Labor Harmony. The parties acknowledge that it is of the utmost importance to City, Tenant, and all those occupying or to occupy space in the Domestic and International Terminals that there be no interruption in the progress of the construction work. Accordingly, City and Tenant agree as follows:
Labor Harmony. Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment, or labor and employment practices that, in Landlord’s good faith judgment, may cause strikes, picketing or boycotts or disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Property.
Labor Harmony. Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment, or labor and employment practices that, in Landlord's good faith judgment, may cause strikes, picketing or boycotts or disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Property.
Labor Harmony. The Shareholder shall cause its contractors and subcontractors to undertake the Work, and employ only such laborers, as shall not in any manner interfere or conflict with, or cause any labor disturbances or stoppages with, any of the unions whose members are either employees of the Corporation or employees of any contractor or other third party servicing the Building.
Labor Harmony. Tenant agrees that any work performed by or on behalf of Tenant or any Tenant Party shall be performed in such manner and by such persons as shall maintain harmonious labor relations at the Project. If labor disharmony arises as a result of non-union labor employed by a subcontractor or other contractor engaged by Tenant or any Tenant Party, and such labor disharmony causes a delay in the construction of the Non-TI Project Improvements or Landlord’s Work, such delay shall be a Tenant Delay under this Work Letter. If labor disharmony arises as a result of a contractor or subcontractor engaged by Tenant or any Tenant Party, or if Landlord reasonably believes that a contractor or subcontractor employed by Tenant or any Tenant Party will cause labor disharmony in the Project, Landlord shall have the right, in addition to other rights and remedies under the Work Letter or Lease, to exclude from the Premises and Project such contractor or subcontractor employed by Tenant or any Tenant Party.
Labor Harmony. Tenant shall not, at any time prior to or during the Demised Term, directly or indirectly employ, or permit the employment of, any contractor, mechanic or laborer in the Demised Premises, whether in connection with any Alteration or otherwise, if such employment will interfere or cause any conflict with other contractors, mechanics, or laborers engaged in the construction, maintenance or operation of the Building by Owner, Tenant or others. In the event of any such interference or conflict, Tenant, upon demand of Owner, shall cause all contractors, mechanics or laborers causing such interference or conflict to leave the Building immediately.
Labor Harmony. The Trade Contractor shall only employ labor in connection with the Trade Contractor Work capable of working harmoniously with all trades, crafts, and any other Persons associated with the Project. The Trade Contractor shall also use its best efforts to minimize the likelihood of any strike, work stoppage, or other labor disturbance.
Labor Harmony. Tenant will not, directly or indirectly, employ or permit the employment of any contractor, shipper, mechanic or laborer or permit any items or materials to be brought into the Premises or the rest of the Project, if it would create any work slow down, sabotage, strike, wild-cat strike, picketing or jurisdictional dispute, or would in any way disturb the peaceful and harmonious operation, management, maintenance, cleaning, security or improvement of the Project or Minuteman Park or any part thereof (in any case, a “Labor/Disturbance Incident”). Tenant will be solely responsible for all Liabilities resulting from any such Labor/Disturbance incident, and, without limiting any other rights and remedies of Landlord, upon demand of Landlord Tenant at its cost immediately will cause all contractors, shippers, mechanics, laborers, items or materials that are the subject or cause of such Labor/Disturbance Incident to be removed from the Project.
Labor Harmony. If (i) Tenant employs, or permits the employment of, any contractor, mechanic or laborer in the Premises, whether in connection with any Alteration or otherwise, (ii) such employment interferes or causes any conflict with other contractors, mechanics or laborers engaged in the maintenance, repair, management or operation of the Building or any adjacent property owned or managed by Landlord, and (iii) Landlord gives Tenant notice thereof (which notice may be given verbally to the person employed by Tenant with whom Landlord’s representative ordinarily discusses matters relating to the Premises), then Tenant shall cause all contractors, mechanics or laborers causing such interference or conflict to leave the Building promptly and shall take such other action as may be reasonably necessary to resolve such conflict.
Labor Harmony. The Trade Contractor will take all actions necessary, including entering into a Project Labor Agreement if required, to maintain labor harmony regarding the Trade Contractor work.
