Punitive Damages are those damages awarded as a penalty, the amount of which is neither governed nor fixed by statute.
Consequential Damages means Losses claimed to have resulted from any indirect, incidental, reliance, special, consequential, punitive, exemplary, multiple or any other Loss, including damages claimed to have resulted from harm to business, loss of anticipated revenues, savings, or profits, or other economic Loss claimed to have been suffered not measured by the prevailing Party’s actual damages, and any other damages typically considered consequential damages under Applicable Law, regardless of whether the Parties knew or had been advised of the possibility that such damages could result in connection with or arising from anything said, omitted, or done hereunder or related hereto, including willful acts or omissions.
Special Damages shall have the meaning as set forth in Section 5.07.
Compensatory Damages are those amounts awarded to compensate for the actual damages sustained, and are not awarded as a penalty, nor fixed in amount by statute.
Actual Damages has the meaning set forth in Section 12.4(C).
Damages means any loss, claim, damage, liability, costs and expenses (including, without limitation, reasonable attorney's fees and disbursements and costs and expenses of expert witnesses and investigation).
Direct Damage has the meaning given to it in clause 26.2;
Indirect Losses means loss of profits, loss of production, loss of business, loss of business opportunity, or any claim for consequential loss or for indirect loss of any nature;
Environmental Damages means all claims, judgments, damages, losses, penalties, fines, liabilities, encumbrances, liens, costs and expenses of investigation and defense of any claim, including, without limitation, attorney’s fees, that are incurred at any time as a result of the existence of Environmental Conditions upon, about or beneath the Project Site or migrating or threatening to migrate to or from the Site, and including, without limitation:
Consequential Loss means loss of profits, anticipated loss of profit or revenue, loss of production, loss of business opportunity, loss of or damage to goodwill or reputation, loss of use or any other similar loss, but excludes:
Delay Damages means the damages assessed pursuant to Section 3.2(a) hereof.
Economic damages means objectively verifiable monetary losses, including medical expenses, loss of earnings, burial costs, loss of use of property, cost of replacement or repair, cost of obtaining substitute domestic services, loss of employment, and loss of business or employment opportunities.
Indemnified Damages shall have the meaning assigned to such term in Section 6(a).
Loss or Damage means any loss or damage to the Vehicle, including that caused by theft of the Vehicle or by adverse weather events, that requires repair or replacement including the loss of use of the Vehicle (demurrage), legal expenses, assessment fees, towing and recovery costs, storage, service charges and any appraisal fees of the Vehicle;
Seller Damages shall have the meaning given to such term in Section 14.3.
Compensable injury means an injury by accident arising out of and in the course of hazardous employment which must be established by medical evidence supported by objective medical findings.
Direct Losses means all damages, losses, liabilities, penalties, fines, assessments, claims, actions, costs, expenses (including the cost of legal or professional services, legal costs being on a substantial indemnity basis), proceedings, demands and charges whether arising under statute, contract or at common law, except Indirect Losses.
Indemnified Matter has the meaning specified in Section 11.4 (Indemnities).
Attorneys’ Fees means the full and actual cost of any legal services actually performed in connection with the matter involved calculated on the basis of the usual fee charged by the attorney performing such services and shall not be limited to "reasonable attorneys' fees" as defined in any statute or rule of court.
Losses shall have the meaning set forth in Section 5(a).
Indemnified Matters has the meaning specified therefor in Section 12.15.
Breach of Contract means the failure of a Party to perform any of its obligations in accordance with this Contract, in whole or in part or in a timely or satisfactory manner. The institution of proceedings under any bankruptcy, insolvency, reorganization or similar law, by or against Contractor, or the appointment of a receiver or similar officer for Contractor or any of its property, which is not vacated or fully stayed within 30 days after the institution of such proceeding, shall also constitute a breach. If Contractor is debarred or suspended under §24-109-105, C.R.S. at any time during the term of this Contract, then such debarment or suspension shall constitute a breach.
Adverse Consequences means all actions, suits, proceedings, hearings, investigations, charges, complaints, claims, demands, injunctions, judgments, orders, decrees, rulings, damages, dues, penalties, fines, costs, amounts paid in settlement, Liabilities, obligations, Taxes, liens, losses, expenses, and fees, including court costs and attorneys' fees and expenses.
Noneconomic damages ’ means damages for phys-
Attorneys’ Fees and Expenses means such funds as may be awarded to Class Counsel by the Court to compensate them (and all other attorneys for Plaintiff or the Settlement Class) for their fees and all expenses incurred by Plaintiff or Class Counsel in connection with the Litigation.
Causes of Action means any claims, interests, damages, remedies, causes of action, demands, rights, actions, suits, obligations, liabilities, accounts, defenses, offsets, powers, privileges, licenses, liens, indemnities, guaranties, and franchises of any kind or character whatsoever, whether known or unknown, foreseen or unforeseen, existing or hereinafter arising, contingent or non-contingent, liquidated or unliquidated, secured or unsecured, assertable, directly or derivatively, matured or unmatured, suspected or unsuspected, in contract, tort, law, equity, or otherwise. Causes of Action also include: (a) all rights of setoff, counterclaim, or recoupment and claims under contracts or for breaches of duties imposed by law; (b) the right to object to or otherwise contest Claims or Interests; (c) claims pursuant to sections 362, 510, 542, 543, 544 through 550, or 553 of the Bankruptcy Code; and (d) such claims and defenses as fraud, mistake, duress, and usury, and any other defenses set forth in section 558 of the Bankruptcy Code.