examples of General Construction Agreement in a sentence

  • Brief, Ex. A (“The undersigned Employer and Unions hereby agree to be bound by the terms and conditions set forth in the 2007-12 Building Site and General Construction Agreement, which agreement is incorporated herein as if set forth in the full.”).

  • This construction will be carried out under one General Construction Agreement covering the construction work on this project.

  • Process of the adoption of the practice The Professional Training Card (TPC) was implemented pursuant to the General Construction Agreement (2007) and Law 32/2006 of 18th of October regulating subcontracting in the construction sector.

  • Project will be constructed under a General Construction Agreement.

  • These unions are not part of the General Construction Agreement, and contested the obliga- tion to have the card entailed therein on the basis of their representativeness at regional level.

  • After proposals are received in response hereto and notice of intent to award a contract is made, the successful Respondent will be required to enter into a contract in the form of the Owner’s standard General Construction Agreement.

  • Should any such approval be denied, this resolution and the General Construction Agreement is deemed null and void; 3.

  • To approve the attached Change Order EC-4 to the Freeport Area Athletics Stadium Project General Construction Agreement with Bronder Technical Services, Inc.

  • To approve the attached Change Order EC-2 to the Freeport Area Athletics Stadium Project General Construction Agreement with Bronder Technical Services, Inc.

  • To approve the attached Change Order EC-3 to the Freeport Area Athletics Stadium Project General Construction Agreement with Bronder Technical Services, Inc.


More Definitions of General Construction Agreement

General Construction Agreement means that certain Cubic Corporation Headquarters/CTS Building General Contractor Agreement (Cost of the Work with a Fee and Guaranteed Maximum Price), dated as of February 5, 2019, by and among General Contractor, Developer and Construction Agent, as agent for the Lessor, together with all addendums appended thereto, and assigned to the Lessor pursuant to the Assignment of Contracts, as it may be amended, supplemented or modified from time to time in accordance with the terms thereof and of the Construction and Development Agreement.
Sample 1Sample 2
General Construction Agreement means that certain (i) Project Specific Agreement (PSA No. 001), dated as of February 1, 2023, by and between Parent Guarantor and the General Table of Contents Contractor and assigned to the Lessor, (ii) Project Specific Agreement (PSA No. 002), dated as of November 15, 2023, by and between Parent Guarantor and the General Contractor and assigned to the Lessor, (iii) Project Specific Agreement (PSA No. 003), dated as of December 1, 2023, by and between Parent Guarantor and the General Contractor and assigned to the Lessor, (iv) Project Specific Agreement (PSA No. 004), dated as of December 3, 2023, by and between Parent Guarantor and the General Contractor and assigned to the Lessor, (v) Project Specific Agreement (PSA No. 006), dated as of January 23, 2024, by and between Parent Guarantor and the General Contractor and assigned to the Lessor, (vi) any other Project Specific Agreement entered into on or after the Document Closing Date, by and between Lessor and the General Contractor (or the General Contractor and Parent Guarantor and assigned to the Lessor) (in each case, pursuant to the terms of the Operative Documents) and (vii) Corning Master Agreement, dated as of February 1, 2023 (as amended by that certain First Amendment to Corning Master Agreement, dated as of February 28, 2024), by and between Parent Guarantor and the General Contractor, as incorporated into the Project Specific Agreements referred to in clauses (i) through (vi), which contract shall be a guaranteed maximum price or fixed price contract.
Sample 1
General Construction Agreement means either or both of (i) the Core and Shell Construction Agreement and (ii) the Interior Construction Agreement.
Sample 1

Related to General Construction Agreement

  • Construction Agreement as used in this subsection means an agreement between Seller and any contractor or subcontractor to install the System;

  • Construction Agreements means agreements to which Tenant is a party for Construction Work, rehabilitation, alteration, repair, replacement or demolition performed pursuant to this Lease.

  • Residential construction means construction on single-family or two-family dwellings occupied or used, or intended to be occupied or used, primarily for residential purposes, and includes real property pursuant to chapter 499B.

  • Original construction ’ shall mean the first or initial construction

  • Interconnection Construction Service Agreement means the agreement entered into by an Interconnection Customer, Interconnected Transmission Owner and the Transmission Provider pursuant to Tariff, Part VI, Subpart B and in the form set forth in Tariff, Attachment P, relating to construction of Attachment Facilities, Network Upgrades, and/or Local Upgrades and coordination of the construction and interconnection of an associated Customer Facility. A separate Interconnection Construction Service Agreement will be executed with each Transmission Owner that is responsible for construction of any Attachment Facilities, Network Upgrades, or Local Upgrades associated with interconnection of a Customer Facility. Interconnection Customer:

  • Pre-Construction Phase Services means the participation, documentation and execution of Contractor’s Pre-Construction Phase deliverables as required by this Agreement and further defined in Article 5.

  • New construction means, for the purposes of determining insurance rates, structures for which the "start of construction" commenced on or after the effective date of an initial FIRM or after December 31, 1974, whichever is later, and includes any subsequent improvements to such structures. For floodplain management purposes, "new construction" means structures for which the "start of construction" commenced on or after the effective date of the floodplain management regulations adopted by a community and includes any subsequent improvements to such structures.

  • GENERAL AND SPECIAL CONDITIONS OF CONTRACT means the instructions to Tenderer and General and special conditions of contract pertaining to the work for which above tenders have been called for.

  • Acquisition and Construction Fund means the fund so designated in, and created pursuant to, Section 502 hereof.

  • The constructional plant means all appliances, tools, plants or machinery or whatsoever nature required in or about the execution, completion or maintenance of the works but does not include materials or other things intended to form part of the permanent work.

  • Construction Service Agreement means either an Interconnection Construction Service Agreement or an Upgrade Construction Service Agreement.

  • Completion of Construction means the date, as determined by the Division after consultation with the Recipient, that the work of building and erection of the Project is substantially complete.

  • Construction Management Agreement means the Construction Management Agreement, dated as of the date of the Common Agreement, between Construction Manager and the Project Company.

  • Commencement of Construction means the commencement of construction of foundation components or elements (such as footings, rafts or piles) for the home.

  • Pipeline Construction means a substantial disturbance to agricultural land associated with installation, replacement, removal, operation or maintenance of a pipeline, but shall not include work performed during an emergency. Emergency means a condition where there is clear and immediate danger to life or health, or essential services, or a potentially significant loss of property. When the emergency condition ends, pipeline construction will be in accordance with these rules.

  • General Conditions of Contract means the ‘Instructions to Tenderers’ and ‘General Conditions of Contract’ pertaining to the work for which above tenders have been called for.

  • Existing construction means any structure for which the "start of construction" commenced before the effective date of the initial floodplain management code or ordinance adopted by the community as a basis for that community's participation in the NFIP.

  • Implementation Agreement means the Implementation Agreement dated ……… by and between the GOB, PGCB and the Company in connection with the Project, and also includes any amendment of it made from time to time;

  • Construction Services Agreement means this Construction Services Agreement, together with any duly authorized and executed amendments hereto.

  • Commence Construction means that an owner or operator has either undertaken a continuous program of construction or has entered into a contractual obligation to undertake and complete, within a reasonable time, a continuous program of construction.

  • Start of construction means the date the development permit was issued, provided the actual start of construction, repair, reconstruction, or improvement was within 180 days of the permit date. The actual start means the first placement of permanent construction of the structure such as the pouring of slabs or footings, installation of piles, construction of columns, or any work beyond the stage of excavation, and includes the placement of a manufactured home on a foundation. (Permanent construction does not include initial land preparation, such as clearing, grading and filling; nor does it include the installation of streets and/or walkways; nor does it include excavation for a basement, footings, piers or foundations or the erection of temporary forms; nor does it include the installation on the property of buildings appurtenant to the permitted structure, such as garages or sheds not occupied as dwelling units or part of the main structure. (NOTE: accessory structures are NOT exempt from any ordinance requirements) For a substantial improvement, the actual start of construction means the first alteration of any wall, ceiling, floor, or other structural part of a building, whether or not that alteration affects the external dimensions of the building.

  • General Conditions means the “International Development Association General Conditions for Credits and Grants”, dated July 1, 2005 (as amended through October 15, 2006).

  • Project Management Agreement means the agreement dated the 20th February 1985 made between the Trustee and the Manager providing for the Manager to manage and co‑ordinate the development and construction of the Resort and includes, if that agreement is terminated, any other agreement in like and similar terms made with the prior consent of the Minister;

  • Reservation agreement means a written contract entered into between MBOH and the taxpayer to provide for a Reservation and setting forth the terms and conditions under which the taxpayer may obtain a Carryover Commitment or Final Allocation.

  • Building construction means any physical activity on the site involved in the erection of a structure, cladding, external finish, formwork, fixture, fitting of service installation and the unloading of plant, machinery, materials or the like.

  • Transition Agreement has the meaning set forth in Section 12.8.1.